Duty to Give Notice to Owner. If the Owner, the Program Manager, or any other person with whom the Owner has a direct contractual relationship shall, in the judgment of the Design-Builder, acts or fails to act in such a manner as to (i) delay the progress of the construction of the Project or (ii) increase the cost of the Project, Design-Builder shall give prompt notice to Owner so as to permit Owner to take corrective action.
Appears in 13 contracts
Samples: Design Build Contract, Design Build Contract, Design Build Contract
Duty to Give Notice to Owner. If the Owner, the Program ManagerExecutive Administrator, or any other person with whom the Owner or Executive Administrator respectively has a direct contractual relationship shall, in the judgment of the Design-Design- Builder, acts or fails to act in such a manner as to (i) delay the progress of the construction of the Project or (ii) increase the cost of the Project, Design-Builder shall give prompt notice to Owner so as to permit Owner to take corrective action.
Appears in 1 contract
Samples: gsfic.georgia.gov
Duty to Give Notice to Owner. If the Owner, the Program Manager, or any other person with whom the Owner has a direct contractual relationship shall, in the judgment of the Design-Builder, acts or fails to act in such a manner as to (i) delay the progress of the construction of the Project or (ii) increase the cost of the Project, Design-Builder shall give prompt notice to Owner so as to permit Owner to take corrective action.to
Appears in 1 contract
Samples: Design Build Contract
Duty to Give Notice to Owner. If the Owner, the Program ManagerExecutive Administrator, or any other person with whom the Owner or Executive Administrator respectively has a direct contractual relationship shall, in the judgment of the Design-Builder, acts or fails to act in such a manner as to (i) delay the progress of the construction of the Project or (ii) increase the cost of the Project, Design-Builder shall give prompt notice to Owner so as to permit Owner to take corrective action.
Appears in 1 contract
Samples: Construction Contract
Duty to Give Notice to Owner. If the Owner, the Program ManagerArchitect, or any other person with whom the Owner or Architect respectively has a direct contractual relationship relationship, including the Program Manager, shall, in the judgment of the Design-BuilderConstruction Manager, acts act or fails fail to act in such a manner as to (i) delay the progress of the construction of the Project or (ii) increase the cost of the Project, Design-Builder shall give prompt notice to Owner so as to permit Owner to take corrective action.or
Appears in 1 contract
Samples: Construction Management Agreement