Early Access Sublandlord agrees to cooperate with Subtenant to allow Subtenant access to the Initial Premises from the day following the Consent Date to the Delivery Date and deliver exclusive possession of the Initial Premises, including the Data Room (but excluding the Lab Space), on the Delivery Date, for design and construction purposes and for the purposes of the installation of furniture, fixtures and equipment and preparing the Initial Premises for occupancy (the “Early Access Activities”), provided that Subtenant has first given Sublandlord at least one (1) business day’s prior notice of any such access (for access prior to the Delivery Date only) and has first delivered to Sublandlord a certificate of insurance evidencing compliance with the insurance obligations herein. Such access (a) shall be solely for the Early Access Activities and not for the purposes of occupancy or possession of the Initial Premises, or of conducting business therein, and (b) shall be subject to and upon all the terms and conditions of this Sublease (including without limitation Section 11 hereof), except that Subtenant shall have no obligation to pay Base Rent or Additional Rent for the period prior to the Initial Premises Commencement Date; provided, however, that if Subtenant’s pursuit of the Early Access Activities causes an increase of more than ten percent (10%) in the cost of utilities (including without limitation water, electricity, heat or air conditioning) allocable to the Initial Premises on a square-foot basis (as compared to the average cost for such utilities over the prior three (3) months), Subtenant shall reimburse Sublandlord for such increase in the cost of utilities within thirty (30) days following Sublandlord’s presentation of an invoice therefor (including reasonable supporting documentation), which invoice shall be presented to Subtenant within fifteen (15) days following each month of such Early Access Activities. The Early Access Activities shall be performed between the hours of 6:00 a.m. and 5:00 p.m. on business days, and shall be coordinated with Sublandlord. Subtenant’s early access shall not affect or alter the Initial Premises Commencement Date, the Expansion Premises Commencement Date, the Expiration Date, or the Term.
Completion Date Completion date" shall be the date on which the improvements erected and to be erected upon the leased premises shall have been completed in accordance with the plans and specifications described in article 6.00. The completion date shall constitute the commencement of the term of this Lease for all purposes, whether or not Lessee has actually taken possession. Lessor shall use its best efforts to establish the completion date as the date set forth in section 1.03. In the event that the improvements have not in fact been completed as of that date, Lessee shall notify Lessor in writing of its objections. Lessor shall have a reasonable time after delivery of the notice in which to take such corrective action as may be necessary and shall notify Lessee in writing as soon as it deems such corrective action has been completed and the improvements are ready for occupancy. Upon completion of construction, Lessee shall deliver to Lessor a letter accepting the leased premises as suitable for the purposes for which they are let and the date of such letter shall constitute the commencement of the term of this Lease. Whether or not Lessee has executed such letter of acceptance, taking possession of the leased premises by Lessee shall be deemed to establish conclusively that the improvements have been completed in accordance with the plans and specifications, are suitable for the purposes for which the leased premises are let, and that the leased premises are in good and satisfactory condition as of the date possession was so taken by Lessee, except for latent defects, if any.
Network Access Control The VISION Web Site and the Distribution Support Services Web Site (the “DST Web Sites”) are protected through multiple levels of network controls. The first defense is a border router which exists at the boundary between the DST Web Sites and the Internet Service Provider. The border router provides basic protections including anti-spoofing controls. Next is a highly available pair of stateful firewalls that allow only HTTPS traffic destined to the DST Web Sites. The third network control is a highly available pair of load balancers that terminate the HTTPS connections and then forward the traffic on to one of several available web servers. In addition, a second highly available pair of stateful firewalls enforce network controls between the web servers and any back-end application servers. No Internet traffic is allowed directly to the back-end application servers. The DST Web Sites equipment is located and administered at DST’s Winchester data center. Changes to the systems residing on this computer are submitted through the DST change control process. All services and functions within the DST Web Sites are deactivated with the exception of services and functions which support the transfer of files. All ports on the DST Web Sites are disabled, except those ports required to transfer files. All “listeners,” other than listeners required for inbound connections from the load balancers, are deactivated. Directory structures are “hidden” from the user. Services which provide directory information are also deactivated.
Commencement Date Landlord shall deliver possession of the Premises to Tenant on the date (the “Delivery Date”) that Landlord’s Market Ready Improvements described on EXHIBIT C attached hereto and the Tenant Improvements to be completed by Landlord pursuant to the Work Letter Agreement attached hereto as EXHIBIT D are substantially completed. For purposes of this Lease, Landlord’s Market Ready Improvements and the Tenant Improvements shall be deemed to be “substantially completed” when Landlord’s Market Ready Improvements and the Tenant Improvements have been completed in accordance with any plans and specifications therefor, subject only to the completion of any minor punch-list items, and the City of Sunnyvale has completed a final inspection of such work and issued a temporary certificate of occupancy or other written approvals permitting legal occupancy of the Premises. The term of this Lease (“Term”) shall be seventy-six (76) months commencing on the date (the “Commencement Date”) which is thirty (30) days from the Delivery Date. If the Delivery Date does not occur on or before May 1, 2018, for any reason other than (i) ArcTec’s failure to complete the Final Plans and Specifications (as such term is defined in the Work Letter attached as EXHIBIT D) and submit such Final Plans and Specifications (and any other documentation required by the City of Sunnyvale for the issuance of a building permit for the Tenant Improvements) to Landlord’s general contractor by January 8, 2018, (ii) the City requiring Landlord to stop construction due to its commencement of the Tenant Improvements before the permits therefor were issued or (iii) delays caused by the acts or omission of Tenant, as defined in Paragraph 3(c) below, then the date Tenant is otherwise obliged to commence payment of Rent shall be delayed by one (1) additional day for each day the Delivery Date is delayed beyond such date.
Access Control Landlord shall be the sole determinant of the type and amount of any access control or courtesy guard services to be provided to the Project, if any. IN ALL EVENTS, LANDLORD SHALL NOT BE LIABLE TO TENANT, AND TENANT HEREBY WAIVES ANY CLAIM AGAINST LANDLORD, FOR (I) ANY UNAUTHORIZED OR CRIMINAL ENTRY OF THIRD PARTIES INTO THE PREMISES, THE BUILDING OR THE PROJECT, (II) ANY DAMAGE TO PERSONS, OR (III) ANY LOSS OF PROPERTY IN AND ABOUT THE PREMISES, THE BUILDING OR THE PROJECT, BY OR FROM ANY UNAUTHORIZED OR CRIMINAL ACTS OF THIRD PARTIES, REGARDLESS OF ANY ACTION, INACTION, FAILURE, BREAKDOWN, MALFUNCTION AND/OR INSUFFICIENCY OF THE ACCESS CONTROL OR COURTESY GUARD SERVICES PROVIDED BY LANDLORD, IF ANY. Tenant shall provide such supplemental security services and shall install within the Premises such supplemental security equipment, systems and procedures as may reasonably be required for the protection of its employees and invitees, provided that Tenant shall coordinate such services and equipment with any security provided by Landlord. The determination of the extent to which such supplemental security equipment, systems and procedures are reasonably required shall be made in the sole judgment, and shall be the sole responsibility, of Tenant. Tenant acknowledges that it has neither received nor relied upon any representation or warranty made by or on behalf of Landlord with respect to the safety or security of the Premises or the Project or any part thereof or the extent or effectiveness of any security measures or procedures now or hereafter provided by Landlord, and further acknowledges that Tenant has made its own independent determinations with respect to all such matters.
Extension of Scheduled Termination Date Under the Fee Agreement, the Fund shall have the right, exercisable not more than one hundred twenty (120) days nor less than ninety (90) days prior to the Scheduled Termination Date, to request that the Liquidity Provider extend the term of such Scheduled Termination Date for an additional period of up to 364 days or, if mutually agreed upon by the parties to the Fee Agreement, a period greater than 364 days, which request may be conditioned upon terms and conditions that are different from the terms and conditions of this Agreement and the Fee Agreement then in effect. The Liquidity Provider shall, no later than thirty (30) days after receiving such request, notify the Fund and the Tender and Paying Agent of its acceptance or rejection of such request, which acceptance by the Liquidity Provider may be a Conditional Acceptance conditioned upon terms and conditions which are different from the terms and conditions of this Agreement and the Fee Agreement then in effect or the terms and conditions proposed by the Fund in making an extension request. If the Liquidity Provider fails to notify the Fund and the Tender and Paying Agent of its acceptance or rejection of the Fund's request for extension within such 30-day period, such failure to respond shall constitute a rejection of such request. If the Liquidity Provider provides a Conditional Acceptance, then the Fund shall have thirty (30) days thereafter to notify the Liquidity Provider and the Tender and Paying Agent of its acceptance or rejection of the terms and conditions specified in the Liquidity Provider's Conditional Acceptance. The Fund's failure to notify the Liquidity Provider and the Tender and Paying Agent within the 30-day period will be deemed a rejection of the terms and conditions specified in the Liquidity Provider's Conditional Acceptance. Under the Fee Agreement, the Fund will acknowledge and agree that the Liquidity Provider may grant or deny any request for extension of the Scheduled Termination Date in its sole and absolute discretion.
Technology Access Fee In consideration of the licenses and rights granted to Regado herein, Regado shall, as of the date immediately preceding the closing (the “Closing”) of the first equity financing of Regado in which Regado is assigned a pre-money valuation of not less than [***] dollars ($[***]), issue to Archemix fully-paid and non-assessable shares of common stock of Regado equal to [***] percent ([***]%) of the total number of equity shares of Regado, on a fully diluted basis, immediately prior to the issuance of shares at the Closing. Regado shall deliver written notice of the Closing to Archemix at least [***] business days prior to such Closing in accordance with the notice provisions contained in Section 14.1 of this Agreement. Archemix and Regado shall enter into such agreements relating to the issuance of the common stock as are customary under such circumstances. For the purpose of this Agreement, “fully diluted basis” shall mean the aggregate of (a) the number of shares of common stock issued and outstanding on the determination date, (b) the number of shares of common stock issuable upon exercise, exchange or conversion of all exercisable, exchangeable or convertible securities outstanding on the determination date, assuming such securities were exercised, exchanged or converted on the determination date (without regard to whether such securities are actually exercisable, exchangeable or convertible on the determination date) and (c) the number of shares of common stock issuable pursuant to any other obligation or agreement of, or right granted by, Regado, whether vested or unvested, contingent or otherwise.
Delivery; Acceptance of Premises; Commencement Date Landlord shall use reasonable efforts to deliver the Premises to Tenant on or before the Target Commencement Date, with Landlord’s Work Substantially Completed (“Delivery” or “Deliver”). If Landlord fails to timely Deliver the Premises, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and this Lease shall not be void or voidable except as provided herein. If Landlord does not Deliver the Premises within 90 days of the Target Commencement Date for any reason other than Force Majeure delays and Tenant Delays, this Lease may be terminated by Landlord or Tenant by written notice to the other, and if so terminated by either: (a) the Security Deposit, or any balance thereof (i.e., after deducting therefrom all amounts to which Landlord is entitled under the provisions of this Lease), shall be returned to Tenant, and (b) neither Landlord nor Tenant shall have any further rights, duties or obligations under this Lease, except with respect to provisions which expressly survive termination of this Lease. As used herein, the terms “Landlord’s Work,” “Tenants’ Work,” and “Force Majeure Delays” shall have the meanings set forth for such terms in the Work Letter. If neither Landlord nor Tenant elects to void this Lease within 10 business days of the lapse of such 90 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect; provided, however, that if Landlord does not Deliver the Premises within 150 days of the Target Commencement Date for any reason other than Force Majeure delays and Tenant Delays, this Lease may be terminated by Tenant by written notice to Landlord, in which case subsections (a) and (b) of this paragraph shall apply. If Tenant does not elected to void this Lease within 10 business days of the lapse of such 150 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect.
Post-Closing Access In order to facilitate Seller’s efforts to administer and close the Bankruptcy Case (including, without limitation, the preparation of filings in the Bankruptcy Case and state, local and federal Tax Returns and other filings, reconciliation of claims filed in the Case, removal of corporate and other records and information relating or belonging to entities other than Seller), for a period of three (3) years following the Closing, (a) the Buyer shall permit Seller’s counsel and other professionals and counsel for any successor to Seller and its respective professionals, and its employees (collectively, “Permitted Access Parties”) reasonable access to the financial and other books and records relating to the Acquired Assets or the Business and the systems containing such information, books and records, which access shall include (i) the right of such Permitted Access Parties to copy, at such Permitted Access Parties’ expense, such documents and records as they may request in furtherance of the purposes described above, and (ii) Buyer’s copying and delivering to the relevant Permitted Access Parties such documents or records as they may request, but only to the extent such Permitted Access Parties furnish Buyer with reasonably detailed written descriptions of the materials to be so copied and the applicable Permitted Access Party reimburses the Buyer for the reasonable costs and expenses thereof, and (b) Buyer shall provide the Permitted Access Parties (at no cost to the Permitted Access Parties) with reasonable access to those individuals with knowledge of how to access the relevant financial and books and records during regular business hours to assist Seller and the other Permitted Access Parties in their post-Closing activities (including, without limitation, preparation of Tax Returns), provided that such access does not unreasonably interfere with the Buyer’s business operations.
Commencement Date Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”):
