Draw Request to Be Submitted to the Agent and the Construction Consultant Sample Clauses

Draw Request to Be Submitted to the Agent and the Construction Consultant. The Borrower shall submit to the Agent and the Construction Consultant documentation (substantially in the forms attached hereto as Exhibit I (such items collectively referred to as a “Draw Request”) not less than seven (7) Business Days prior to the date upon which a disbursement of the Loan is requested to be made (the “Borrowing Date”) and no more frequently than once in each calendar month. As part of each Draw Request, the Borrower shall submit, as irrevocable notice of its intention to borrow funds, a Borrower’s Requisition Letter in the form set forth in Exhibit I-1 (“Borrower’s Requisition Letter”), which shall be executed by any authorized officer or authorized representative of the Borrower. Borrower’s Requisition Letter shall be accompanied by: (i) a Borrower’s Requisition Spreadsheet in the form set forth in Exhibit I-2; (ii) a completed Application and Certificate for Payment (AIA Document G702) attached hereto as Exhibit I-3 that is executed by the Construction Manager and the Architect; (iii) a Borrowing Certificate in the form set forth in Exhibit I-4; (iv) Payment Receipts in the form set forth in Exhibit G from the Construction Manager and all contractors, subcontractors, suppliers and materialmen, evidencing that they have been paid in full for all work performed and/or materials supplied to the date of the preceding Advance, except for Retainage provided for in this Agreement or in the applicable contract or subcontract; (v) at the request of the Agent, current requisitions for payment from the Construction Manager and all contractors, subcontractors, suppliers and/or materialmen allocable to the Project; (vi) such other information and documents as may be reasonably requested or required by the Agent or the Construction Consultant with respect to the Hard Costs covered by such Draw Request; and (vii) invoices, statements or such other information and documentation as the Agent shall reasonably request or require with respect to any Soft Costs covered by such Draw Request. All such requests and requisitions for payment shall be deemed approved for funding by the Agent, and shall be funded by each Lender in accordance with Section 3.5.2(b) hereof, unless, not less than two (2) Business Days prior to the applicable Borrowing Date, the Agent notifies the Borrower that the Agent has disapproved any such request or requisition and setting forth the reasons for such disapproval.
Sample 1
AutoNDA by SimpleDocs

Related to Draw Request to Be Submitted to the Agent and the Construction Consultant

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Conditions Precedent to All Borrowings The obligation of each Lender to make an Advance on the occasion of each Borrowing and of the Issuing Lender to issue, increase, or extend any Letter of Credit shall be subject to the further conditions precedent that on the date of such Borrowing or the date of the issuance, increase, or extension of such Letter of Credit: (a) the following statements shall be true (and each of the giving of the applicable Notice of Borrowing, or Letter of Credit Application and the acceptance by the Borrower of the proceeds of such Borrowing or the issuance, increase, or extension of such Letter of Credit shall constitute a representation and warranty by the Borrower that on the date of such Borrowing or on the date of such issuance, increase, or extension of such Letter of Credit, as applicable, such statements are true): (i) the representations and warranties contained in Article IV of this Agreement and the representations and warranties contained in the Security Instruments, the Guaranties, and each of the other Loan Documents are true and correct in all material respects on and as of the date of such Borrowing or the date of the issuance, increase, or extension of such Letter of Credit, before and after giving effect to such Borrowing or to the issuance, increase, or extension of such Letter of Credit and to the application of the proceeds from such Borrowing, as though made on and as of such date except to the extent that any such representation or warranty expressly relates solely to an earlier date, in which case it shall have been true and correct in all material respects as of such earlier date; and (ii) no Default has occurred and is continuing or would result from such Borrowing or from the application of the proceeds therefrom, or would result from the issuance, increase, or extension of such Letter of Credit; and (b) the Administrative Agent shall have received such other approvals, opinions, or documents reasonably deemed necessary or desirable by any Lender as a result of circumstances occurring after the date of this Agreement, as any Lender through the Administrative Agent may reasonably request.

  • Acceptance of Appointment and Other Matters Relating to the Servicer (a) The Servicer shall service and administer the Receivables, shall collect payments due under the Receivables and shall charge-off as uncollectible Receivables, all in accordance with its customary and usual servicing procedures for servicing wholesale receivables comparable to the Receivables which the Servicer services for its own account and in accordance with the Floorplan Financing Guidelines. The Servicer shall have full power and authority, acting alone or through any party properly designated by it hereunder, to do any and all things in connection with such servicing and administration which it may deem necessary or desirable. Without limiting the generality of the foregoing and subject to Section 10.01, the Servicer is hereby authorized and empowered, unless such power and authority is revoked by the Trustee on account of the occurrence of a Service Default pursuant to Section 10.01, (i) to instruct the Trustee to make withdrawals and payments from the Collection Account and any Series Account as set forth in this Agreement, (ii) to instruct the Trustee to take any action required or permitted under any Enhancement, (iii) to execute and deliver, on behalf of the Trust for the benefit of the Certificateholders and the other Beneficiaries, any and all instruments of satisfaction or cancellation, or of partial or full release or discharge, and all other comparable instruments, with respect to the Receivables and, after the delinquency of any Receivable and to the extent permitted under and in compliance with applicable Requirements of Law, to commence enforcement proceedings with respect to such Receivables, (iv) to make any filings, reports, notices, applications, registrations with, and seek any consents or authorizations from, the Securities and Exchange Commission and any State securities authority on behalf of the Trust as may be necessary or advisable to comply with any Federal or State securities laws or reporting requirement, and (v) to delegate certain of its servicing, collection, enforcement and administrative duties hereunder with respect to the Accounts and the Receivables to any Person who agrees to conduct such duties in accordance with the Floorplan Financing Guidelines and this Agreement; provided, however, that the Servicer shall notify the Trustee, the Rating Agencies, any Agent and any Enhancement Providers in writing of any such delegation of its duties which is not in the ordinary course of its business, that no delegation will relieve the Servicer of its liability and responsibility with respect to such duties and that the Rating Agency Condition shall have been satisfied with respect to any such delegation. The Trustee shall furnish the Servicer with any powers of attorney and other documents necessary or appropriate to enable the Servicer to carry out its servicing and administrative duties hereunder. (b) In the event that the Seller is unable for any reason to transfer Receivables to the Trust in accordance with the provisions of this Agreement (including by reason of the application of the provisions of Section 9.02 or any court of competent jurisdiction ordering that the Seller not transfer any additional Principal Receivables to the Trust) then, in any such event, the Servicer agrees (i) to give prompt written notice thereof to any Enhancement Providers, any Agent and each Rating Agency and (ii) that it shall in any such event allocate after the occurrence of such event, payments on each Account with respect to the principal balance of such Account first to the oldest principal balance of such Account, subject to the proviso set forth in Section 2.06(b), and to have such payments applied as Collections in accordance with Section 4.

  • Conditions Precedent to Each Borrowing The obligation of each Bank to make an Advance on the occasion of each Borrowing to any Borrower (including the initial Borrowing) shall be subject to the further conditions precedent that on the date of such Borrowing: (a) the following statements shall be true (and each of the giving of the applicable Notice of Borrowing and the acceptance by a Borrower of the proceeds of such Borrowing shall constitute a representation and warranty by such Borrower that on the date of such Borrowing such statements are true): (i) The representations and warranties contained in Section 4.01 (excluding those contained in the second sentence of subsection (e) and in subsection (f) thereof), and if such Borrowing is by CFSC, CIF or CFKK, Section 4.02, are correct on and as of the date of such Borrowing, before and after giving effect to such Borrowing and to the application of the proceeds therefrom, as though made on and as of such date, and (ii) No event has occurred and is continuing, or would result from such Borrowing or from the application of the proceeds therefrom, which constitutes an Event of Default with respect to any Borrower; and (b) the Agent shall have received such other approvals, opinions or documents as any Bank through the Agent may reasonably request.

  • Actions of Custodian Based on Proper Instructions and Special Instructions So long as and to the extent that the Custodian acts in accordance with (a) Proper Instructions or Special Instructions, as the case may be, and (b) the terms of this Agreement, the Custodian shall not be responsible for the title, validity or genuineness of any property, or evidence of title thereof, received by it or delivered by it pursuant to this Agreement.

  • Award of Construction Contract and Other Future Contracts 6.2.1 A-E is hereby informed that provisions of the Public Contract Code, the Political Reform Act of 1974, other statutes, regulations, and COUNTY policy prohibit, as an impermissible conflict of interest, the award of a contract for the construction of the project(s) on which A-E performed architectural-engineering services under this A-E CONTRACT. A-E is hereby informed that these statutes and regulations could also prohibit the award to A-E of design or other contracts on future phases related to tasks performed by A-E under this CONTRACT. This prohibition applies also to a subcontractor of or parent company of the firm that performed architectural-engineering tasks under this CONTRACT.

  • Conditions Precedent to Borrowings 5.1 Conditions Precedent to the Initial Borrowing of TBC 37 5.2 Conditions Precedent to Each Committed Borrowing of TBC 38 5.3 Conditions Precedent to Each Bid Borrowing of TBC 38 5.4 Conditions Precedent to the Initial Borrowing of a Subsidiary Borrower 39 5.5 Conditions Precedent to Each Committed Borrowing of a Subsidiary Borrower 39 5.6 Conditions Precedent to Each Bid Borrowing of a Subsidiary Borrower 40

  • Conditions Precedent to Each Loan and Letter of Credit The obligation of each Lender on any date (including the Closing Date) to make any Loan and of each L/C Issuer on any date (including the Closing Date) to Issue any Letter of Credit is subject to the satisfaction of each of the following conditions precedent:

  • Conditions Precedent to Borrowing The obligation of the Liquidity Provider to make an Advance on the occasion of each Borrowing shall be subject to the conditions precedent that the Effective Date shall have occurred and, prior to the date of such Borrowing, the Borrower shall have delivered a Notice of Borrowing which conforms to the terms and conditions of this Agreement and has been completed as may be required by the relevant form of the Notice of Borrowing for the type of Advances requested.

  • Notice to Lenders by the Administrative Agent Promptly following receipt of an Interest Election Request, the Administrative Agent shall advise each Lender of the details thereof and of such Lender’s portion of each resulting Borrowing.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!