Waiver of Breach; Specific Performance The waiver of a breach of any provision of this Agreement shall not operate or be construed as a waiver of any other breach. Each of the parties to this Agreement will be entitled to enforce this Agreement, specifically, to recover damages by reason of any breach of this Agreement, and to exercise all other rights existing in that party’s favor. The parties hereto agree and acknowledge that money damages may not be an adequate remedy for any breach of the provisions of this Agreement and that any party may apply to any court of law or equity of competent jurisdiction for specific performance or injunctive relief to enforce or prevent any violations of the provisions of this Agreement.
Excuse for Nonperformance or Delayed Performance Except with respect to defaults of subcontractors, Contractor/Vendor shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure by Contractor/Vendor to make progress in the prosecution of the work hereunder which endangers such performance) if Contractor/Vendor has notified the Commission or designee within 15 days after the cause of the delay and the failure arises out of causes such as: acts of God; acts of the public enemy; acts of the State and any other governmental entity in its sovereign or contractual capacity; fires; floods; epidemics; quarantine restrictions; strikes or other labor disputes; freight embargoes; or unusually severe weather. If the failure to perform is caused by the failure of a subcontractor to perform or to make progress, and if such failure arises out of causes similar to those set forth above, Contractor/Vendor shall not be deemed to be in default, unless the services to be furnished by the subcontractor were reasonably obtainable from other sources in sufficient time to permit Contractor to meet the contract requirements. Upon request of Contractor, the Commission or designee shall ascertain the facts and extent of such failure, and, if such officer determines that any failure to perform was occasioned by any one or more of the excusable causes, and that, but for the excusable cause, Contractor’s progress and performance would have met the terms of the contract, the delivery schedule shall be revised accordingly, subject to the rights of the State under the clause entitled (in fixed-price contracts, “Termination for Convenience,” in cost-reimbursement contracts, “Termination”). (As used in this Paragraph of this clause, the term “subcontractor” means subcontractor at any tier).
Excuse from performance of obligations If the Affected Party is rendered wholly or partially unable to perform its obligations under this Agreement because of a Force Majeure Event, it shall be excused from performance of such of its obligations to the extent it is unable to perform on account of such Force Majeure Event; provided that: (a) the suspension of performance shall be of no greater scope and of no longer duration than is reasonably required by the Force Majeure Event; (b) the Affected Party shall make all reasonable efforts to mitigate or limit damage to the other Party arising out of or as a result of the existence or occurrence of such Force Majeure Event and to cure the same with due diligence; and (c) when the Affected Party is able to resume performance of its obligations under this Agreement, it shall give to the other Party notice to that effect and shall promptly resume performance of its obligations hereunder.
Right to Specific Performance THE COMPANY HEREBY ACKNOWLEDGES AND AGREES THAT THE DAMAGES TO BE INCURRED BY PARTICIPANT AS A RESULT OF THE COMPANY’S BREACH OF THIS AGREEMENT WILL BE DIFFICULT, IF NOT IMPOSSIBLE, TO ASCERTAIN, THAT DAMAGES WILL NOT BE AN ADEQUATE REMEDY AND THAT ANY BREACH OR THREATENED BREACH OF ANY OF THE PROVISIONS OF THIS AGREEMENT BY THE COMPANY MAY CAUSE IMMEDIATE IRREPARABLE HARM FOR WHICH THERE MAY BE NO ADEQUATE REMEDY AT LAW. ACCORDINGLY, THE PARTIES AGREE THAT, IN THE EVENT OF ANY SUCH BREACH OR THREATENED BREACH, PARTICIPANT SHALL BE ENTITLED TO IMMEDIATE AND PERMANENT EQUITABLE RELIEF (INCLUDING INJUNCTIVE RELIEF AND SPECIFIC PERFORMANCE OF THE PROVISIONS OF THIS AGREEMENT) FROM A COURT OF COMPETENT JURISDICTION (IN ADDITION TO ANY OTHER REMEDY TO WHICH IT MAY BE ENTITLED AT LAW OR IN EQUITY). THE PARTIES AGREE AND STIPULATE THAT PARTICIPANT SHALL BE ENTITLED TO SUCH EQUITABLE (INCLUDING INJUNCTIVE) RELIEF WITHOUT POSTING A BOND OR OTHER SECURITY AND THE COMPANY FURTHER WAIVES ANY DEFENSE IN ANY SUCH ACTION FOR SPECIFIC PERFORMANCE OR INJUNCTIVE RELIEF THAT A REMEDY AT LAW WOULD BE ADEQUATE AND ANY REQUIREMENT UNDER LAW TO POST SECURITY AS A PREREQUISITE TO OBTAINING EQUITABLE RELIEF. NOTHING CONTAINED IN THIS SECTION SHALL LIMIT THE PARTIES’ RIGHT TO ANY REMEDIES AT LAW, INCLUDING THE RECOVERY OF DAMAGES FOR BREACH OF THIS AGREEMENT.
Right to Compel Performance Notwithstanding the foregoing, upon the occurrence of an event of Default, a non-Defaulting Interconnection Party shall be entitled to (a) commence an action to require the Defaulting Interconnection Party to remedy such Default and specifically perform its duties and obligations hereunder in accordance with the terms and conditions hereof, (b) withhold payments, (c) suspend performance hereunder, and (d) exercise such other rights and remedies as it may have in equity or at law; provided, however, that the Transmission Provider shall not terminate the Interconnection Service Agreement due to the failure of Interconnection Customer to make a payment hereunder unless such failure could reasonably be expected to have a material adverse effect on the Interconnected Transmission Owner.
Contractor’s Performance Warranties Contractor represents and warrants to the State that: (i) Each and all of the services shall be performed in a timely, diligent, professional and skillful manner, in accordance with the highest professional or technical standards applicable to such services, by qualified persons with the technical skills, training and experience to perform such services in the planned environment. (ii) Any time software is delivered to the State, whether delivered via electronic media or the internet, no portion of such software or the media upon which it is stored or delivered will have any type of software routine or other element which is designed to facilitate unauthorized access to or intrusion upon; or unrequested disabling or erasure of; or unauthorized interference with the operation of any hardware, software, data or peripheral equipment of or utilized by the State. Without limiting the generality of the foregoing, if the State believes that harmful code may be present in any software delivered hereunder, Contractor will, upon State’s request, provide a new or clean install of the software. Notwithstanding the foregoing, Contractor assumes no responsibility for the State’s negligence or failure to protect data from viruses, or any unintended modification, destruction or disclosure. (iii) To the extent Contractor resells commercial hardware or software it purchased from a third party, Contractor will, to the extent it is legally able to do so, pass through any such third party warranties to the State and will reasonably cooperate in enforcing them. Such warranty pass-through will not relieve the Contractor from Contractor’s warranty obligations set forth herein.
Work Performance Xxxxxx agrees that all Services performed hereunder shall be performed on a best effort basis by employees, students, faculty, graduate assistants and staff having an appropriate experience and skill level and in compliance with the statement of work.
Performance by Affiliates Each Party may discharge any obligations and exercise any right hereunder through any of its Affiliates. Each Party hereby guarantees the performance by its Affiliates of such Party’s obligations under this Agreement, and shall cause its Affiliates to comply with the provisions of this Agreement in connection with such performance. Any breach by a Party’s Affiliate of any of such Party’s obligations under this Agreement shall be deemed a breach by such Party, and the other Party may proceed directly against such Party without any obligation to first proceed against such Party’s Affiliate.
Specific Performance, Etc The parties recognize that if any provision of this Agreement is violated by the Company, Indemnitee may be without an adequate remedy at law. Accordingly, in the event of any such violation, Indemnitee shall be entitled, if Indemnitee so elects, to institute Proceedings, either in law or at equity, to obtain damages, to enforce specific performance, to enjoin such violation, or to obtain any relief or any combination of the foregoing as Indemnitee may elect to pursue.
Compensation for Damages 4.1 If the Principal has disqualified the Bidder from the tender process prior to the award according to Section 3, the Principal is entitled to demand and recover the damages equivalent Xxxxxxx Money Deposit/Bid Security. 4.2 If the Principal has terminated the contract according to Section 3, or if the Principal is entitled to terminate the contract according to section 3, the Principal shall be entitled to demand and recover from the Contractor liquidated damages equivalent to 5% of the contract value or the amount equivalent to Security Deposit/Performance Bank Guarantee, whichever is higher.
