Construction Change Directive A written order prepared and issued by the District, the Construction Manager, and/or the Architect and signed by the District and the Architect, directing a change in the Work.
Contract Suspension and Modification (a) Contracting Officer may, by written order, delay or interrupt authorized operations under this contract or, notwithstanding B8.3, modify this contract, in whole or in part:
F3 Variation F3.1 The Authority may from time to time during the Contract Period, by written notice to the Contractor, request a variation of the Contract provided that such variation does not amount to a material change to it. Such a change is hereinafter called a “Variation”.
Contract Modification The conditions of this timber sale are completely set forth in this contract. Except as provided in B8.32 and B8.33, this contract can be modified only by written agreement between the parties. Only Contracting Officer may make contract modifications, with compensating adjustments to Current Contract Rates where appropriate, on behalf of Forest Service.
DESCRIPTION OF CONTRACT MODIFICATION This contract modification is made in accordance with Exhibit E-Revised-1, Contractual Terms and Conditions, Section 22. CHANGES, to be made part hereof for all pertinent purposes. The changes are as follows:
Private Letter Ruling or Change or Clarification of Law At Interconnection Customer’s request and expense, Transmission Owner shall file with the IRS a request for a private letter ruling as to whether any property transferred or sums paid, or to be paid, by Interconnection Customer to Transmission Owner under this GIA are subject to federal income taxation. Interconnection Customer will prepare the initial draft of the request for a private letter ruling, and will certify under penalties of perjury that all facts represented in such request are true and accurate to the best of Interconnection Customer’s knowledge. Transmission Owner and Interconnection Customer shall cooperate in good faith with respect to the submission of such request. Transmission Owner shall keep Interconnection Customer fully informed of the status of such request for a private letter ruling and shall execute either a privacy act waiver or a limited power of attorney, in a form acceptable to the IRS, that authorizes Interconnection Customer to participate in all discussions with the IRS regarding such request for a private letter ruling. Transmission Owner shall allow Interconnection Customer to attend all meetings with IRS officials about the request and shall permit Interconnection Customer to prepare the initial drafts of any follow-up letters in connection with the request.
MODIFICATION & VARIATION The Company may, from time to time and at any time without notice to You, modify this Agreement. You agree that the Company has the right to modify this Agreement or revise anything contained herein. You further agree that all modifications to this Agreement are in full force and effect immediately upon posting on the Website and that modifications or variations will replace any prior version of this Agreement, unless prior versions are specifically referred to or incorporated into the latest modification or variation of this Agreement.
Construction Safety Prior to contract award, the successful bidder must provide a Certificate of Recognition or Letter of Good Standing issued by an occupational health and safety organization approved by the Workers’ Compensation Board of Nova Scotia.
Construction Change Directives 7.3.1 A Construction Change Directive is written order prepared by the Architect and signed by the Owner and Architect, directing a change in the Work and stating a proposed basis for adjustment, if any, in the Contract Sum, or Contract Time, or both. The Owner may by Construction Change Directive, without invalidating the Contract, order changes in the Work within the general scope of the Contract consisting of additions, deletions or other revisions, the Contract Sum and Contract Time being adjusting accordingly.
The Change Order The Change Order is the instrument by which adjustments in the Contract Sum and the Contract Time are effected. The Change Order shall be accompanied by a breakdown as set forth in Paragraph 3.2.7.4. The breakdown is for the purpose of enabling the Design Professional and the Owner to make a judgment on the dollar amount of the adjustment in the Contract Sum and is not a part of the Change Order. No condition, term, qualification, limitation, exception, exemption, modification, or proviso, except as set forth in this Part, shall appear in the breakdown. Only such conditions, terms, qualifications, limitations, exceptions, exemptions, modifications, and provisos as are permitted under this Part are valid. The Design Professional shall certify to the dollar amount and description of the adjustments permitted by the Change Order.
