Certification of Funds; Budget and Fiscal Provisions; Termination in the Event of Non-Appropriation This Agreement is subject to the budget and fiscal provisions of the City’s Charter. Charges will accrue only after prior written authorization certified by the Controller, and the amount of City’s obligation hereunder shall not at any time exceed the amount certified for the purpose and period stated in such advance authorization. This Agreement will terminate without penalty, liability or expense of any kind to City at the end of any fiscal year if funds are not appropriated for the next succeeding fiscal year. If funds are appropriated for a portion of the fiscal year, this Agreement will terminate, without penalty, liability or expense of any kind at the end of the term for which funds are appropriated. City has no obligation to make appropriations for this Agreement in lieu of appropriations for new or other agreements. City budget decisions are subject to the discretion of the Mayor and the Board of Supervisors. Contractor’s assumption of risk of possible non-appropriation is part of the consideration for this Agreement. THIS SECTION CONTROLS AGAINST ANY AND ALL OTHER PROVISIONS OF THIS AGREEMENT.
Calculation of Charges Contractor shall provide an invoice to the City on a monthly basis for goods delivered and/or Services completed in the immediate preceding month, unless a different schedule is set out in Appendix B, “Calculation of Charges.” Compensation shall be made for goods and/or Services identified in the invoice that the City, in his or her sole discretion, concludes has been satisfactorily performed. In no event shall the amount of this Agreement exceed [insert whole dollar amount in numbers and words -- no pennies and no “.00”]. The breakdown of charges associated with this Agreement appears in Appendix B, “Calculation of Charges.” A portion of payment may be withheld until conclusion of the Agreement if agreed to by both Parties as retainage, described in Appendix B. In no event shall City be liable for interest or late charges for any late payments. City will not honor minimum service order charges for any services covered by this Agreement.
Allocation of Charges There will not be any agreement or understanding between the Servicer and the Borrower (other than as expressly set forth herein or as consented to by the Administrative Agent), providing for the allocation or sharing of obligations to make payments or otherwise in respect of any Taxes, fees, assessments or other governmental charges; provided that it is understood and acknowledged that the Borrower will be consolidated with or treated as a disregarded entity of the Servicer for tax purposes.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Unavailability of Tenor of Benchmark Notwithstanding anything to the contrary herein or in any other Loan Document, at any time (including in connection with the implementation of a Benchmark Replacement), (i) if the then-current Benchmark is a term rate (including the Term SOFR Reference Rate) and either (A) any tenor for such Benchmark is not displayed on a screen or other information service that publishes such rate from time to time as selected by the Administrative Agent in its reasonable discretion or (B) the regulatory supervisor for the administrator of such Xxxxxxxxx has provided a public statement or publication of information announcing that any tenor for such Benchmark is not or will not be representative, then the Administrative Agent may modify the definition of “Interest Period” (or any similar or analogous definition) for any Benchmark settings at or after such time to remove such unavailable or non-representative tenor and (ii) if a tenor that was removed pursuant to clause (i) above either (A) is subsequently displayed on a screen or information service for a Benchmark (including a Benchmark Replacement) or (B) is not, or is no longer, subject to an announcement that it is not or will not be representative for a Benchmark (including a Benchmark Replacement), then the Administrative Agent may modify the definition of “Interest Period” (or any similar or analogous definition) for all Benchmark settings at or after such time to reinstate such previously removed tenor.
SUBMISSION OF THE MONTHLY MI REPORT 4.1 The completed MI Report shall be completed electronically and returned to the Authority by uploading the electronic MI Report computer file to MISO in accordance with the instructions provided in MISO.
4.2 The Authority reserves the right (acting reasonably) to specify that the MI Report be submitted by the Supplier using an alternative communication to that specified in paragraph 4.1 above such as email. The Supplier agrees to comply with any such instructions provided they do not materially increase the burden on the Supplier.
How Much May I Contribute to a Xxxx XXX As a result of the Economic Growth and Tax Relief Reconciliation Act (“EGTRRA”) of 2001, the maximum dollar amount of annual contributions you may make to a Xxxx XXX is $5,500 for tax years beginning in 2013 with the potential for Cost-of-Living Adjustment (COLA) increases in $500 increments. However, these amounts are phased out or eliminated entirely if your adjusted gross income is over a certain level, as explained in more detail below. Year 2020 2021 Xxxx XXX Contribution Limit $6,000 $6,000 You may make annual contributions to a Xxxx XXX in any amount up to 100% of your compensation for the year or the maximum contribution limits shown in the table above, whichever is less. The limitation is reduced by any contributions made by you or on your behalf to any other individual retirement plan (such as a Traditional IRA) except SEP IRAs and SIMPLE IRAs. Your annual contribution limitation is not reduced by contributions you make to a Xxxxxxxxx Education Savings Account that covers someone other than yourself. In addition, qualifying rollover contributions and transfers are not subject to these limitations. If you are age 50 or older by the end of the year, you may make additional “catch-up” contributions to a Xxxx XXX. The “catch-up” contribution limit is $1,000 for tax years 2009 and beyond. If you are married and file a joint return, you may make contributions to your spouse’s Xxxx XXX. However, the maximum amount contributed to both your own and to your spouse’s Xxxx XXX may not exceed 100% of your combined compensation or the maximum contribution shown in the table above, whichever is less. The maximum amount that may be contributed to either your Xxxx XXX or your spouse’s Xxxx XXX is shown in the table above. Again, these dollar limits are reduced by any contributions made by or on behalf of you or your spouse to any other individual retirement plan (such as a Traditional IRA) except SEP IRAs and SIMPLE IRAs. Again, the limit is not reduced for contributions either of you make to a Xxxxxxxxx Education Savings Account for someone other than yourselves. As noted in Item 1, your eligibility to contribute to a Xxxx XXX depends on your AGI (as defined below). The amount that you may contribute to a Xxxx XXX is reduced proportionately for AGI which exceeds the applicable dollar amount. For the 2020 and 2021 tax years, the amount that you may contribute to your Xxxx XXX is as follows: Single Individual Year Eligible to Make a Contribution if AGI is Less Than: Eligible to Make a Partial Contribution if AGI is Between: Not Eligible to Make A Contribution if AGI is Over: 2020 $124,000 $124,000 - $139,000 $139,000 2021 & After - sub- ject to COLA increases $125,000 $125,000 - $140,000 $140,000 Married Individual Filing a Joint Income Tax Return Year Eligible to Make a Contribution if AGI is Less Than: Eligible to Make a Partial Contribution if AGI is Between: Not Eligible to Make A Contribution if AGI is Over: 2020 $196,000 $196,000 - $206,000 $206,000 2021 & After - sub- ject to COLA increases $198,000 $198,000 - $208,000 $208,000 If you are a married taxpayer filing separately, your contribution phases out over the first $10,000 of AGI, so that if your AGI is $10,000 or more you may not contribute to a Xxxx XXX for the year. Note that the amount you may contribute to a Xxxx XXX is not affected by your participation in an employer-sponsored retirement plan. To determine the amount you may contribute to a Xxxx XXX (assuming it does not exceed 100% of your compensation), you can refer to IRS Publication 590-A: Modified Adjusted Gross Income for Xxxx XXX Purposes and Determining Your Reduced Xxxx XXX Contribution Limit. The amount you contribute may not exceed the maximum contribution limits shown in the table above reduced by the amount contributed on your behalf to all other individual retirement accounts (except SEP IRAs and SIMPLE IRAs). Your contribution to a Xxxx XXX is not reduced by any amount you contribute to a Xxxxxxxxx Education Savings Account for the benefit of someone other than yourself. If you are the beneficiary of a Xxxxxxxxx Education Savings Account, additional limits may apply to you. Please contact your tax advisor for more information.
Determination of One-Month LIBOR Pursuant to the terms of the Global Agency Agreement, the Global Agent shall calculate the Class Coupons for the applicable Classes of Notes (including MAC Notes on which the Exchange Administrator has directed the Global Agent to make payments) for each Accrual Period (after the first Accrual Period) on the applicable LIBOR Adjustment Date. U.S. dollar deposits with a maturity of one month set by ICE Benchmark Administration Limited (“ICE”) as of 11:00 a.m. (London time) on the LIBOR Adjustment Date (the “ICE Method”). ICE’s Interest Settlement Rates are currently displayed on Bloomberg L.P.’s page “BBAM.” That page, or any other page that may replace page BBAM on that service or any other service that ICE nominates as the information vendor to display the ICE’s Interest Settlement Rates for deposits in U.S. dollars, is a “Designated Page.” ICE’s Interest Settlement Rates currently are rounded to five decimal places. If ICE’s Interest Settlement Rate does not appear on the Designated Page as of 11:00 a.m. (London time) on a LIBOR Adjustment Date, or if the Designated Page is not then available, One-Month LIBOR for that date will be the most recently published Interest Settlement Rate. If ICE no longer sets an Interest Settlement Rate, Xxxxxxx Mac will designate an alternative index that has performed, or that Xxxxxxx Mac (or its agent) expects to perform, in a manner substantially similar to ICE’s Interest Settlement Rate.
Prevention or Delay of Performance by the Company or the Depositary Neither the Depositary nor the Company nor any of their respective directors, employees, agents or affiliates shall incur any liability to any Owner or Holder:
(i) if by reason of (A) any provision of any present or future law or regulation or other act of the government of the United States, any State of the United States or any other state or jurisdiction, or of any governmental or regulatory authority or stock exchange; (B) (in the case of the Depositary only) any provision, present or future, of the articles of association or similar document of the Company, or any provision of any securities issued or distributed by the Company, or any offering or distribution thereof; or (C) any event or circumstance, whether natural or caused by a person or persons, that is beyond the ability of the Depositary or the Company, as the case may be, to prevent or counteract by reasonable care or effort (including, but not limited to, earthquakes, floods, severe storms, fires, explosions, war, terrorism, civil unrest, labor disputes, criminal acts or outbreaks of infectious disease; interruptions or malfunctions of utility services, Internet or other communications lines or systems; unauthorized access to or attacks on computer systems or websites; or other failures or malfunctions of computer hardware or software or other systems or equipment), the Depositary or the Company is, directly or indirectly, prevented from, forbidden to or delayed in, or could be subject to any civil or criminal penalty on account of doing or performing and therefore does not do or perform, any act or thing that, by the terms of this Deposit Agreement or the Deposited Securities, it is provided shall be done or performed;
(ii) for any exercise of, or failure to exercise, any discretion provided for in this Deposit Agreement (including any determination by the Depositary to take, or not take, any action that this Deposit Agreement provides the Depositary may take);
(iii) for the inability of any Owner or Holder to benefit from any distribution, offering, right or other benefit that is made available to holders of Deposited Securities but is not, under the terms of this Deposit Agreement, made available to Owners or Holders; or
(iv) for any special, consequential or punitive damages for any breach of the terms of this Deposit Agreement. Where, by the terms of a distribution to which Section 4.1, 4.2 or 4.3 applies, or an offering to which Section 4.4 applies, or for any other reason, that distribution or offering may not be made available to Owners, and the Depositary may not dispose of that distribution or offering on behalf of Owners and make the net proceeds available to Owners, then the Depositary shall not make that distribution or offering available to Owners, and shall allow any rights, if applicable, to lapse.
