District The public agency or the school district for which the Work is performed. The governing board of the District or its designees will act for the District in all matters pertaining to the Contract. The District may, at any time:
1.1.23.1 Direct Developer to communicate with or provide notice to the Construction Manager or the Architect on matters for which the Contract Documents indicate Developer will communicate with or provide notice to the District; and/or
1.1.23.2 Direct the Construction Manager or the Architect to communicate with or direct Developer on matters for which the Contract Documents indicate the District will communicate with or direct Developer.
Pending Proceedings and Examinations The Registration Statement is not the subject of a pending proceeding or examination under Section 8(d) or 8(e) of the 1933 Act, and the Company is not the subject of a pending proceeding under Section 8A of the 1933 Act in connection with the offering of the Securities.
Responsibilities of the District 12.1. The District shall examine the documents submitted by the Architect and shall render decisions so as to avoid unreasonable delay in the process of the Architect’s Services.
12.2. The District shall verbally or in writing advise Architect if the District becomes aware of any fault or defect in the Project, including any errors, omissions or inconsistencies in the Architect’s documents. Failure to provide such notice shall not relieve Architect of its responsibility therefore, if any.
12.3. Unless the District and Architect agree that a hazardous materials consultant shall be a Consultant of the Architect, the District shall furnish the services of a hazardous material consultant or other consultants when such services are requested in writing by Architect and deemed necessary by the District or are requested by the District. These services shall include: asbestos and lead paint survey; abatement documentation; and specifications related to said matters, which are to be incorporated into bid documents prepared by Architect. If the hazardous materials consultant is furnished by the District and is not a Consultant of the Architect, the specifications shall include a note to the effect that the hazardous materials consultant’s specifications are included in the Architect’s bid documents for the District’s convenience and have not been prepared or reviewed by the Architect. The note shall also direct questions about the hazardous materials consultant’s specifications related to asbestos and lead paint survey and/or abatement documentation to the preparer of the hazardous materials consultant’s specifications.
District Approval The work completed herein must meet the approval of the District and shall be subject to the District’s general right of inspection and supervision to secure the satisfactory completion thereof.
Responsibilities of the City The City’s Contract Manager will be responsible for exercising general oversight of the Contractor’s activities in completing the Scope of Work. Specifically, the Contract Manager will represent the City’s interests in resolving day-to-day issues that may arise during the term of this Contract, shall participate regularly in conference calls or meetings for status reporting, shall promptly review any written reports submitted by the Contractor, and shall approve all invoices for payment, as appropriate. The City’s Contract Manager shall give the Contractor timely feedback on the acceptability of progress and task reports.
Obligations of the City A. The City agrees to give the Contractor access to the Project area and other City- owned properties as required to perform the necessary Services under this Agreement.
B. The City shall notify the Contractor of any defects in the Services of which the Contract Administrator has actual notice.
Professional Organizations During the Term, Executive shall be reimbursed by the Company for the annual dues payable for membership in professional societies associated with subject matter related to the Company's interests. New memberships for which reimbursement will be sought shall be approved by the Company in advance.
Governing Law; Exclusive Jurisdiction All questions concerning the construction, validity, enforcement and interpretation of the Transaction Documents shall be governed by and construed and enforced in accordance with the internal laws of the State of New York, without regard to the principles of conflicts of law thereof. Each party agrees that all legal Proceedings concerning the interpretations, enforcement and defense of the transactions contemplated by this Agreement and any other Transaction Documents (whether brought against a party hereto or its respective affiliates, directors, officers, shareholders, partners, members, employees or agents) shall be commenced exclusively in the state and federal courts sitting in the City of New York. Each party hereby irrevocably submits to the exclusive jurisdiction of the state and federal courts sitting in the City of New York, Borough of Manhattan for the adjudication of any dispute hereunder or in connection herewith or with any transaction contemplated hereby or discussed herein (including with respect to the enforcement of any of the Transaction Documents), and hereby irrevocably waives, and agrees not to assert in any Action or Proceeding, any claim that it is not personally subject to the jurisdiction of any such court, that such Action or Proceeding is improper or is an inconvenient venue for such Proceeding. Each party hereby irrevocably waives personal service of process and consents to process being served in any such Action or Proceeding by mailing a copy thereof via registered or certified mail or overnight delivery (with evidence of delivery) to such party at the address in effect for notices to it under this Agreement and agrees that such service shall constitute good and sufficient service of process and notice thereof. Nothing contained herein shall be deemed to limit in any way any right to serve process in any other manner permitted by law. If any party shall commence an Action or Proceeding to enforce any provisions of the Transaction Documents, then, in addition to the obligations of the Company elsewhere in this Agreement, the prevailing party in such Action or Proceeding shall be reimbursed by the non-prevailing party for its reasonable attorneys’ fees and other costs and expenses incurred with the investigation, preparation and prosecution of such Action or Proceeding.
Prosecution Hospital shall be responsible for the preparation, filing, prosecution and maintenance of all patent applications and patents included in Patent Rights. Company shall reimburse Hospital for Patent Costs incurred by Hospital relating thereto in accordance with Section 4.2.
DISTRICT RIGHTS 4.1 It is understood and agreed that the District retains all of its powers and authority to direct, manage and control to the full extent of the law. Included in, but not limited to, those duties and powers are the exclusive right to: determine its organization; direct the work of its employees; determine the times and hours of operation; determine the kinds and levels of service to be provided, and the methods and means of providing them; establish its educational policies, goals and objectives; insure the rights and educational opportunities of students; determine staffing patterns; determine the number and kinds of personnel required; maintain the efficiency of District operation; determine the curriculum; build, move or modify facilities; establish budget procedures and determine budgetary allocation; determine the methods of raising revenue; contract out work as legally allowed under the Education and Government Codes; and take action on any matter in the event of an emergency. In addition, the District retains the right to hire, assign, evaluate, promote, layoff, terminate and discipline employees.
4.2 The exercise of the foregoing powers, rights, authority, duties and responsibilities by the District, the adoption of policies, rules, regulations and practices in furtherance thereof, and the use of judgment and discretion in connection therewith, shall be limited only by the specific and express terms of this Agreement, and then only to the extent such specific and express terms are in conformance with law.
4.3 The District retains its right to amend, modify or suspend policies and practices covered in this Agreement in emergency circumstances. Examples of emergency circumstances are physical catastrophe and acts of nature. Such changes, if any, will remain in effect only for the duration of the emergency. All grievance time lines expressly set forth in the Agreement will be held in abeyance while the contract is suspended.
4.4 The exercise of any right reserved to the District herein in a particular manner or the non- exercise of any such right shall not be deemed a waiver of the District's right or preclude the District from exercising their rights.
4.5 Any dispute arising out of or in any way connected with either the existence of or the exercise of any of the above described rights of the District is not subject to the grievance provisions set forth in this Agreement unless such dispute is otherwise grievable under another Article of the Agreement.
