Disbursement of Tenant Improvement Allowance During the construction of the Tenant Improvements, Landlord shall make monthly disbursements of the Tenant Improvement Allowance for Tenant Improvement Allowance Items for the benefit of Tenant and shall authorize the release of monies for the benefit of Tenant as follows.
Disbursement of the Tenant Improvement Allowance Except as otherwise set forth in this Tenant Work Letter, the Tenant Improvement Allowance shall be disbursed by Landlord (each of which disbursement shall be made pursuant to Landlord’s standard disbursement process), only for the following items and costs (collectively, the “Tenant Improvement Allowance Items”):
Tenant Improvement Allowance Items Except as otherwise set forth in this Tenant Work Letter, the Tenant Improvement Allowance shall be disbursed by Landlord only for the following items and costs (collectively the “Tenant Improvement Allowance Items”):
Budget For Tenant Improvements A preliminary detailed breakdown by trade of the costs incurred or that will be incurred in connection with the design and construction of the Tenant Improvements is set forth on Schedule 3 attached hereto (the “Budget”). The Budget is based upon the TI Construction Drawings approved by Tenant and shall include a payment to Landlord of administrative rent (“Administrative Rent”) equal to 1.5% of the TI Costs, which Administrative Rent shall include, without limitation, all out-of-pocket costs, expenses and fees incurred by or on behalf of Landlord arising from, out of, or in connection with monitoring the construction of the Tenant Improvements and Changes, and shall be payable out of the TI Fund. Landlord shall provide Tenant with a final Budget promptly following approval of the TI Construction Drawings by Landlord and Tenant. The Budget shall be subject to Tenant’s review and approval which approval shall not be unreasonably withheld, conditioned or delayed by Tenant. Tenant shall have the right to approve any use of the contingency in the Budget by Landlord; provided, however, that, Tenant’s approval shall not be unreasonably withheld, conditioned or delayed, and the contingency shall not be available for use by Tenant for any Changes until all unforeseen conditions, changes to resulting from governmental agencies and the like have first been paid for out of the contingency.
Cost of Tenant Improvements Unless specified otherwise herein, Landlord shall bear and pay the cost of the Tenant Improvements (which cost shall include, without limitation, the costs of construction, the cost of permits and permit expediting, the costs of code compliance work, if such work is required as a result of, or is a condition imposed by appropriate governmental authorities for, construction of the Tenant Improvements, and all architectural and engineering services obtained by Landlord in connection with the Tenant Improvements, the Contractor's fees, Landlord's fee for construction administration in an amount which shall not exceed three percent (3%) of hard costs, utilities, and Landlord's Insurance Costs (including, without limitation, course of construction insurance), from the date of this Work Letter until the Lease Commencement Date up to a maximum of $450,000.00 (the "Tenant Improvement Allowance"). The Tenant Improvement Allowance shall be utilized only for building improvements to the Building, and not for signage, furniture costs, any third party consulting or contracting fees, any telecom/cabling costs, or any other purpose. Tenant shall bear and pay the cost of the Tenant Improvements (including but not limited to all of the foregoing fees and costs) in excess of the Tenant Improvement Allowance, if any. The cost of the Tenant Improvements shall exclude the cost of furniture, fixtures and inventory and other items of Tenant's Work (as defined below). Tenant shall have the right to elect to increase the Tenant Improvement Allowance by up to an additional $450,000.00 (the "Additional Allowance"), subject to the following terms and conditions: (i) Tenant shall make such election, if at all, no later than August 15, 1998; (ii) such amount shall be paid to Landlord in equal monthly installments over the seven (7) year Lease Term with interest at 10%, as additional Base Monthly Rent in the manner specified by Article 3 of the Lease; and (iii) the Additional Allowance shall otherwise constitute a part of the Tenant Improvement Allowance and shall be subject to the restrictions and conditions on such Tenant Improvement Allowance provided in this Work Letter. Notwithstanding anything to the contrary contained herein or in the Lease, Landlord shall be responsible at its sole cost and expense for the incremental costs incurred by either Landlord or Tenant for asbestos removal within the interior of the Leased Premises required solely as a result of the construction of the Tenant Improvements. 5.
Tenant Improvement Allowance Subject to the terms of this Section 38 set forth below, there shall be paid by the Landlord as the Landlord’s contribution toward Tenant’s Initial Alterations, the sum (“Allowance”) of $7,191,555.84, based upon a contribution of $68.04 per rentable square foot for 105,696 rentable square feet in the Initial Premises. Tenant shall submit to Landlord Tenant’s good faith estimate (“Qualified Cost Estimate”) of the Qualified Costs (hereinafter defined) to be incurred by Tenant in connection with its move to and the construction of Initial Alterations in the Premises. Installments of the Allowance shall be payable in accordance with the procedures set forth below. Installments of the Allowance, which shall in no event exceed in the aggregate the amount of the Allowance, shall be paid to Tenant (or, at Landlord’s option if Landlord reasonably determines that Tenant is not paying its contractors and such failure to pay may give rise to a lien against the Building, to the order of the contractor that performed the work set forth in the respective invoices) or, at Tenant’s option to Tenant’s contractors, with respect to Qualified Costs theretofore incurred by Tenant (and not theretofore paid to Tenant or which were Tenant’s responsibility as set forth in this Article 38) for which Tenant has submitted a requisition consisting of, (i) in the case of other than costs incurred under architectural and engineering contracts (collectively “Professional Services Contracts”) or under construction contracts, such as furniture or moving or professional fees that are contracted for by Tenant separate from construction and Professional Services Contracts, paid invoices, (ii) in the case of Professional Services Contracts, invoices, and (iii) in the case of construction costs (a) an application for payment and sworn statement of a contractor performing general contracting work in the Premises substantially in the form of AIA Document G-702 covering all work for which disbursement is to be made to a date specified therein which is part of the construction contract; (b) a certification from an AIA architect substantially in the form of the Architect’s Certificate for Payment which is located on AIA Document G702, Application and Certificate of Payment; (c) contractor’s, project managers and subcontractor’s waivers of liens which shall cover all applicable items of Qualified Costs under such construction contracts for which disbursement is being requested and any other statements and forms required for compliance with the mechanics’ lien laws of the Commonwealth of Massachusetts, together with invoices with respect to such Qualified Costs and such other supporting data as Landlord or Landlord’s Mortgagee may reasonably require; (iv) a cost breakdown for each trade or subcontractor performing the work included in Qualified Costs for which a request for disbursement under such construction contracts is being made; (v) copies of all construction contracts for the such Alterations, together with copies of all change orders, if any; and (iii) a request to disburse from Tenant containing an acknowledgement by Tenant of the work done and a good faith estimate of the cost to complete the Initial Alterations to the Premises. Upon completion of the Initial Alterations, and as part of the requisition for final disbursement of the Allowance for hard construction costs, Tenant shall furnish Landlord with: (1) general contractor and architect’s completion affidavits, (2) full and final waivers of lien, (3) receipted bills covering all labor and materials expended and used, (4) as-built plans of the Alterations, and (5) the certification of Tenant’s architect to the Landlord that, based on on-site observation and the data comprising the application for disbursement, to the best of the architect’s knowledge, information and belief, the Alterations have progressed as indicated in the application, the quality of the Alterations is in accordance with the construction contract documents and the contractor is entitled to; payment of the amount certified in the application. Notwithstanding the foregoing, if the Qualified Cost Estimate exceeds the Allowance, Tenant shall be entitled to payments with respect to any requisition in accordance with the terms hereof except that each individual disbursement of the Allowance by Landlord shall be in the same ratio to the amount properly requisitioned as the Allowance bears to the Adjusted Qualified Cost Estimate (hereinafter defined). “Adjusted
Tenant Improvement Costs The Tenant Improvements’ cost (the “Tenant Improvement Costs”) shall mean and include any and all costs and expenses of the Work, including, without limitation, all of the following:
Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.
Tenant Allowance Landlord shall provide Tenant an allowance for each Building in an amount not to exceed the sum set forth in the Basic Lease Information for the Tenant Allowance for the applicable Building (collectively, the “Tenant Allowance”), to be applied toward the cost of the following items in respect of the Tenant Improvements in the applicable Building: Architectural and engineering fees, space planning, building permits or other governmental fees, and the cost of labor, materials, contractors fees and overhead, and other charges included in the construction contract for construction of Tenant Improvements, including the contractor’s fee, overhead and general conditions, sales and use taxes, the cost of the builder’s risk insurance during construction and all testing and inspection costs. If Landlord elects to itself construct the Restroom Improvements, Landlord shall make payments to its contractor for the Restroom Improvements as and when such costs are incurred and deduct the amount of such payments from the Tenant Allowance for Building 2 up to the maximum amount stated in Paragraph I of this Work Letter. Landlord shall not be obligated to disburse any remaining portion of the Tenant Allowance attributable to a Building until such time as (i) the Commencement Date for the applicable Building has occurred and Tenant has accepted delivery of the Building and made the initial prepayment of Rent with respect to the applicable portion of the Premises; and (ii) Tenant has delivered to Landlord and Landlord has approved, in Landlord’s reasonable discretion, all of the following: (A) invoices, paid receipts and/or related evidence reasonably acceptable to Landlord establishing that Tenant has paid an amount equal to that portion of the Tenant Allowance requested by Tenant to third parties in connection with the Tenant Improvements in the applicable Building; (B) executed unconditional final mechanics’ lien releases, in statutory form, from Tenant’s contractor and all subcontractors, laborers, materialmen and suppliers used by Tenant with respect to all work in and to the Premises located in the applicable Building; (C) a certificate from Tenant’s architect or space planner, in a form reasonably acceptable to Landlord, certifying that the construction of the Tenant Improvements in the applicable Building has been substantially completed and meets all applicable building codes; (D) a copy of the certificate of occupancy (or similar governmental authorization) for the applicable Building; (E) “as-built” drawings for the Tenant Improvements in the applicable Building, signed by either Tenant’s architect, space planner or contractor, and electronic CAD files from Tenant’s Contractor and all subcontractors; and (F) a final punch list signed off by both Tenant and Landlord and/or their architects. Thereafter, Landlord shall deliver, within fifteen (15) days following Tenant’s delivery of the materials and information required for disbursement thereof in the preceding sentence, a check payable to Tenant in the amount of that portion of the Tenant Allowance requested by Tenant and paid to third parties in connection with the Tenant Improvements for the applicable Building (which amount shall not exceed the portion of the Tenant Allowance provided for such Building as specified in the Basic Lease Information). Landlord’s payment of any portion of the Tenant Allowance shall not be deemed Landlord’s approval any of the Tenant Improvements absent Landlord’s prior approval pursuant to this Work Letter. Landlord’s obligation to disburse the Tenant Allowance for each Building under this Paragraph 9(b) shall expire six (6) months after the Delivery Date for the applicable Building, subject to extension due to Force Majeure, such that Landlord shall not be obligated to provide to Tenant any undisbursed portion of the Tenant Allowance for a Building unless Tenant has delivered to Landlord all documents required above within nine (9) months after the Delivery Date of such Building.
Landlord’s General Conditions for Tenant’s Agents and Tenant Improvement Work Tenant’s and Tenant’s Agent’s construction of the Tenant Improvements shall comply with the following: (i) the Tenant Improvements shall be constructed in strict accordance with the Approved Working Drawings; (ii) Tenant’s Agents shall submit schedules of all work relating to the Tenant’s Improvements to Contractor and Contractor shall, within five (5) business days of receipt thereof, inform Tenant’s Agents of any changes which are necessary thereto, and Tenant’s Agents shall adhere to such corrected schedule; and (iii) Tenant shall abide by all rules made by Landlord’s Building manager with respect to the use of freight, loading dock and service elevators, storage of materials, coordination of work with the contractors of other tenants, and any other matter in connection with this Tenant Work Letter, including, without limitation, the construction of the Tenant Improvements.
