Certification Regarding Debarment, Suspension, Ineligibility and Voluntary Exclusion First Tier Participants:
a. The prospective first tier participant certifies to the best of its knowledge and belief, that it and its principals:
(1) Are not presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from participating in covered transactions by any Federal department or agency;
(2) Have not within a three-year period preceding this proposal been convicted of or had a civil judgment rendered against them for commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public (Federal, State or local) transaction or contract under a public transaction; violation of Federal or State antitrust statutes or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, or receiving stolen property;
(3) Are not presently indicted for or otherwise criminally or civilly charged by a governmental entity (Federal, State or local) with commission of any of the offenses enumerated in paragraph (a)(2) of this certification; and
(4) Have not within a three-year period preceding this application/proposal had one or more public transactions (Federal, State or local) terminated for cause or default.
b. Where the prospective participant is unable to certify to any of the statements in this certification, such prospective participant shall attach an explanation to this proposal.
CERTIFICATION REGARDING DEBARMENT AND SUSPENSION The undersigned (authorized official signing for the contracting organization) certifies to the best of his or her knowledge and belief, that the contractor, defined as the primary participant in accordance with 45 CFR Part 76, and its principals: are not presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from covered transactions by any Federal Department or agency have not within a 3-year period preceding this contract been convicted of or had a civil judgment rendered against them for commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public (Federal, State, or local) transaction or contract under a public transaction; violation of Federal or State antitrust statutes or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, or receiving stolen property; are not presently indicted or otherwise criminally or civilly charged by a governmental entity (Federal, State, or local) with commission of any of the offenses enumerated in Section 2 of this certification; and have not within a 3-year period preceding this contract had one or more public transactions (Federal, State, or local) terminated for cause or default. Should the Contractor or Subrecipient not be able to provide this certification, an explanation as to why should be placed after the assurances page in the contract. The contractor agrees by signing this contract that it will include, without modification, the clause above certification in all lower tier covered transactions (i.e., transactions with sub-grantees and/or contractors) and in all solicitations for lower tier covered transactions in accordance with 45 CFR Part 76.
Certification Regarding Suspension or Debarment Contractor certifies under the pains and penalties of perjury that, as of the date this contract amendment is signed, neither Contractor nor Contractor’s principals (officers, directors, owners, or partners) are presently debarred, suspended, proposed for debarment, declared ineligible or excluded from participation in federal programs, or programs supported in whole or in part by federal funds.
SUSPENSION & DEBARMENT Contractor represents and warrants as previously certified in Contractor’s Bidder’s Certification, that neither Contractor nor its principals or affiliates presently are nor have ever been debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from participation in any governmental contract by any governmental department or agency within the United States.
CERTIFICATION REGARDING DEBARMENT OR SUSPENSION Contractor certifies that neither Contractor or its principals; its subcontractors or their principals; the sub-recipients (if applicable) or their principals are suspended, debarred, proposed for debarment, voluntarily excluded from covered transactions, or otherwise disqualified by any federal department or agency from doing business with the Federal Government pursuant to Executive Orders 12549 and 12689. Contractor specifically covenants that neither the Contractor or its principals, its sub-contractors or their principals, or the sub-recipients (if applicable) or their principals are included on the Excluded Parties List System (“EPLS”) maintained by the General Services Administration (“GSA”).
CERTIFICATION REGARDING DEBARMENT, SUSPENSION, INELIGIBILITY AND VOLUNTARY EXCLUSION
Suspension of Work Authorization DocuSign Envelope ID: F977C999-9391-4B1E-8882-3E74EBE07795
DEBARMENT AND SUSPENSION CERTIFICATION CONTRACTOR certifies that it and its principals:
Debarment and Suspension A. The Contractor certifies by entering into this Contract that neither it nor its principals nor any of its subcontractors are presently debarred, suspended, proposed for debarment, declared ineligible or voluntarily excluded from entering into this Contract by any federal agency or by any department, agency or political subdivision of the State of Indiana. The term “principal” for purposes of this Contract means an officer, director, owner, partner, key employee or other person with primary management or supervisory responsibilities, or a person who has a critical influence on or substantive control over the operations of the Contractor.
B. The Contractor certifies that it has verified the state and federal suspension and debarment status for all subcontractors receiving funds under this Contract and shall be solely responsible for any recoupment, penalties or costs that might arise from use of a suspended or debarred subcontractor. The Contractor shall immediately notify the State if any subcontractor becomes debarred or suspended, and shall, at the State’s request, take all steps required by the State to terminate its contractual relationship with the subcontractor for work to be performed under this Contract.
Available Relief for a Force Majeure Event 11.7.1 Subject to this Article 11:
(a) no Party shall be in breach of its obligations pursuant to this Agreement except to the extent that the performance of its obligations was prevented, hindered or delayed due to a Force Majeure Event;
(b) every Party shall be entitled to claim relief in relation to a Force Majeure Event in regard to its obligations, including but not limited to those specified under Article 4.5;
(c) For avoidance of doubt, neither Party’s obligation to make payments of money due and payable prior to occurrence of Force Majeure events under this Agreement shall be suspended or excused due to the occurrence of a Force Majeure Event in respect of such Party.
(d) Provided that no payments shall be made by either Party affected by a Force Majeure Event for the period of such event on account of its inability to perform its obligations due to such Force Majeure Event.
