REVIEW OF CONTRACT DOCUMENTS 4.2.1 The Contractor shall carefully study and compare the Contract Documents and shall immediately report in writing to the Architect and the State any error, inconsistency or omission he may discover. The Contractor shall not be liable to the State or the Architect for any damage resulting from any such errors, inconsistencies or omissions in the Contract Documents. The
Maintaining Records; Access to Properties and Inspections Maintain financial records in accordance with GAAP and, upon reasonable notice, permit any representatives designated by the Administrative Agent or any Lender to visit and inspect the financial records and the properties of the Borrower or any Significant Subsidiary during normal business hours and to discuss the affairs, finances and condition of the Borrower or any Significant Subsidiary with the officers thereof and independent accountants therefor.
THE CONTRACT DOCUMENTS The Contract Documents consist of the State-Contractor Agreement, the Conditions of the Contract (General, Supplementary and other Conditions), the Drawings, the Specifications, and all Addenda issued prior to bid opening and any Change Orders after execution of the Contract.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Contract Construction 6.27.1 The parties acknowledge that each party and its counsel have reviewed this CONTRACT and that the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this CONTRACT or any amendment or exhibits hereto.
Construction Contracts Item A: Enter the total dollar amount of all contacts awarded on the project/ program. Item B: Enter the total dollar amount of contracts connected with this project/program that were awarded to Section 3 businesses.
Copies of Contract Documents to Contractor Without charge to the Contractor the Design Professional shall furnish to the Contractor up to five sets of completed Contract Documents in hardcopy, one set of reproducible and electronic background floor and reflected ceiling plan drawings and, if requested, one copy in read-only electronic format. The Contractor may obtain such additional sets of Contract Documents, as the Contractor deems necessary and shall pay the cost of reproduction of such additional sets to the Design Professional.
Project Construction The Contractor agrees to provide continuous on-site supervision on each Job Order, while progress on the project is being accomplished. The Contractor’s Project Manager will ensure:
1. Coordination and providing supervision to all Subcontractor and workers;
2. Posting of the prevailing wage scale;
3. Maintaining a copy of the Contractors safety program manual made available to all construction personnel;
4. Conducting weekly on-site safety meetings;
5. Completing the daily labor and construction progress log on a daily basis and submit copies to the County on a daily basis. Copies of the previous day’s reports must be submitted by 9:00AM of the following day.
a. Daily labor log is to include a listing of Subcontractor(s) and a count of workers by trade providing services for the day.
b. Construction progress log is to include a narrative of the Work provided by trade(s). Narrative agrees to include the various areas of the jobsite where Work was performed and any problems or conditions that were encountered.
c. In the event the Contractor fails to provide a daily log and/or construction progress log, the County may impose damages against the Contractor in the amount of fifty dollars ($50.00) for each log and deduct from the Contractor’s payment request, for each day the Contractor does not provide the documentation.
6. County may suspend Contractor operations if no Contractor Superintendent is observed. All delays caused by the suspension will be the responsibility of the Contractor. No time extension or claims for cost(s) associated with the suspension will be granted by the County.
EXAMINATION OF MORTGAGE FILES AND DUE DILIGENCE REVIEW 3.1 Seller shall (i) deliver to Purchaser on or before the Closing Date a diskette acceptable to Purchaser that contains such information about the Mortgage Loans as may be reasonably requested by Purchaser, (ii) deliver to Purchaser on or before the Closing Date investor files (collectively the “Collateral Information”) with respect to the Mortgage Loans proposed to be included in the Issuing Entity and made available at Purchaser’s headquarters in New York, and (iii) otherwise cooperate fully with Purchaser in its examination of the credit files, underwriting documentation and Mortgage Files for the Mortgage Loans and its due diligence review of the Mortgage Loans. The fact that Purchaser has conducted or has failed to conduct any partial or complete examination of the credit files, underwriting documentation or Mortgage Files for the Mortgage Loans shall not affect the right of Purchaser or the Trustee to cause Seller to cure any Material Defect, or to repurchase or replace the defective Mortgage Loans pursuant to Section 5 hereof.
3.2 On or prior to the Closing Date, Seller shall allow representatives of Purchaser and any designees thereof to examine and audit all books, records and files pertaining to the Mortgage Loans, Seller’s underwriting procedures and Seller’s ability to perform or observe all of the terms, covenants and conditions of this Agreement. Such examinations and audits shall take place upon reasonable prior advance notice at one or more offices of Seller during normal business hours and shall not be conducted in a manner that is disruptive to Seller’s normal business operations. In the course of such examinations and audits, Seller will make available to such representatives of Purchaser and any designees thereof reasonably adequate facilities, as well as the assistance of a sufficient number of knowledgeable and responsible individuals who are familiar with the Mortgage Loans and the terms of this Agreement, and Seller shall cooperate fully with any such examination and audit in all material respects. On or prior to the Closing Date, Seller shall provide Purchaser with all material information regarding Seller’s financial condition and access to knowledgeable financial or accounting officers for the purpose of answering questions with respect to Seller’s financial condition, financial statements as provided to Purchaser or other developments affecting Seller’s ability to consummate the transactions contemplated hereby or otherwise affecting Seller in any material respect. Within forty-five (45) days after the Closing Date, Seller shall provide the Master Servicer with any additional information identified by the Master Servicer as necessary to complete the CREFC® Property File, to the extent that such information is available to Seller.
3.3 Purchaser may exercise any of its rights hereunder through one or more designees or agents, provided Purchaser has provided Seller with prior notice of the identity of such designee or agent.
3.4 Purchaser shall keep confidential any information regarding Seller and, to the extent required pursuant to the terms of the Pooling and Servicing Agreement, the Mortgage Loans that has been delivered into Purchaser’s possession and that is not otherwise publicly available; provided, that such information shall not be kept confidential (and the right to require confidentiality under any confidentiality agreement is hereby waived) to the extent Purchaser deems such information necessary and appropriate or required to be included in the Preliminary Memorandum, the Final Memorandum, the Preliminary Prospectus, the Prospectus (as defined in the Pooling and Servicing Agreement) or any other disclosure document relating to the Certificates or Purchaser is required by law or court order to disclose such information. If Purchaser is required or otherwise deems it necessary and appropriate to disclose in the Preliminary Prospectus, the Preliminary Memorandum, the Final Memorandum, the Prospectus or any other disclosure document relating to the Certificates confidential information regarding Seller as described in the preceding sentence, Purchaser shall provide to Seller a copy of the proposed form of such disclosure prior to making such disclosure and Seller shall promptly, and in any event within two (2) Business Days, notify Purchaser of any inaccuracies therein, in which case Purchaser shall modify such form in a manner that corrects such inaccuracies. If Purchaser is required by law or court order to disclose confidential information regarding Seller as described in the second preceding sentence, Purchaser shall notify Seller and cooperate in Seller’s efforts to obtain a protective order or other reasonable assurance that confidential treatment will be accorded such information and, if in the absence of a protective order or such assurance, Purchaser is compelled as a matter of law to disclose such information, Purchaser shall, prior to making such disclosure, advise and consult with Seller and its counsel as to such disclosure and the nature and wording of such disclosure and Purchaser shall use reasonable efforts to obtain confidential treatment therefor. Notwithstanding the foregoing, if reasonably advised by counsel that Purchaser is required by a regulatory agency or court order to make such disclosure immediately, then Purchaser shall be permitted to make such disclosure without prior review by Seller and shall give Seller prompt notice of such disclosure.
Books and Records; Inspection and Examination The Borrower will keep accurate books of record and account for itself pertaining to the Collateral and pertaining to the Borrower's business and financial condition and such other matters as the Lender may from time to time request in which true and complete entries will be made in accordance with GAAP and, upon the Lender's request, will permit any officer, employee, attorney or accountant for the Lender to audit, review, make extracts from or copy any and all corporate and financial books and records of the Borrower at all times during ordinary business hours, to send and discuss with account debtors and other obligors requests for verification of amounts owed to the Borrower, and to discuss the Borrower's affairs with any of its directors, officers, employees or agents. The Borrower will permit the Lender, or its employees, accountants, attorneys or agents, to examine and inspect any Collateral, other collateral covered by the Security Documents or any other property of the Borrower at any time during ordinary business hours.
