Limitation on Out-of-State Litigation - Texas Business and Commerce Code § 272 This is a requirement of the TIPS Contract and is non-negotiable. Texas Business and Commerce Code § 272 prohibits a construction contract, or an agreement collateral to or affecting the construction contract, from containing a provision making the contract or agreement, or any conflict arising under the contract or agreement, subject to another state’s law, litigation in the courts of another state, or arbitration in another state. If included in Texas construction contracts, such provisions are voidable by a party obligated by the contract or agreement to perform the work. By submission of this proposal, Vendor acknowledges this law and if Vendor enters into a construction contract with a Texas TIPS Member under this procurement, Vendor certifies compliance.
BREACH DISCOVERY AND NOTIFICATION 23 1. Following the discovery of a Breach of Unsecured PHI, CONTRACTOR shall notify 24 COUNTY of such Breach, however both parties agree to a delay in the notification if so advised by a 25 law enforcement official pursuant to 45 CFR § 164.412.
Certification Regarding Prohibition of Boycotting Israel (Tex Gov. Code 2271) If (a) Vendor is not a sole proprietorship; (b) Vendor has ten (10) or more full-time employees; and (c) this Agreement or any agreement with a TIPS Member under this procurement has value of $100,000 or more, the following certification shall apply; otherwise, this certification is not required. Vendor certifies, where applicable, that neither the Vendor, nor any affiliate, subsidiary, or parent company of Vendor, if any, boycotts Israel, and Vendor agrees that Vendor and Vendor Companies will not boycott Israel during the term of this Agreement. For purposes of this Agreement, the term “boycott” shall mean and include refusing to deal with, terminating business activities with, or otherwise taking any action that is intended to penalize, inflict economic harm on, or limit commercial relations with Israel, or with a person or entity doing business in Israel or in an Israeli-controlled territory but does not include an action made for ordinary business purposes. When applicable, does Vendor certify? Yes
Waiver of Appellate and Post-Conviction Rights a. The defendant acknowledges, understands and agrees that by pleading guilty pursuant to this plea agreement he waives his right to appeal or collaterally attack a finding of guilt following the acceptance of this plea agreement, except on grounds of (1) ineffective assistance of counsel; or (2) prosecutorial misconduct.
Duties of arbitrator in relation to Performance Orders Without prejudice to any additional remedies that may be ordered by the arbitrator under Clause 13.4, where a dispute is allocated in accordance with the ADRR to arbitration and a party has applied for a Performance Order, the parties shall agree in a Procedure Agreement, as defined in the ADRR, that:
APPLICATION AND PARTIES BOUND 5.1 The parties bound by this General Agreement are listed in Schedule 5.
NOTIFICATION OF PUBLIC EVENTS AND MEETINGS 2 A. CONTRACTOR shall notify ADMINISTRATOR of any public event or meeting funded in 3 whole or in part by the COUNTY, except for those events or meetings that are intended solely to serve 4 clients or occur in the normal course of business.
Certification of Funds; Budget and Fiscal Provisions; Termination in the Event of Non-Appropriation This Agreement is subject to the budget and fiscal provisions of the City’s Charter. Charges will accrue only after prior written authorization certified by the Controller, and the amount of City’s obligation hereunder shall not at any time exceed the amount certified for the purpose and period stated in such advance authorization. This Agreement will terminate without penalty, liability or expense of any kind to City at the end of any fiscal year if funds are not appropriated for the next succeeding fiscal year. If funds are appropriated for a portion of the fiscal year, this Agreement will terminate, without penalty, liability or expense of any kind at the end of the term for which funds are appropriated. City has no obligation to make appropriations for this Agreement in lieu of appropriations for new or other agreements. City budget decisions are subject to the discretion of the Mayor and the Board of Supervisors. Contractor’s assumption of risk of possible non-appropriation is part of the consideration for this Agreement. THIS SECTION CONTROLS AGAINST ANY AND ALL OTHER PROVISIONS OF THIS AGREEMENT.
Necessity for Written Approvals All approvals and decisions of the Regional Water Board under the terms of this Stipulated Order shall be communicated to the Settling Respondent in writing. No oral advice, guidance, suggestions, or comments from Regional Water Board employees or officials regarding submissions or notices shall be construed to relieve the Settling Respondent of its obligation to obtain any final written approval this Stipulated Order requires.
Judicial Council 's Obligation Subject to Availability of Funds A. The Judicial Council's obligation under this Agreement is subject to the availability of authorized funds. The Judicial Council may terminate the Agreement or any part of the Contract Work, without prejudice to any right or remedy of the Judicial Council, for lack of appropriation of funds. If expected or actual funding is withdrawn, reduced, or limited in any way prior to the expiration date set forth in this Agreement, or in any Amendment hereto, the Judicial Council may, upon written Notice to the Contractor, terminate this Agreement in whole or in part. Such termination shall be in addition to the Judicial Council's rights to terminate for cause or other than for cause, as set forth herein.
