Landlord Delay Landlord’s (a) failure to comply with any time requirements expressly set forth in Paragraph 2.d. above with respect to Landlord’s obligation to provide notice of approval or disapproval of the Space Plan, Working Drawings or Change Orders, or (b) Landlord’s unreasonable interference with the completion of Tenant Improvements, including any failure or refusal of Landlord or Landlord’s agents or contractors to permit Tenant, its agents or contractors, access to and use of the Building or any Building facilities or services (including hoists, elevators, and loading docks) which access or use is reasonably required for the orderly and continuous performance of the work necessary to complete Tenant Improvements, are referred to collectively herein as “Landlord Delay” (provided that no Landlord Delay as described in clause (b) above will be deemed to have occurred unless and until Tenant has notified Landlord of the event which Tenant claims constitutes a Landlord Delay and Landlord has failed to cure such event within five (5) Business Days thereafter). Tenant will use commercially reasonable efforts to mitigate its damages and/or construction delays in the event of an alleged Landlord Delay. Notwithstanding anything to the contrary in this Paragraph 2, if and to the extent Tenant reasonably incurs a net increased cost (taking into account any cost saving Landlord might have facilitated by its actions, including any Landlord Delay) of design or construction of the Tenant Improvements as a direct result of any Landlord Delay (as reasonably evidenced by Tenant, with supporting documentation), Landlord will be responsible for such reasonable increased costs and Landlord’s Allowance will be increased by the amount of such reasonable increased cost. Further, when determining whether a particular Landlord Delay delayed Substantial Completion of the Tenant Improvements, the subject Landlord Delay shall be offset by any action or response by Landlord that achieved a reduction in Tenant’s construction schedule (each day saved in Tenant’s construction schedule being a “Schedule Saving Day”) and any aggregate Landlord Delay as described in this Paragraph 2.f. shall first be offset against, and reduced on a day-for-day basis by, the aggregate number of Schedule Saving Days. In the event of a disagreement between Landlord and Tenant as to whether a Landlord Delay has occurred and/or as to the application of this grammatical paragraph, either party may submit the issue to the dispute resolution procedure set forth in Paragraph 2.j. below. This Paragraph 2.f. is inapplicable to delays in Delivery, whether caused by Landlord, Landlord’s Contractor or otherwise (such delays being expressly covered by Paragraph 2.a. above) and this Paragraph 2.f. only applies to delays in the commencement or Substantial Completion of the Tenant Improvements following Delivery.
Landlord’s Termination Right Whether or not the Premises are affected, Landlord may, by notice to Tenant, within 60 days following the date upon which Landlord receives notice of the Taking of all or a portion of the Real Property, the Building or the Premises, terminate this Lease, provided that Landlord elects to terminate leases (including this Lease) affecting at least 50% of the rentable area of the Building.
Tenant Delay If the Substantial Completion of the Tenant Improvement Work is delayed (a “Tenant Delay”) as a result of (a) any failure of Tenant to approve the Construction Pricing Proposal pursuant to Section 2.6 above on or before Tenant’s Approval Deadline; (b) Tenant’s failure to timely approve any matter requiring Tenant’s approval; (c) any breach by Tenant of this Work Letter or the Lease; (d) any request by Tenant for a revision to the Approved Construction Drawings (except to the extent such delay results from any failure of Landlord to perform its obligations under Section 2.7 above); (e) Tenant’s requirement for materials, components, finishes or improvements that are not available in a commercially reasonable time given the anticipated date of Substantial Completion of the Tenant Improvement Work as set forth in this Agreement; (f) any change to the base, shell or core of the Premises or Building required by the Approved Construction Drawings; or (g) any other act or omission of Tenant or any of its agents, employees or representatives, then, notwithstanding any contrary provision of this Agreement, and regardless of when the Tenant Improvement Work is actually Substantially Completed, the Tenant Improvement Work shall be deemed to be Substantially Completed on the date on which the Tenant Improvement Work would have been Substantially Completed if no such Tenant Delay had occurred.
Determination of Market Rent If Tenant timely and appropriately objects to the Market Rent in Tenant’s Acceptance, Landlord and Tenant shall attempt to agree upon the Market Rent using their best good-faith efforts. If Landlord and Tenant fail to reach agreement within twenty-one (21) days following Tenant’s Acceptance (“Outside Agreement Date”), then each party shall make a separate determination of the Market Rent which shall be submitted to each other and to arbitration in accordance with the following items (i) through (vii):
Determination of Option Rent In the event Tenant timely and appropriately exercises an option to extend the Lease Term, Landlord shall notify Tenant of Landlord’s determination of the Option Rent within thirty (30) days thereafter. If Tenant, on or before the date which is ten (10) days following the date upon which Tenant receives Landlord’s determination of the Option Rent, in good faith objects to Landlord’s determination of the Option Rent, then Landlord and Tenant shall attempt to agree upon the Option Rent using their best good-faith efforts. If Landlord and Tenant fail to reach agreement within ten (10) days following Tenant’s objection to the Option Rent (the “Outside Agreement Date”), then Tenant shall have the right to withdraw its exercise of the option by delivering written notice thereof to Landlord within five (5) days thereafter, in which event Tenant’s right to extend the Lease pursuant to this Section 2.2 shall be of no further force or effect. If Tenant does not withdraw its exercise of the extension option, each party shall make a separate determination of the Option Rent, as the case may be, within ten (10) days after the Outside Agreement Date, and such determinations shall be submitted to arbitration in accordance with Sections 2.2.3.1 through 2.2.3.7, below. If Tenant fails to object to Landlord’s determination of the Option Rent within the time period set forth herein, then Tenant shall be deemed to have objected to Landlord’s determination of Option Rent.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Tenant’s Termination Right If the part of the Buildings or the Real Property so acquired or condemned contains a substantial part of the total area of the portion of the Premises located in such Building immediately prior to such acquisition or condemnation, or if, by reason of such acquisition or condemnation, Tenant no longer has reasonable means of access to the Premises, Tenant may terminate this Lease as to such portion of the Premises by notice to Landlord given within 60 days following the date upon which Tenant received notice of such acquisition or condemnation; provided, however, that if the portion of the Premises so affected shall be the Music Hall, then Tenant’s right of termination shall apply to the whole of the Premises. Furthermore, if by virtue of the nature of the space in the Music Hall which is acquired or condemned, the space remaining in the Music Hall after giving effect to such acquisition or condemnation cannot economically be used for its intended purpose, following the date upon which Tenant received notice of such acquisition or condemnation, Tenant may terminate this Lease by notice to Landlord. If Tenant so notifies Landlord, this Lease shall terminate and the Term shall end and expire upon the date set forth in the notice as to the portion of the Premises covered thereby, which date shall not be more than 30 days following the giving of such notice. If a part of the Premises shall be so acquired or condemned and this Lease and the Term shall not be terminated in accordance with this Section, Landlord, at Landlord’s expense but without requiring Landlord to spend more than it collects as an award, shall, subject to the provisions of any Mortgage or Superior Lease, restore such portion of the Premises not so acquired or condemned to a self-contained unit substantially equivalent (with respect to character, quality, appearance and services) to that which existed immediately prior to such acquisition or condemnation, to the extent commercially practicable to do so, in which case Tenant shall be obligated to restore Tenant’s Property relating to such portion of the Premises to the condition which existed immediately prior to such acquisition or condemnation.
Non-Renewal Termination If the Agreement expires as set forth in Section 6(g) [Non-Renewal Termination], then, subject to Section 22 [Compliance with Section 409A], in addition to all salary, annual bonuses, expense reimbursements, benefits and accrued vacation days earned by the Executive pursuant to Section 4 through the date of the Executive’s termination of employment, the Executive shall be entitled to the compensation set forth in Sections 8(d)(i) through (v), provided that within sixty days following the Executive’s termination of employment (i) the Executive has executed and delivered the Release to the Company, and (ii) the Release has become irrevocable:
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Lease Termination Except as provided in this Section 9.04, upon expiration or earlier termination of this Lease Tenant shall surrender the Premises to Landlord in the same condition as existed on the date Tenant first occupied the Premises, (whether pursuant to this Lease or an earlier lease), subject to reasonable wear and tear. All Alterations shall become a part of the Premises and shall become the property of Landlord upon the expiration or earlier termination of this Lease, unless Landlord shall, by written notice given to Tenant, require Tenant to remove some or all of Tenant's Alterations, in which event Tenant shall promptly remove the designated Alterations and shall promptly repair any resulting damage, all at Tenant's sole expense. All business and trade fixtures, machinery and equipment, furniture, movable partitions and items of personal property owned by Tenant or installed by Tenant at its expense in the Premises shall be and remain the property of Tenant; upon the expiration or earlier termination of this Lease, Tenant shall, at its sole expense, remove all such items and repair any damage to the Premises or the Building caused by such removal. If Tenant fails to remove any such items or repair such damage promptly after the expiration or earlier termination of the Lease, Landlord may, but need not, do so with no liability to Tenant, and Tenant shall pay Landlord the cost thereof upon demand. Notwithstanding the foregoing to the contrary, in the event that Landlord gives its consent, pursuant to the provisions of Section 9.01 of this Lease, to allow Tenant to make an Alteration in the Premises, Landlord agrees, upon Tenant's written request, to notify Tenant in writing at the time of the giving of such consent whether Landlord will require Tenant, at Tenant's cost, to remove such Alteration at the end of the Lease Term.
