Rights of the Company in Respect of the Master Servicer The Master Servicer shall afford the Company, upon reasonable notice, during normal business hours access to all records maintained by the Master Servicer in respect of its rights and obligations hereunder and access to officers of the Master Servicer responsible for such obligations. Upon request, the Master Servicer shall furnish the Company with its most recent financial statements and such other information as the Master Servicer possesses regarding its business, affairs, property and condition, financial or otherwise. The Master Servicer shall also cooperate with all reasonable requests for information including, but not limited to, notices, tapes and copies of files, regarding itself, the Mortgage Loans or the Certificates from any Person or Persons identified by the Company or Residential Funding. The Company may, but is not obligated to, enforce the obligations of the Master Servicer hereunder and may, but is not obligated to, perform, or cause a designee to perform, any defaulted obligation of the Master Servicer hereunder or exercise the rights of the Master Servicer hereunder; provided that the Master Servicer shall not be relieved of any of its obligations hereunder by virtue of such performance by the Company or its designee. The Company shall not have any responsibility or liability for any action or failure to act by the Master Servicer and is not obligated to supervise the performance of the Master Servicer under this Agreement or otherwise.
Respective Liabilities of the Depositor and the Master Servicer The Depositor and the Master Servicer shall each be liable in accordance herewith only to the extent of the obligations specifically and respectively imposed upon and undertaken by them herein.
Rights of the Depositor in Respect of the Master Servicer The Master Servicer shall afford (and any Sub-Servicing Agreement shall provide that each Sub-Servicer shall afford) the Depositor, the NIMS Insurer and the Trustee, upon reasonable notice, during normal business hours, access to all records maintained by the Master Servicer (and any such Sub-Servicer) in respect of the Master Servicer's rights and obligations hereunder and access to officers of the Master Servicer (and those of any such Sub-Servicer) responsible for such obligations. Upon request, the Master Servicer shall furnish to the Depositor, the NIMS Insurer and the Trustee its (and any such Sub-Servicer's) most recent financial statements and such other information relating to the Master Servicer's capacity to perform its obligations under this Agreement that it possesses. To the extent such information is not otherwise available to the public, the Depositor, the NIMS Insurer and the Trustee shall not disseminate any information obtained pursuant to the preceding two sentences without the Master Servicer's (or any such Sub-Servicer's) written consent, except as required pursuant to this Agreement or to the extent that it is appropriate to do so (i) in working with legal counsel, auditors, taxing authorities or other governmental agencies, rating agencies or reinsurers or (ii) pursuant to any law, rule, regulation, order, judgment, writ, injunction or decree of any court or governmental authority having jurisdiction over the Depositor, the Trustee or the Trust Fund, and in either case, the Depositor, the NIMS Insurer or the Trustee, as the case may be, shall use its best efforts to assure the confidentiality of any such disseminated non-public information. The Depositor may, but is not obligated to, enforce the obligations of the Master Servicer under this Agreement and may, but is not obligated to, perform, or cause a designee to perform, any defaulted obligation of the Master Servicer under this Agreement or exercise the rights of the Master Servicer under this Agreement; provided that the Master Servicer shall not be relieved of any of its obligations under this Agreement by virtue of such performance by the Depositor or its designee. The Depositor shall not have any responsibility or liability for any action or failure to act by the Master Servicer and is not obligated to supervise the performance of the Master Servicer under this Agreement or otherwise.
Respective Liabilities of the Depositor and the Servicer The Depositor and the Servicer shall each be liable in accordance herewith only to the extent of the obligations specifically and respectively imposed upon and undertaken by them herein.
Responsibilities of the City The City’s Contract Manager will be responsible for exercising general oversight of the Contractor’s activities in completing the Scope of Work. Specifically, the Contract Manager will represent the City’s interests in resolving day-to-day issues that may arise during the term of this Contract, shall participate regularly in conference calls or meetings for status reporting, shall promptly review any written reports submitted by the Contractor, and shall approve all invoices for payment, as appropriate. The City’s Contract Manager shall give the Contractor timely feedback on the acceptability of progress and task reports.
Outside Activities of the Limited Partners Subject to the provisions of Section 7.5, which shall continue to be applicable to the Persons referred to therein, regardless of whether such Persons shall also be Limited Partners, any Limited Partner shall be entitled to and may have business interests and engage in business activities in addition to those relating to the Partnership, including business interests and activities in direct competition with the Partnership Group. Neither the Partnership nor any of the other Partners shall have any rights by virtue of this Agreement in any business ventures of any Limited Partner.
Responsibilities of the District 12.1. The District shall examine the documents submitted by the Architect and shall render decisions so as to avoid unreasonable delay in the process of the Architect’s Services.
12.2. The District shall verbally or in writing advise Architect if the District becomes aware of any fault or defect in the Project, including any errors, omissions or inconsistencies in the Architect’s documents. Failure to provide such notice shall not relieve Architect of its responsibility therefore, if any.
12.3. Unless the District and Architect agree that a hazardous materials consultant shall be a Consultant of the Architect, the District shall furnish the services of a hazardous material consultant or other consultants when such services are requested in writing by Architect and deemed necessary by the District or are requested by the District. These services shall include: asbestos and lead paint survey; abatement documentation; and specifications related to said matters, which are to be incorporated into bid documents prepared by Architect. If the hazardous materials consultant is furnished by the District and is not a Consultant of the Architect, the specifications shall include a note to the effect that the hazardous materials consultant’s specifications are included in the Architect’s bid documents for the District’s convenience and have not been prepared or reviewed by the Architect. The note shall also direct questions about the hazardous materials consultant’s specifications related to asbestos and lead paint survey and/or abatement documentation to the preparer of the hazardous materials consultant’s specifications.
OTHER INVESTMENT ACTIVITIES OF THE SUB-ADVISER The Fund acknowledges that the Sub-Adviser or one or more of its affiliated persons may have investment responsibilities or render investment advice to or perform other investment advisory services for other individuals or entities and that the Sub-Adviser, its affiliated persons or any of its or their directors, officers, agents or employees may buy, sell or trade in any securities for its or their own respective accounts ("Affiliated Accounts"). Subject to the provisions of Section 7(b) hereof, the Fund agrees that the Sub-Adviser or its affiliated persons may give advice or exercise investment responsibility and take such other action with respect to other Affiliated Accounts which may differ from the advice given or the timing or nature of action taken with respect to the Series Account, provided that the Sub-Adviser acts in good faith, and provided further, that it is the Sub-Adviser's policy to allocate, within its reasonable discretion, investment opportunities to the Series Account over a period of time on a fair and equitable basis relative to the Affiliated Accounts, taking into account the investment objective and policies of the Series and any specific investment restrictions applicable thereto. The Fund acknowledges that one or more of the Affiliated Accounts may at any time hold, acquire, increase, decrease, dispose of or otherwise deal with positions in investments in which the Series Account may have an interest from time to time, whether in transactions which involve the Series Account or otherwise. The Sub-Adviser shall have no obligation to acquire for the Series Account a position in any investment which any Affiliated Account may acquire, and the Fund shall have no first refusal, co-investment or other rights in respect of any such investment, either for the Series Account or otherwise.
ACTIVITIES OF THE SUB-ADVISOR It is understood that the Sub-Advisor may perform investment advisory services for various other clients, including other investment companies. The Sub-Advisor will report to the Board of Trustees of the Trust (at regular quarterly meetings and at such other times as such Board of Trustees reasonably shall request)
(i) the financial condition and prospects of the Sub-Advisor, (ii) the nature and amount of transactions affecting the Fund that involve the Sub-Advisor and affiliates of the Sub-Advisor, (iii) information regarding any potential conflicts of interest arising by reason of its continuing provision of advisory services to the Fund and to its other accounts, and (iv) such other information as the Board of Trustees shall reasonably request regarding the Fund, the Fund's performance, the services provided by the Sub-Advisor to the Fund as compared to its other accounts and the plans of, and the capability of, the Sub-Advisor with respect to providing future services to the Fund and its other accounts. At least annually, the Sub-Advisor shall report to the Trustees the total number and type of such other accounts and the approximate total asset value thereof (but not the identities of the beneficial owners of such accounts). The Sub-Advisor agrees to submit to the Trust a statement defining its policies with respect to the allocation of business among the Fund and its other clients. It is understood that the Sub-Advisor may become interested in the Trust as a shareholder or otherwise. The Sub-Advisor has supplied to the Advisor and the Trust copies of its Form ADV with all exhibits and attachments thereto (including the Sub-Advisor's statement of financial condition) and will hereafter supply to the Advisor, promptly upon the preparation thereof, copies of all amendments or restatements of such document.
Duties of the Master Servicer The Certificateholders, by their purchase and acceptance of the Certificates, appoint Aurora Loan Services Inc., as Master Servicer. For and on behalf of the Depositor, the Trustee and the Certificateholders, the Master Servicer shall master service the Mortgage Loans in accordance with the provisions of this Agreement and the provisions of the applicable Servicing Agreement.
