PREVAILING WAGE RATES - PUBLIC WORKS AND BUILDING SERVICES CONTRACTS If any portion of work being Bid is subject to the prevailing wage rate provisions of the Labor Law, the following shall apply:
Construction Period During the construction period, Redeveloper agrees to keep the construction area, including completed operations insured against loss or damage by fire, and such other risks, casualties, and hazards as are customarily covered by builders’ risk or extended coverage policies in an amount not less than the replacement value but allowing for reasonable coinsurance clauses and deductibles. In the event of any insured damage or destruction, Redeveloper agrees to use its good faith efforts to commence restoration of the Private Improvements to its prior condition within nine (9) months from the date of the damage or destruction, and shall diligently pursue the same to completion.
SAVINGS/FORCE MAJEURE A Force Majeure occurrence is an event or effect that cannot be reasonably anticipated or controlled and is not due to the negligence or willful misconduct of the affected party. Force Majeure includes, but is not limited to, acts of God, acts of war, acts of public enemies, terrorism, strikes, fires, explosions, actions of the elements, floods, or other similar causes beyond the control of the Contractor or the Commissioner in the performance of the Contract where non- performance, by exercise of reasonable diligence, cannot be prevented. The affected party shall provide the other party with written notice of any Force Majeure occurrence as soon as the delay is known and provide the other party with a written contingency plan to address the Force Majeure occurrence, including, but not limited to, specificity on quantities of materials, tooling, people, and other resources that will need to be redirected to another facility and the process of redirecting them. Furthermore, the affected party shall use its commercially reasonable efforts to resume proper performance within an appropriate period of time. Notwithstanding the foregoing, if the Force Majeure condition continues beyond thirty (30) days, the Parties shall jointly decide on an appropriate course of action that will permit fulfillment of the Parties’ objectives hereunder. The Contractor agrees that in the event of a delay or failure of performance by the Contractor, under the Contract due to a Force Majeure occurrence:
a. The Commissioner may purchase from other sources (without recourse to and by the Contractor for the costs and expenses thereof) to replace all or part of the Products which are the subject of the delay, which purchases may be deducted from the Contract quantities without penalty or liability to the State, or
b. The Contractor will make commercially reasonable efforts to provide Authorized Users with access to Products first in order to fulfill orders placed before the Force Majeure event occurred. The Commissioner agrees that Authorized Users shall accept allocated performance or deliveries during the occurrence of the Force Majeure event. Neither the Contractor nor the Commissioner shall be liable to the other for any delay in or failure of performance under the Contract due to a Force Majeure occurrence. Any such delay in or failure of performance shall not constitute default or give rise to any liability for damages. The existence of such causes of such delay or failure shall extend the period for performance to such extent as determined by the Contractor and the Commissioner to be necessary to enable complete performance by the Contractor if reasonable diligence is exercised after the cause of delay or failure has been removed. Notwithstanding the above, at the discretion of the Commissioner where the delay or failure will significantly impair the value of the Contract to the State or to Authorized Users, the Commissioner may terminate the Contract or the portion thereof which is subject to delays, and thereby discharge any unexecuted portion of the Contract or the relative part thereof. In addition, the Commissioner reserves the right, in his/her sole discretion, to make an equitable adjustment in the Contract terms and/or pricing should extreme and unforeseen volatility in the marketplace affect pricing or the availability of supply. "Extreme and unforeseen volatility in the marketplace" is defined as market circumstances which meet the following criteria: (i) the volatility is due to causes outside the control of Contractor; (ii) the volatility affects the marketplace or industry, not just the particular Contract source of supply; (iii) the effect on pricing or availability of supply is substantial; and (iv) the volatility so affects Contractor's performance that continued performance of the Contract would result in a substantial loss. Failure of the Contractor to agree to any adjustment shall be a dispute under the Disputes clause; provided however, that nothing in this clause shall excuse the Contractor from performing in accordance with the Contract as changed.
Additional Accounting Services Ultimus shall also perform the following additional accounting services for each Portfolio:
(i) Provide monthly (or as frequently as may reasonably be requested by the Trust or a Portfolio's investment adviser) a set of financial statements for each Portfolio as described below, upon request of the Trust: Statement of Assets and Liabilities Statement of Operations Statement of Changes in Net Assets Security Purchases and Sales Journals Portfolio Holdings Reports
(ii) Provide accounting information for the following:
(A) federal and state income tax returns and federal excise tax returns; (B) the Trust's semi-annual reports with the SEC on Form N-SAR; (C) the Trust's annual, semi-annual and quarterly (if any) shareholder reports; (D) registration statements on Form N-1A and other filings relating to the registration of shares; (E) Ultimus' monitoring of the Trust's status as a regulated investment company under Subchapter M of the Internal Revenue Code, as amended; (F) annual audit by the Trust's auditors; and (G) examinations performed by the SEC.
Random Testing Notwithstanding any provisions of the Collective Agreement or any special agreements appended thereto, section 4.6 of the Canadian Model will not be applied by agreement. If applied to a worker dispatched by the Union, it will be applied or deemed to be applied unilaterally by the Employer. The Union retains the right to grieve the legality of any imposition of random testing in accordance with the Grievance Procedure set out in this Collective Agreement.
FLORIDA CONVICTED/SUSPENDED/DISCRIMINATORY COMPLAINTS By submission of an offer, the respondent affirms that it is not currently listed in the Florida Department of Management Services Convicted/Suspended/Discriminatory Complaint Vendor List.
Operational Control Directing the operation of the Transmission Facilities Under ISO Operational Control to maintain these facilities in a reliable state, as defined by the Reliability Rules. The ISO shall approve operational decisions concerning these facilities, made by each Transmission Owner before the Transmission Owner implements those decisions. In accordance with ISO Procedures, the ISO shall direct each Transmission Owner to take certain actions to restore the system to the Normal State. Operational Control includes security monitoring, adjustment of generation and transmission resources, coordination and approval of changes in transmission status for maintenance, determination of changes in transmission status for reliability, coordination with other Control Areas, voltage reductions and Load Shedding, except that each Transmission Owner continues to physically operate and maintain its facilities.
Termination for Force Majeure 15.5.1. The License Agreement may be terminated for Force Majeure Reasons as specified in Article -14.
Study Population Infants who underwent creation of an enterostomy receiving postoperative care and awaiting enterostomy closure: to be assessed for eligibility: n = 201 to be assigned to the study: n = 106 to be analysed: n = 106 Duration of intervention per patient of the intervention group: 6 weeks between enterostomy creation and enterostomy closure Follow-up per patient: 3 months, 6 months and 12 months post enterostomy closure, following enterostomy closure (12-month follow-up only applicable for patients that are recruited early enough to complete this follow-up within the 48 month of overall study duration).
Contractor Selection In this section, please describe the selection process, including other sources considered and the rationale for selecting the contractor. Please answer all questions:
a. What specific skill set does this contractor bring to the project? Please attach a copy of the contractor’s resume if an individual or link to contractor website if a company: Little to Great Scientists is an international leader in early childhood, elementary, middle and high school science education. xxxxx://xxxxxxxxxxxxxxxxxxxxxxx.xxx/
b. How was the Contractor selected? Quotes, RFP/RFQ, Sealed Bid or Sole Source designation from the City of New Haven Purchasing Department? This contractor was selected because of their continued commitment to NHPS. They possess the knowledge base, resources, and motivation to support hands-on science education in New Haven. No other contractors were considered for this partnership.
c. Is the contractor the lowest bidder? N/A If no, why? Why was this contractor selected? This contractor was selected because of their unique expertise in hands-on science learning and their continued commitment to New Haven Public Schools. They possess the knowledge and resources to support science learning at Xxxxxxx Xxxxxx School.
d. Who were the members of the selection committee that scored bid applications? N/A
e. If the contractor is Sole Source, please attach a copy of the Sole Source designation letter from the City of New Haven Purchasing Department. N/A
