Equitable Adjustments (1) If the Contracting Officer confirms that Government conduct effected a change as alleged by the Contractor, and the conduct causes an increase or decrease in the Contractor's cost of, or the time required for, performance of any part of the work under this contract, whether changed or not changed by such conduct, an equitable adjustment shall be made-- (i) In the contract price or delivery schedule or both; and (ii) In such other provisions of the contract as may be affected. (2) The contract shall be modified in writing accordingly. In the case of drawings, designs or specifications which are defective and for which the Government is responsible, the equitable adjustment shall include the cost and time extension for delay reasonably incurred by the Contractor in attempting to comply with the defective drawings, designs or specifications before the Contractor identified, or reasonably should have identified, such defect. When the cost of property made obsolete or excess as a result of a change confirmed by the Contracting Officer under this clause is included in the equitable adjustment, the Contracting Officer shall have the right to prescribe the manner of disposition of the property. The equitable adjustment shall not include increased costs or time extensions for delay resulting from the Contractor's failure to provide notice or to continue performance as provided, respectively, in (b) and (c) above.
Equitable Adjustment Trading volume amounts, price/volume amounts and similar figures in the Transaction Documents shall be equitably adjusted (but without duplication) to offset the effect of stock splits, similar events and as otherwise described in this Agreement and Warrants.
Adjustment for Certain Events The number and kind of securities purchasable upon the exercise of this Warrant and the Warrant Price shall be subject to adjustment from time to time upon the occurrence of certain events, as follows:
Equitable Adjustments to Prices Whenever any provision of this Indenture requires the Company to calculate the average of the Last Reported Sale Prices, or any function thereof, over a period of multiple days (including to calculate the Stock Price or an adjustment to the Conversion Rate), or to calculate Daily VWAPs over an Observation Period, the Company will make proportionate adjustments, if any, to such calculations to account for any adjustment to the Conversion Rate pursuant to Section 5.05(A)(i) that becomes effective, or any event requiring such an adjustment to the Conversion Rate where the Ex-Dividend Date or effective date, as applicable, of such event occurs, at any time during such period or Observation Period, as applicable.
Determination of Adjustments If any questions will at any time arise with respect to the Exercise Price or any adjustment provided for in Section 4.8, such questions will be conclusively determined by the Company’s Auditors, or, if they decline to so act any other firm of certified public accountants in the United States of America that the Company may designate and who will have access to all appropriate records and such determination will be binding upon the Company and the Holders of the Warrants.
Calculation of Adjustments All adjustments to the Settlement Rate shall be calculated to the nearest 1/10,000th of a share of Common Stock (or if there is not a nearest 1/10,000th of a share to the next lower 1/10,000th of a share). No adjustment in the Settlement Rate shall be required unless such adjustment would require an increase or decrease of at least one percent therein; provided, that any adjustments which by reason of this subparagraph are not required to be made shall be carried forward and taken into account in any subsequent adjustment. If an adjustment is made to the Settlement Rate pursuant to paragraph (1), (2), (3), (4), (5), (6), (7) or (10) of this Section 5.6(a), an adjustment shall also be made to the Applicable Market Value solely to determine which of clauses (i), (ii) or (iii) of the definition of Settlement Rate in Section 5.1(a) will apply on the Stock Purchase Date. Such adjustment shall be made by multiplying the Applicable Market Value by a fraction, the numerator of which shall be the Settlement Rate immediately after such adjustment pursuant to paragraph (1), (2), (3), (4), (5), (6), (7) or (10) of this Section 5.6(a) and the denominator of which shall be the Settlement Rate immediately before such adjustment; provided, that if such adjustment to the Settlement Rate is required to be made pursuant to the occurrence of any of the events contemplated by paragraph (1), (2), (3), (4), (5), (7) or (10) of this Section 5.6(a) during the period taken into consideration for determining the Applicable Market Value, appropriate and customary adjustments shall be made to the Settlement Rate.
Fee Adjustments The fixed fees and other fees expressed as stated dollar amounts in this Schedule C and in this Agreement are subject to annual increases, commencing on the one-year anniversary date of the date of this Agreement, in an amount equal to the percentage increase in consumer prices for services as measured by the United States Consumer Price Index entitled “All Services Less Rent of Shelter,” or a similar index should such index no longer be published, since such one-year anniversary or since the date of the last fee increase, as applicable.
Certification of Adjustments Whenever an adjustment is made as provided in Sections 11 and 13 hereof, the Company shall (a) promptly prepare a certificate signed by its Chief Executive Officer, its President or any Vice President and by the Treasurer or any Assistant Treasurer or the Secretary or any Assistant Secretary of the Company setting forth such adjustment and a brief statement of the facts giving rise to such adjustment, (b) promptly file with the Rights Agent and with each transfer agent for the Preferred Stock and the Common Stock a copy of such certificate and (c) mail a brief summary thereof to each holder of a Right Certificate (or, if prior to the Distribution Date, to each holder of a certificate representing shares of Common Stock) in accordance with Section 26 hereof. Notwithstanding the foregoing sentence, the failure of the Company to give such notice shall not affect the validity of or the force or effect of or the requirement for such adjustment. The Rights Agent shall be fully protected in relying on any certificate prepared by the Company pursuant to Sections 11 and 13 and on any adjustment therein contained and shall not be deemed to have knowledge of any such adjustment unless and until it shall have received such certificate. Any adjustment to be made pursuant to Sections 11 and 13 of this Rights Agreement shall be effective as of the date of the event giving rise to such adjustment.
Performance Adjustment One-twelfth of the annual Performance Adjustment Rate will be applied to the average of the net assets of the Portfolio (computed in the manner set forth in the Fund's Declaration of Trust or other organizational document) determined as of the close of business on each business day throughout the month and the performance period.
Share Adjustments If the Company's outstanding shares of Common Stock are increased or decreased or changed into or exchanged for a different number or kind of shares or other securities of the Company by reason of any recapitalization, reclassification, stock split, combination of shares, stock dividend, or transaction having similar effect, the Board shall proportionately and appropriately adjust the number and kind of shares that are subject to this Option and the Exercise Price Per Share, without any change in the aggregate price to be paid therefor upon exercise of this Option.
