Exhibit B, Paragraph 4 A and B – Completion Dates. These subparagraph provisions are deleted in their entirety and replaced with the following:
Exhibit B, Paragraph 4 A and B – Completion Dates Sample Clauses
Related to Exhibit B, Paragraph 4 A and B – Completion Dates
Completion Dates The Recipient agrees to complete each Project within the time periods specified in the Underlying Agreement and all activities must be completed by the Award’s end date, unless FTA agrees in writing to extend the end date. Unless FTA determines otherwise in writing, interim milestone dates and other completion dates applicable to the Award are good faith estimates and are not intended to be firm contractual requirements. However, FTA and the Recipient agree that milestone dates and other completion dates for Full Funding Grant Agreements, Small Starts Grant Agreements or other specific agreements in which FTA expressly states that the milestone dates or other completion dates for the Underlying Agreement are firm dates that may be enforced.
ADDITIONAL SPECIAL CONTRACT CONDITIONS A. Special Contract Conditions revisions: the corresponding subsections of the Special Contract Conditions referenced below are replaced in their entirety with the following:
C4 Price adjustment on extension of the Initial Contract Period C4.1 The Contract Price shall apply for the Initial Contract Period. In the event that the Client agrees to extend the Initial Contract Period pursuant to clause F8 (Extension of Initial Contract Period) the Client shall, in the 6 month period prior to the expiry of the Initial Contract Period, enter into good faith negotiations with the Contractor (for a period of not more than 30 Working Days) to agree a variation in the Contract Price.
Commencement Date The Subcontractor shall be permitted to begin the Services on , 20 (“Commencement Date”).
COMPLETE STATEMENTS 1 THROUGH 5 BELOW 1. This request is for an: Update Amendment See Contract Modification Procedure for an explanation of these terms. 2. The intent of this submittal is to request: Addition of new products or services Deletion of products or services Change in pricing level Other Update Other Amendment
EFFECTIVE DATE/COMPLETION OF SERVICES 3.1 Notwithstanding any provision of this Agreement to the contrary, and subject to the approval of the Governor and Executive Council of the State of New Hampshire, if applicable, this Agreement, and all obligations of the parties hereunder, shall become effective on the date the Governor and Executive Council approve this Agreement as indicated in block 1.17, unless no such approval is required, in which case the Agreement shall become effective on the date the Agreement is signed by the State Agency as shown in block 1.13 (“Effective Date”).
Substantial Completion Date Substantial Completion of the Work as defined in Article 6.1.2 of the General Conditions to the Continuing Contract for Construction Management shall be achieved by July 31, 2022.
Salary Schedule Progression Employees shall progress from step to step in salary grade on the basis of satisfactory job performance based upon established standards of performance. Seasonal employee's initial anniversary date shall be established after being in pay status for two thousand eighty (2,080) hours. Such date shall then be used for annual performance evaluation and step progression consideration. When an employee's anniversary date falls on any day from the first day of a pay week through Wednesday of the pay week, the employee's merit increase shall be effective as of the first day of the pay week within which the anniversary date falls. Otherwise, the merit increase shall be effective on the first day of the next pay week. Grievances arising from the denial of merit increases shall not be arbitrable under this Agreement but shall be processed as follows:
Completion Date The Work under this Contract shall be completed by midnight of the date required in the Contract as the Material Completion and Occupancy Date unless extended by approved requests for extension of time.
Requesting Price Increase/Required Documentation Contractor must submit a written notification at least thirty (30) calendar days prior to the requested effective date of the change, setting the amount of the increase, along with an itemized list of any increased prices, showing the Contractor’s current price, revised price, the actual dollar difference and the percentage of the price increase by line item. Price change requests must include H-GAC Forms D Offered Item Pricing and E Options Pricing, or the documentation used to submit pricing in the original Response and be supported with substantive documentation (e.g. manufacturer's price increase notices, copies of invoices from suppliers, etc.) clearly showing that Contractor's actual costs have increased per the applicable line item bid. The Producer Price Index (PPI) may be used as partial justification, subject to approval by H-GAC, but no price increase based solely on an increase in the PPI will be allowed. This documentation should be submitted in Excel format to facilitate analysis and updating of the website. The letter and documentation must be sent to the Bids and Specifications manager, Xxxxxxx Xxxxxx, at Xxxxxxx.Xxxxxx@x-xxx.xxx Review/Approval of Requests If H-GAC approves the price increase, Contractor will be notified in writing; no price increase will be effective until Contractor receives this notice. If H-GAC does not approve Contractor’s price increase, Contractor may terminate its performance upon sixty (60) days advance written notice to H-GAC, however Contractor must fulfill any outstanding Purchase Orders. Termination of performance is Contractor’s only remedy if H-GAC does not approve the price increase. H-GAC reserves the right to accept or reject any price change request.
