Common use of EXHIBITS TO THIS AGREEMENT Clause in Contracts

EXHIBITS TO THIS AGREEMENT. The documents below are attached to and fully incorporated into this Agreement as substantive parts of this Agreement. Exhibit A – Uniform General and Supplementary General Conditions for University of Texas System Building Construction Contracts (UGC) Exhibit B – Respondent’s Pricing and Delivery Proposal & Execution of Offer Exhibit C – Attachment “A” Minimum Wage Rate Determination Exhibit D – Rider 105; Contractor’s Affirmations and Warranties Exhibit E – Rider 106; Premises Rules Exhibit F – Rider 107; Travel Policy Exhibit G – Rider 116; Invoice Payment Requirements Exhibit H – Rider 104; Policy on Utilization Historically Underutilized Businesses Exhibit I – Approved HUB Subcontracting Plan Exhibit J - Rider 1 to the Agreement, Quality Assurance Exhibit K - Tax Exemption Certification Exhibit L - Rider 117; Compliance with Institutional Policies BY SIGNING BELOW, the Contractor has executed and bound itself to this Agreement as of the day and year first above written. The Agreement shall become effective only upon the execution of the Agreement by both parties. Change orders, additional services, amendments, modifications, deletions or other changes to the Agreement, if any, shall become effective upon the issuance of a signed Notice to Proceed by Owner to the Contractor. Subsequent to the issuance of a signed Notice to Proceed, Owner will issue a Purchase Order Revision reflecting the changes in scope, additional services, amendments, modifications, deletions or other changes to the Agreement. Contractor must receive the Purchase Order revision prior to Contractor submitting invoice for payment for the associated Agreement change. (SEAL) (Contractor’s Name) ATTEST: By: (original signature) By: (original signature) (name and title typed) (name and title typed) Date: CONTENT APPROVED: THE UNIVERSITY OF TEXAS M. D. XXXXXXXX CANCER CENTER (Owner) Office of Vice President Operations & Facilities Management By: (original signature) Name: Xxxxxxx X. Xxxxxxxx Title: V.P. Operations & Facilities Management Date: Office of the Associate Vice President Supply Chain Management By: (original signature) Name: Xxxx Xx. Xxxxx Title: Associate V.P. Supply Chain Management Date: Surety Bond No. STATE OF TEXAS § KNOW ALL MEN BY THESE PRESENTS: COUNTY OF § That we, , as Principal, and Texas as Obligee in the penal sum of ($ ) for payment whereof the said Principal and Surety bind themselves, their heirs, executors, administrators, and successors, jointly and severally, firmly by these presents. The conditions of this obligation are such that whereas the Principal entered into a certain contract, hereto attached, and made a part hereof, with the State of Texas, acting by and through the Board of Regents of The University of Texas System for and on behalf of , , dated , , for (Project No. ).

EXHIBITS TO THIS AGREEMENT. The documents below are attached to and fully incorporated into this Agreement as substantive parts of this Agreement. Exhibit A – Uniform General and Supplementary General Conditions for University of Texas System Building Construction Contracts (UGC) Rider 1 to the Agreement Exhibit B – Respondent’s Pricing and Delivery Proposal & Exhibit C – Execution of Offer Exhibit C – Attachment “A” Minimum Wage Rate Determination Exhibit D – Rider 105; Contractor’s Affirmations and Warranties Vendor Affirmation Exhibit E – Rider 106; Premises Rules Exhibit F – Rider 107; Travel Policy Exhibit G – Rider 116; Invoice Payment Requirements Payments Exhibit H – Rider 104; Policy on Utilization Historically Underutilized Businesses Exhibit I – Contractor’s Approved HUB Subcontracting Plan Exhibit J - Rider 1 to the Agreement, Quality Assurance 117; Institutional Policies Exhibit K - Tax Exemption Certification Exhibit L - Rider 117; Compliance with Institutional Policies – 2013 Uniform General Conditions for the University of Texas System Building Construction Contracts BY SIGNING BELOW, the Contractor has executed and bound itself to this Agreement as of the day and year first above written. The Agreement shall become effective only upon the execution of the Agreement by both parties. Change orders, additional services, amendments, modifications, deletions or other changes to the Agreement, if any, shall become effective upon the issuance of a signed Notice to Proceed by Owner to the Contractor. Subsequent to the issuance of a signed Notice to Proceed, Owner will issue a Purchase Order Revision reflecting the changes in scope, additional services, amendments, modifications, deletions or other changes to the Agreement. Contractor must receive the Purchase Order revision prior to Contractor submitting invoice for payment for the associated Agreement change. (SEAL) (ATTEST: [Contractor’s Name) ATTEST: ] By: (original signature) By: (original signature) (name and title typedtitle) (name and title typedtitle) Date: CONTENT APPROVED: THE UNIVERSITY OF TEXAS M. D. XXXXXXXX CANCER CENTER (Owner) Office of Vice President Operations & Facilities Management By: (original signature) Name: Xxxxxxx X. Xxxxxxxx Title: V.P. Operations & Facilities Management Date: Office of the Associate Vice President Supply Chain Management By: (original signature) Name: Xxxx Xx. Xxxxxxx Xxxxx Title: Associate V.P. Supply Chain Vice President for Operations and Facilities Management Date: Name: Title: Date: Surety Bond No. STATE OF TEXAS § KNOW ALL MEN BY THESE PRESENTS: COUNTY OF § That we, , as Principal, and Texas as Obligee in the penal sum of ($ ) for payment whereof the said Principal and Surety bind themselves, their heirs, executors, administrators, and successors, jointly and severally, firmly by these presents. The conditions of this obligation are such that whereas the Principal entered into a certain contract, hereto attached, and made a part hereof, with the State of Texas, acting by and through the Board of Regents of The University of Texas System for and on behalf of , , dated , , for (Project No. ).

EXHIBITS TO THIS AGREEMENT. The documents below are attached to and fully incorporated into this Agreement as substantive parts of this Agreement. Exhibit A – Uniform General and Supplementary General Conditions for University of Texas System Building Construction Contracts (UGC) Rider 1 to the Agreement Exhibit B – Respondent’s Pricing and Delivery Proposal & Exhibit C – Execution of Offer Exhibit C – Attachment “A” Minimum Wage Rate Determination Exhibit D – Rider 105; Contractor’s Affirmations and Warranties Vendor Affirmation Exhibit E – Rider 106; Premises Rules Exhibit F – Rider 107; Travel Policy Exhibit G – Rider 116; Invoice Payment Requirements Payments Exhibit H – Rider 104; Policy on Utilization Historically Underutilized Businesses Exhibit I – Approved HUB Subcontracting Plan Exhibit J - Rider 1 to the Agreement, Quality Assurance 117; Institutional Policies Exhibit K - Tax Exemption Certification Exhibit L - Rider 117; Compliance with Institutional Policies – 2010 Uniform General and Supplementary General Conditions for the University of Texas System Building Construction Contracts BY SIGNING BELOW, the Contractor has executed and bound itself to this Agreement as of the day and year first above written. The Agreement shall become effective only upon the execution of the Agreement by both parties. Change orders, additional services, amendments, modifications, deletions or other changes to the Agreement, if any, shall become effective upon the issuance of a signed Notice to Proceed by Owner to the Contractor. Subsequent to the issuance of a signed Notice to Proceed, Owner will issue a Purchase Order Revision reflecting the changes in scope, additional services, amendments, modifications, deletions or other changes to the Agreement. Contractor must receive the Purchase Order revision prior to Contractor submitting invoice for payment for the associated Agreement change. (SEAL) (ATTEST: [Contractor’s Name) ATTEST: ] By: (original signature) By: (original signature) (name and title typedtitle) (name and title typedtitle) Date: CONTENT APPROVED: THE UNIVERSITY OF TEXAS M. D. XXXXXXXX CANCER CENTER (Owner) Office of Vice President Operations & Facilities Management By: (original signature) Name: Xxxxxxx X. Xxxxxxxx Title: V.P. Operations & Facilities Management Date: Office of the Associate Vice President Supply Chain Management By: (original signature) Name: Xxxx Xx. Xxxxxxx Xxxxx Title: Associate V.P. Supply Chain Vice President for Operations and Facilities Management Date: Name: Title: Date: Surety Bond No. STATE OF TEXAS § KNOW ALL MEN BY THESE PRESENTS: COUNTY OF § That we, , as Principal, and Texas as Obligee in the penal sum of ($ ) for payment whereof the said Principal and Surety bind themselves, their heirs, executors, administrators, and successors, jointly and severally, firmly by these presents. The conditions of this obligation are such that whereas the Principal entered into a certain contract, hereto attached, and made a part hereof, with the State of Texas, acting by and through the Board of Regents of The University of Texas System for and on behalf of , , dated , , for (Project No. ).

EXHIBITS TO THIS AGREEMENT. The documents below are attached to and fully incorporated into this Agreement as substantive parts of this Agreement. Exhibit A – Uniform General and Supplementary General Conditions for University of Texas System Building Construction Contracts (UGC) Rider 1 to the Agreement Exhibit B – Respondent’s Pricing and Delivery Proposal & Exhibit C – Execution of Offer Exhibit C – Attachment “A” Minimum Wage Rate Determination Exhibit D – Rider 105; Contractor’s Affirmations and Warranties Vendor Affirmation Exhibit E – Rider 106; Premises Rules Exhibit F – Rider 107; Travel Policy Exhibit G – Rider 116; Invoice Payment Requirements Payments Exhibit H – Rider 104; Policy on Utilization Historically Underutilized Businesses Exhibit I – Approved HUB Subcontracting Plan Exhibit J - Rider 1 to the Agreement, Quality Assurance Exhibit K - Tax Exemption Certification Exhibit L - Rider 117; Compliance with Institutional Policies BY SIGNING BELOW, the Contractor has executed and bound itself to this Agreement as of the day and year first above written. The Agreement shall become effective only upon the execution of the Agreement by both parties. Change orders, additional services, amendments, modifications, deletions or other changes to the Agreement, if any, shall become effective upon the issuance of a signed Notice to Proceed by Owner to the Contractor. Subsequent to the issuance of a signed Notice to Proceed, Owner will issue a Purchase Order Revision reflecting the changes in scope, additional services, amendments, modifications, deletions or other changes to the Agreement. Contractor must receive the Purchase Order revision prior to Contractor submitting invoice for payment for the associated Agreement change. (SEAL) (ATTEST: [Contractor’s Name) ATTEST: ] By: (original signature) By: (original signature) (name and title typed) (name and title typed) Date: CONTENT APPROVED: THE UNIVERSITY OF TEXAS M. D. XXXXXXXX CANCER CENTER (Owner) Office of Vice President Operations & Facilities Management By: (original signature) By: (original signature) Name: Xxxxxxx X. Xxxxxxxx Title: V.P. Operations & Facilities Management Date: Office of the Associate Vice President Supply Chain Management By: (original signature) Name: Xxxx Xx. Xxxxx Title: Associate V.P. Supply Chain Management Date: Surety Bond No. STATE OF TEXAS § KNOW ALL MEN BY THESE PRESENTS: COUNTY OF § That we, , as Principal, and Texas as Obligee in the penal sum of ($ ) for payment whereof the said Principal and Surety bind themselves, their heirs, executors, administrators, and successors, jointly and severally, firmly by these presents. The conditions of this obligation are such that whereas the Principal entered into a certain contract, hereto attached, and made a part hereof, with the State of Texas, acting by and through the Board of Regents of The University of Texas System for and on behalf of , , dated , , for (Project No. ).and

EXHIBITS TO THIS AGREEMENT. The documents below are attached to and fully incorporated into this Agreement as substantive parts of this Agreement. Exhibit A – Uniform General and Supplementary General Conditions for University of Texas System Building Construction Contracts (UGC) Rider 1 to the Agreement Exhibit B – Respondent’s Pricing and Delivery Proposal & Exhibit C – Execution of Offer Exhibit C – Attachment “A” Minimum Wage Rate Determination Exhibit D – Rider 105; Contractor’s Affirmations and Warranties Vendor Affirmation Exhibit E – Rider 106; Premises Rules Exhibit F – Rider 107; Travel Policy Exhibit G – Rider 116; Invoice Payment Requirements Payments Exhibit H – Rider 104; Policy on Utilization Historically Underutilized Businesses Exhibit I – Approved HUB Subcontracting Plan Exhibit J - Rider 1 to the Agreement, Quality Assurance Exhibit K - Tax Exemption Certification Exhibit L - Rider 117; Compliance with Institutional Policies BY SIGNING BELOW, the Contractor has executed and bound itself to this Agreement as of the day and year first above written. The Agreement shall become effective only upon the execution of the Agreement by both partiesparties and the issuance of a Purchase Order by Owner to the Contractor. Change orders, additional services, amendments, modifications, deletions or other changes to the Agreement, if any, shall become effective only upon the issuance of a signed Notice to Proceed Purchase Order by Owner to the Contractor. Subsequent Only Supply Chain Services is authorized to the issuance of a signed Notice to Proceed, Owner will award official agreements and issue a Purchase Order Revision reflecting the changes in scope, additional services, amendments, modifications, deletions or other changes to the Agreement. Contractor must receive the Purchase Order revision prior to Contractor submitting invoice for payment for the associated Agreement changeOrders binding on Owner. (SEAL) (ATTEST: [Contractor’s Name) ATTEST: ] By: (original signature) By: (original signature) (name and title typed) (name and title typed) Date: CONTENT APPROVED: THE UNIVERSITY OF TEXAS M. D. XXXXXXXX CANCER CENTER (Owner) Office of Vice President Operations & Facilities Management By: (original signature) By: (original signature) Name: Xxxxxxx X. Xxxxxxxx Title: V.P. Operations & Facilities Management Date: Office of the Associate Vice President Supply Chain Management By: (original signature) Name: Xxxx Xx. Xxxxx Title: Associate V.P. Supply Chain Management Date: Surety Bond No. STATE OF TEXAS § KNOW ALL MEN BY THESE PRESENTS: COUNTY OF § That we, , as Principal, and Texas as Obligee in the penal sum of ($ ) for payment whereof the said Principal and Surety bind themselves, their heirs, executors, administrators, and successors, jointly and severally, firmly by these presents. The conditions of this obligation are such that whereas the Principal entered into a certain contract, hereto attached, and made a part hereof, with the State of Texas, acting by and through the Board of Regents of The University of Texas System for and on behalf of , , dated , , for (Project No. ).

EXHIBITS TO THIS AGREEMENT. The documents below are attached to and fully incorporated into this Agreement as substantive parts of this Agreement. Exhibit A – Uniform General and Supplementary General Conditions for University of Texas System Building Construction Contracts (UGC) Rider 1 to the Agreement Exhibit B – Respondent’s Pricing and Delivery Proposal & Exhibit C – Execution of Offer Exhibit C – Attachment “A” Minimum Wage Rate Determination Exhibit D – Rider 105; Contractor’s Affirmations and Warranties Vendor Affirmation Exhibit E – Rider 106; Premises Rules Exhibit F – Rider 107; Travel Policy Exhibit G – Rider 116; Invoice Payment Requirements Payments Exhibit H – Rider 104; Policy on Utilization Historically Underutilized Businesses Exhibit I – Approved HUB Subcontracting Plan Exhibit J - Rider 1 to the Agreement, Quality Assurance Exhibit K - Tax Exemption Certification Exhibit L - Rider 117; Compliance with Institutional Policies BY SIGNING BELOW, the Contractor has executed and bound itself to this Agreement as of the day and year first above written. The Agreement shall become effective only upon the execution of the Agreement by both parties. Change orders, additional services, amendments, modifications, deletions or other changes to the Agreement, if any, shall become effective upon the issuance of a signed Notice to Proceed by Owner to the Contractor. Subsequent to the issuance of a signed Notice to Proceed, Owner will issue a Purchase Order Revision reflecting the changes in scope, additional services, amendments, modifications, deletions or other changes to the Agreement. Contractor must receive the Purchase Order revision prior to Contractor submitting invoice for payment for the associated Agreement change. (SEAL) (ATTEST: [Contractor’s Name) ATTEST: ] By: (original signature) By: (original signature) (name and title typed) (name and title typed) Date: CONTENT APPROVED: THE UNIVERSITY OF TEXAS M. D. XXXXXXXX CANCER CENTER (Owner) Office of Vice President Operations & Facilities Management Vice President’s Office By: (original signature) By: (original signature) Name: Xxxxxxx X. Xxxxxxxx Xxxxx Title: V.P. Operations VP & Chief Facilities Management Officer Date: Office of the Associate Vice President Supply Chain Management By: (original signature) Name: Xxxx Xx. Xxxxx X. St. Amant Title: Associate V.P. VP, Supply Chain Management Date: Surety Bond No. STATE OF TEXAS § KNOW ALL MEN BY THESE PRESENTS: COUNTY OF § That we, , as Principal, and Texas as Obligee in the penal sum of ($ ) for payment whereof the said Principal and Surety bind themselves, their heirs, executors, administrators, and successors, jointly and severally, firmly by these presents. The conditions of this obligation are such that whereas the Principal entered into a certain contract, hereto attached, and made a part hereof, with the State of Texas, acting by and through the Board of Regents of The University of Texas System for and on behalf of , , dated , , for (Project No. ).and

EXHIBITS TO THIS AGREEMENT. The documents below are attached to and fully incorporated into this Agreement as substantive parts of this Agreement. Exhibit A – Uniform General and Supplementary General Conditions for University of Texas System Building Construction Contracts (UGC) Rider 1 to the Agreement Exhibit B – Respondent’s Pricing and Delivery Proposal & Exhibit C – Execution of Offer Exhibit C – Attachment “A” Minimum Wage Rate Determination Exhibit D – Rider 105; Contractor’s Affirmations and Warranties Vendor Affirmation Exhibit E – Rider 106; Premises Rules Exhibit F – Rider 107; Travel Policy Exhibit G – Rider 116; Invoice Payment Requirements Payments Exhibit H – Rider 104; Policy on Utilization Historically Underutilized Businesses Exhibit I – Approved HUB Subcontracting Plan Exhibit J - Rider 1 to the Agreement, Quality Assurance 117; Institutional Policies Exhibit K - Tax Exemption Certification Exhibit L - Rider 117; Compliance with Institutional Policies – 2010 Uniform General and Supplementary General Conditions for the University of Texas System Building Construction Contracts BY SIGNING BELOW, the Contractor has executed and bound itself to this Agreement as of the day and year first above written. The Agreement shall become effective only upon the execution of the Agreement by both parties. Change orders, additional services, amendments, modifications, deletions or other changes to the Agreement, if any, shall become effective upon the issuance of a signed Notice to Proceed by Owner to the Contractor. Subsequent to the issuance of a signed Notice to Proceed, Owner will issue a Purchase Order Revision reflecting the changes in scope, additional services, amendments, modifications, deletions or other changes to the Agreement. Contractor must receive the Purchase Order revision prior to Contractor submitting invoice for payment for the associated Agreement change. (SEAL) (ATTEST: [Contractor’s Name) ATTEST: ] By: (original signature) By: (original signature) (name and title typedtitle) (name and title typedtitle) Date: CONTENT APPROVED: THE UNIVERSITY OF TEXAS M. D. XXXXXXXX CANCER CENTER (Owner) Office of Vice President Operations & Facilities Management By: (original signature) Name: Xxxxxxx X. Xxxxxxxx Title: V.P. Operations & Facilities Management Date: Office of the Associate Vice President Supply Chain Management By: (original signature) Name: Xxxx Xx. Xxxxxxx Xxxxx Title: Associate V.P. Supply Chain Vice President for Operations and Facilities Management Date: Surety Bond No. STATE OF TEXAS § KNOW ALL MEN BY THESE PRESENTSName: Title: Date: COUNTY OF § That we, , as Principal, and Texas as Obligee in the penal sum of ($ ) for payment whereof the said Principal and Surety bind themselves, their heirs, executors, administrators, and successors, jointly and severally, firmly by these presents. The conditions of this obligation are such that whereas the Principal entered into a certain contract, hereto attached, and made a part hereof, with the State of Texas, acting by and through the Board of Regents of The University of Texas System for and on behalf of , , dated , , for (Project No. ).

EXHIBITS TO THIS AGREEMENT. The documents below are attached to and fully incorporated into this Agreement as substantive parts of this Agreement. Exhibit A – Uniform General and Supplementary General Conditions for University of Texas System Building Construction Contracts (UGC) Rider 1 to the Agreement Exhibit B – Respondent’s Pricing and Delivery Proposal & Exhibit C – Execution of Offer Exhibit C – Attachment “A” Minimum Wage Rate Determination Exhibit D – Rider 105; Contractor’s Affirmations and Warranties Vendor Affirmation Exhibit E – Rider 106; Premises Rules Exhibit F – Rider 107; Travel Policy Exhibit G – Rider 116; Invoice Payment Requirements Payments Exhibit H – Rider 104; Policy on Utilization Historically Underutilized Businesses Exhibit I – Approved HUB Subcontracting Plan Exhibit J - Rider 1 to the Agreement, Quality Assurance Exhibit K - Tax Exemption Certification Exhibit L - Rider 117; Compliance with Institutional Policies BY SIGNING BELOW, the Contractor has executed and bound itself to this Agreement as of the day and year first above written. The Agreement shall become effective only upon the execution of the Agreement by both parties. Change orders, additional services, amendments, modifications, deletions or other changes to the Agreement, if any, shall become effective upon the issuance of a signed Notice to Proceed by Owner to the Contractor. Subsequent to the issuance of a signed Notice to Proceed, Owner will issue a Purchase Order Revision reflecting the changes in scope, additional services, amendments, modifications, deletions or other changes to the Agreement. Contractor must receive the Purchase Order revision prior to Contractor submitting invoice for payment for the associated Agreement change. (SEAL) (ATTEST: [Contractor’s Name) ATTEST: ] By: (original signature) By: (original signature) (name and title typed) (name and title typed) Date: CONTENT APPROVED: THE UNIVERSITY OF TEXAS M. D. XXXXXXXX CANCER CENTER (Owner) Office of Vice President Operations & Facilities Management By: (original signature) By: (original signature) Name: Xxxxxxx X. Xxxxxxxx Title: V.P. Operations & Facilities Management Date: Office of the Associate Vice President Supply Chain Management By: (original signature) Name: Xxxx Xx. Xxxxx Title: Associate V.P. Supply Chain Management Date: Surety Bond No. STATE OF TEXAS § KNOW ALL MEN BY THESE PRESENTS: COUNTY OF § That we, , as Principal, and Texas as Obligee in the penal sum of ($ ) for payment whereof the said Principal and Surety bind themselves, their heirs, executors, administrators, and successors, jointly and severally, firmly by these presents. The conditions of this obligation are such that whereas the Principal entered into a certain contract, hereto attached, and made a part hereof, with the State of Texas, acting by and through the Board of Regents of The University of Texas System for and on behalf of , , dated , , for (Project No. ).and

EXHIBITS TO THIS AGREEMENT. The documents below are attached to and fully incorporated into this Agreement as substantive parts of this Agreement. Exhibit A – 2013 Uniform General and Supplementary General Conditions for University of Texas System Building Construction Contracts (UGC) Contracts, Rev. 06/14/2018 Exhibit B – RespondentOwner’s Pricing Division 00 (Conditions of the Contract) and Delivery Proposal & Execution of Offer Division 01 (General Requirements) Specifications Exhibit C – Attachment “A” Minimum Wage Rate Determination List of Drawings, Specifications Addenda, details and other documents developed by the Project Architect Engineer that describe the Project with the date they were issued. Exhibit D – Rider 104-C Policy on Utilization Historically Underutilized Businesses Exhibit E – Contractor’s Approved HUB Subcontracting Plan Exhibit F – Rider 105; Contractor’s Affirmations and Warranties Exhibit E G – Rider 106; Premises Rules Exhibit F H – Rider 107; Travel Policy Exhibit G I – Rider 116; Invoice Payment Requirements Exhibit H J – Rider 104; Policy on Utilization Historically Underutilized Businesses Exhibit I – Approved HUB Subcontracting Plan Exhibit J - Rider 1 to the Agreement, Quality Assurance Exhibit K - Tax Exemption Certification Exhibit L - Rider 117; Compliance with Institutional Policies BY SIGNING BELOW, Exhibit K – Respondent’s Pricing and Delivery Proposal and Execution of Offer Exhibit L – Performance and Payment Bonds Changes in the terms and conditions under which the Contractor has executed and bound itself must perform the Work to be completed under this Agreement as of the day and year first above written. The Agreement shall become effective only upon the execution of a written Amendment to this Agreement. Changes in the Agreement by both parties. Change ordersWork, additional servicesthe Contract Sum, amendments, modifications, deletions or other changes to the Agreement, if any, Contract Time shall become effective upon the issuance execution of a Change Order, signed by duly authorized representatives of the parties. Contractor shall be authorized to proceed with the change as of the Notice to Proceed by Owner to date set forth in the ContractorChange Order. Subsequent to the issuance of a signed Notice to ProceedChange Order, Owner MD Xxxxxxxx will issue a revised Purchase Order Revision reflecting the changes in scope, additional services, amendments, modifications, deletions or other changes to the AgreementContractor. Contractor must receive the revised Purchase Order revision prior to Contractor submitting invoice requesting compensation for payment Work to be completed under the Change Order in its Application for the associated Agreement changePayment. (SEAL) (ContractorOnly duly authorized representatives of MD Anderson’s Name) ATTEST: By: (original signature) By: (original signature) (name and title typed) (name and title typed) Date: CONTENT APPROVED: THE UNIVERSITY OF TEXAS M. D. XXXXXXXX CANCER CENTER (Owner) Office of Vice President Operations & Facilities Management By: (original signature) Name: Xxxxxxx X. Xxxxxxxx Title: V.P. Operations & Facilities Management Date: Office of the Associate Vice President Supply Chain Management By: (original signature) Name: Xxxx Xxdepartment are authorized to execute amendments to this Agreement and issue Purchase Orders to bind MD Xxxxxxxx for any payment to be made to Contractor pursuant to the terms of this Agreement. Xxxxx Title: Associate V.P. Supply Chain Management Date: Surety Bond No. STATE OF TEXAS § KNOW ALL MEN BY THESE PRESENTS: COUNTY OF § That we, , as PrincipalHaving agreed to the foregoing terms, and Texas as Obligee in the penal sum of ($ ) for payment whereof the said Principal and Surety bind themselves, their heirs, executors, administrators, and successors, jointly and severally, firmly by these presents. The conditions of this obligation are such that whereas the Principal entered into a certain contract, hereto attached, and made a part hereof, with the State intention of Texasbeing bound, acting the parties have caused this Agreement to be executed by and through their duly authorized representatives as of the Board of Regents of The University of Texas System for and on behalf of , , dated , , for (Project No. )Effective Date.

EXHIBITS TO THIS AGREEMENT. The documents below are attached to and fully incorporated into this Agreement as substantive parts of this Agreement. Exhibit A – Rider 1 to the Agreement Exhibit B – Contract Sum Breakdown Exhibit C – Respondent’s Pricing and Delivery Proposal Exhibit D – Execution of Offer Exhibit E – Rider 105; Vendor Affirmation Exhibit F – Rider 106; Premises Rules Exhibit G – Rider 107; Travel Policy Exhibit H – Rider 116; Invoice Payments Exhibit I – Policy on Utilization Historically Underutilized Businesses Exhibit J – Approved HUB Plan Exhibit K - Rider 117; Institutional Policies Exhibit L – 2010 Uniform General and Supplementary General Conditions for the University of Texas System Building Construction Contracts (UGC) Exhibit B – Respondent’s Pricing and Delivery Proposal & Execution of Offer Exhibit C – Attachment “A” Minimum Wage Rate Determination Exhibit D – Rider 105; Contractor’s Affirmations and Warranties Exhibit E – Rider 106; Premises Rules Exhibit F – Rider 107; Travel Policy Exhibit G – Rider 116; Invoice Payment Requirements Exhibit H – Rider 104; Policy on Utilization Historically Underutilized Businesses Exhibit I – Approved HUB Subcontracting Plan Exhibit J - Rider 1 to the Agreement, Quality Assurance Exhibit K - Tax Exemption Certification Exhibit L - Rider 117; Compliance with Institutional Policies BY SIGNING BELOW, the Contractor has executed and bound itself to this Agreement as of the day and year first above written. The Agreement shall become effective only upon the execution of the Agreement by both parties. Change orders, additional services, amendments, modifications, deletions or other changes to the Agreement, if any, shall become effective upon the issuance of a signed Notice to Proceed by Owner to the Contractor. Subsequent to the issuance of a signed Notice to Proceed, Owner will issue a Purchase Order Revision reflecting the changes in scope, additional services, amendments, modifications, deletions or other changes to the Agreement. Contractor must receive the Purchase Order revision prior to Contractor submitting invoice for payment for the associated Agreement change. (SEAL) (ATTEST: [Contractor’s Name) ATTEST: ] By: (original signature) By: (original signature) (name and title typedtitle) (name and title typedtitle) Date: CONTENT APPROVED: THE UNIVERSITY OF TEXAS M. D. XXXXXXXX CANCER CENTER (Owner) Office of Vice President Operations & Facilities Management By: (original signature) Name: Xxxxxxx X. Xxxxxxxx Title: V.P. Operations & Facilities Management Date: Office of the Associate Vice President Supply Chain Management By: (original signature) Name: Xxxx Xx. Xxxxxxx Xxxxx Title: Associate V.P. Supply Chain Vice President for Operations and Facilities Management Date: Surety Bond No. STATE OF TEXAS § KNOW ALL MEN BY THESE PRESENTSName: Title: Date: COUNTY OF § That we, , as Principal, and Texas as Obligee in the penal sum of ($ ) for payment whereof the said Principal and Surety bind themselves, their heirs, executors, administrators, and successors, jointly and severally, firmly by these presents. The conditions of this obligation are such that whereas the Principal entered into a certain contract, hereto attached, and made a part hereof, with the State of Texas, acting by and through the Board of Regents of The University of Texas System for and on behalf of , , dated , , for (Project No. ).

EXHIBITS TO THIS AGREEMENT. The documents below are attached to and fully incorporated into this Agreement as substantive parts of this Agreement. Exhibit A – Uniform General and Supplementary General Conditions for University of Texas System Building Construction Contracts (UGC) Rider 1 to the Agreement Exhibit B – Respondent’s Pricing and Delivery Proposal & Exhibit C – Execution of Offer Exhibit C – Attachment “A” Minimum Wage Rate Determination Exhibit D – Rider 105; Contractor’s Affirmations and Warranties Vendor Affirmation Exhibit E – Rider 106; Premises Rules Exhibit F – Rider 107; Travel Policy Exhibit G – Rider 116; Invoice Payment Requirements Payments Exhibit H – Rider 104; Policy on Utilization Historically Underutilized Businesses Exhibit I – Contractor’s Approved HUB Subcontracting Plan Exhibit J - Rider 1 to the Agreement, Quality Assurance 117; Institutional Policies Exhibit K - Tax Exemption Certification Exhibit L - Rider 117; Compliance with Institutional Policies – 2013 Uniform General Conditions for the University of Texas System Building Construction Contracts BY SIGNING BELOW, the Contractor has executed and bound itself to this Agreement as of the day and year first above written. The Agreement shall become effective only upon the execution of the Agreement by both parties. Change orders, additional services, amendments, modifications, deletions or other changes to the Agreement, if any, shall become effective upon the issuance of a signed Notice to Proceed by Owner to the Contractor. Subsequent to the issuance of a signed Notice to Proceed, Owner will issue a Purchase Order Revision reflecting the changes in scope, additional services, amendments, modifications, deletions or other changes to the Agreement. Contractor must receive the Purchase Order revision prior to Contractor submitting invoice for payment for the associated Agreement change. (SEAL) (ATTEST: [Contractor’s Name) ATTEST: ] By: (original signature) By: (original signature) (name and title typedtitle) (name and title typedtitle) Date: CONTENT APPROVED: THE UNIVERSITY OF TEXAS M. D. XXXXXXXX CANCER CENTER (Owner) Office of Vice President Operations & Facilities Management By: (original signature) Name: Xxxxxxx X. Xxxxxxxx Title: V.P. Operations & Facilities Management Date: Office of the Associate Vice President Supply Chain Management By: (original signature) Name: Xxxx Xx. Xxxxxxx Xxxxx Title: VP & Chief Facilities Officer Date: Name: Xxxx X. St. Amant Title: Associate V.P. VP, Supply Chain Management Date: Surety Bond No. STATE OF TEXAS § KNOW ALL MEN BY THESE PRESENTS: COUNTY OF § That we, , as Principal, and Texas as Obligee in the penal sum of ($ ) for payment whereof the said Principal and Surety bind themselves, their heirs, executors, administrators, and successors, jointly and severally, firmly by these presents. The conditions of this obligation are such that whereas the Principal entered into a certain contract, hereto attached, and made a part hereof, with the State of Texas, acting by and through the Board of Regents of The University of Texas System for and on behalf of , , dated , , for (Project No. ).

EXHIBITS TO THIS AGREEMENT. The documents below are attached to and fully incorporated into this Agreement as substantive parts of this Agreement. Exhibit A – Uniform General and Supplementary General Conditions for University of Texas System Building Construction Contracts (UGC) Rider 1 to the Agreement Exhibit B – Contract Sum Breakdown Exhibit C – Respondent’s Pricing and Delivery Proposal & Execution of Offer Exhibit C – Attachment “A” Minimum Wage Rate Determination Exhibit D – Rider 105; Contractor’s Affirmations and Warranties Exhibit E – Rider 106; Premises Rules Exhibit F – Rider 107; Travel Policy Exhibit G – Rider 116; Invoice Payment Requirements Exhibit H – Rider 104; Policy on Utilization Historically Underutilized Businesses Exhibit I – Approved HUB Subcontracting Plan Exhibit J - – Rider 1 to the Agreement, Quality Assurance 117; Institutional Policies Exhibit K - Tax Exemption Certification Attachment “A” Minimum Wage Rate Determination Exhibit L - Rider 117; Compliance with Institutional Policies – 2010 Uniform General and Supplementary General Conditions for the University of Texas System Building Construction Contracts BY SIGNING BELOW, the Contractor has executed and bound itself to this Agreement as of the day and year first above written. The Agreement shall become effective only upon the execution of the Agreement by both parties. Change orders, additional services, amendments, modifications, deletions or other changes to the Agreement, if any, shall become effective upon the issuance of a signed Notice to Proceed by Owner to the Contractor. Subsequent to the issuance of a signed Notice to Proceed, Owner will issue a Purchase Order Revision reflecting the changes in scope, additional services, amendments, modifications, deletions or other changes to the Agreement. Contractor must receive the Purchase Order revision prior to Contractor submitting invoice for payment for the associated Agreement change. (SEAL) ([Contractor’s Name) ] ATTEST: By: By: (original signature) By: (original signature) (name and title typedtitle) Date: (name and title typedtitle) Date: CONTENT APPROVED: THE UNIVERSITY OF TEXAS M. D. XXXXXXXX CANCER CENTER (Owner) Office of Vice President the VP & Chief Facilities Officer Operations & Facilities Management By: (original signature) Name: Xxxxxxx X. Xxxxxxxx Title: V.P. Operations & Facilities Management Date: Office of the Associate Vice President Supply Chain Management By: (original signature) Name: Xxxx Xx. Xxxxxxx Xxxxx Title: Vice President and Chief Facilities Officer Operations & Facilities Management Date: Name: Xxxx St. Amant Title: Associate V.P. Vice President Supply Chain Management Date: Surety Bond No. STATE OF TEXAS § KNOW ALL MEN BY THESE PRESENTS: COUNTY OF § That we, , as Principal, and Texas as Obligee in the penal sum of ($ ) for payment whereof the said Principal and Surety bind themselves, their heirs, executors, administrators, and successors, jointly and severally, firmly by these presents. The conditions of this obligation are such that whereas the Principal entered into a certain contract, hereto attached, and made a part hereof, with the State of Texas, acting by and through the Board of Regents of The University of Texas System for and on behalf of , , dated , , for (Project No. ).and

EXHIBITS TO THIS AGREEMENT. The documents below are attached to and fully incorporated into this Agreement as substantive parts of this Agreement. Exhibit A – Uniform General and Supplementary General Conditions for University of Texas System Building Construction Contracts (UGC) Rider 1 to the Agreement Exhibit B – Respondent’s Pricing and Delivery Proposal & Exhibit C – Execution of Offer Exhibit C – Attachment “A” Minimum Wage Rate Determination Exhibit D – Rider 105; Contractor’s Affirmations and Warranties Vendor Affirmation Exhibit E – Rider 106; Premises Rules Exhibit F – Rider 107; Travel Policy Exhibit G – Rider 116; Invoice Payment Requirements Payments Exhibit H – Rider 104; Policy on Utilization Historically Underutilized Businesses Exhibit I – Approved HUB Subcontracting Plan Exhibit J - Rider 1 to the Agreement, Quality Assurance Exhibit K - Tax Exemption Certification Exhibit L - Rider 117; Compliance with Institutional Policies BY SIGNING BELOW, the Contractor has executed and bound itself to this Agreement as of the day and year first above written. The Agreement shall become effective only upon the execution of the Agreement by both partiesparties and the issuance of a Purchase Order by Owner to the Contractor. Change orders, additional services, amendments, modifications, deletions or other changes to the Agreement, if any, shall become effective only upon the issuance of a signed Notice to Proceed Purchase Order by Owner to the Contractor. Subsequent Only Supply Chain Services is authorized to the issuance of a signed Notice to Proceed, Owner will award official agreements and issue a Purchase Order Revision reflecting the changes in scope, additional services, amendments, modifications, deletions or other changes to the Agreement. Contractor must receive the Purchase Order revision prior to Contractor submitting invoice for payment for the associated Agreement changeOrders binding on Owner. (SEAL) (Contractor’s Name) ATTEST: VENDOR NAME By: (original signature) By: (original signature) (name and title typed) (name and title typed) Date: CONTENT APPROVED: THE UNIVERSITY OF TEXAS M. D. MD XXXXXXXX CANCER CENTER (Owner) Office of Vice President Operations & Facilities Management By: (original signature) By: (original signature) Name: Xxxxxxx X. Xxxxxxxx Title: V.P. Operations & Facilities Management Date: Office of the Associate Vice President Supply Chain Management By: (original signature) Name: Xxxx Xx. Xxxxx ___________________ Title: Associate V.P. Supply Chain Management _________________ Date: Surety Bond No. ________________ STATE OF TEXAS § KNOW ALL MEN BY THESE PRESENTS: COUNTY OF __________________§ That we, _________________________________________________, as Principal, and __________________________________________________________________________________________________________ as Surety, are hereby held and firmly bound unto the State of Texas as Obligee in the penal sum of ___________________________________________________ ($ $_____________) for payment whereof the said Principal and Surety bind themselves, their heirs, executors, administrators, and successors, jointly and severally, firmly by these presents. The conditions of this obligation are such that whereas the Principal entered into a certain contract, hereto attached, and made a part hereof, with the State of Texas, acting by and through the Board of Regents of The University of Texas System for and on behalf of ________________________________________________________, _______________, dated ________________, _______, for __________________________________________________ (Project No. _______).

EXHIBITS TO THIS AGREEMENT. The documents below are attached to and fully incorporated into this Agreement as substantive parts of this Agreement. Exhibit A – Uniform General and Supplementary General Conditions for University of Texas System Building Construction Contracts (UGC) Rider 1 to the Agreement Exhibit B – Respondent’s Pricing and Delivery Proposal & Exhibit C – Execution of Offer Exhibit C – Attachment “A” Minimum Wage Rate Determination Exhibit D – Rider 105; Contractor’s Affirmations and Warranties Vendor Affirmation Exhibit E – Rider 106; Premises Rules Exhibit F – Rider 107; Travel Policy Exhibit G – Rider 116; Invoice Payment Requirements Payments Exhibit H – Rider 104; Policy on Utilization Historically Underutilized Businesses Exhibit I – Approved HUB Subcontracting Plan Exhibit J - Rider 1 to the Agreement, Quality Assurance 117; Institutional Policies Exhibit K - – Sales Tax Exemption Certification Exhibit L - Rider 117; Compliance with Institutional Policies Certificate BY SIGNING BELOW, the Contractor has executed and bound itself to this Agreement as of the day and year first above written. The Agreement shall become effective only upon the execution of the Agreement by both parties. Change orders, additional services, amendments, modifications, deletions or other changes to the Agreement, if any, shall become effective upon the issuance of a signed Notice to Proceed by Owner to the Contractor. Subsequent to the issuance of a signed Notice to Proceed, Owner will issue a Purchase Order Revision reflecting the changes in scope, additional services, amendments, modifications, deletions or other changes to the Agreement. Contractor must receive the Purchase Order revision prior to Contractor submitting invoice for payment for the associated Agreement change. (SEAL) (ATTEST: [Contractor’s Name) ATTEST: ] By: (original signature) By: (original signature) (name and title typed) (name and title typed) Date: CONTENT APPROVED: THE UNIVERSITY OF TEXAS M. D. XXXXXXXX CANCER CENTER (Owner) Office of Vice President Operations & Facilities Management By: (original signature) By: (original signature) Name: Xxxxxxx X. Xxxxxxxx Title: V.P. Operations & Facilities Management Date: Office of the Associate Vice President Supply Chain Management By: (original signature) Name: Xxxx Xx. Xxxxx Title: Associate V.P. Supply Chain Management Date: Surety Bond No. STATE OF TEXAS § KNOW ALL MEN BY THESE PRESENTS: COUNTY OF § That we, , as Principal, and Texas as Obligee in the penal sum of ($ ) for payment whereof the said Principal and Surety bind themselves, their heirs, executors, administrators, and successors, jointly and severally, firmly by these presents. The conditions of this obligation are such that whereas the Principal entered into a certain contract, hereto attached, and made a part hereof, with the State of Texas, acting by and through the Board of Regents of The University of Texas System for and on behalf of , , dated , , for (Project No. ).and

EXHIBITS TO THIS AGREEMENT. The documents below are attached to and fully incorporated into this Agreement as substantive parts of this Agreement. Exhibit A – Uniform General and Supplementary General Conditions for University of Texas System Building Construction Contracts (UGC) Rider 1 to the Agreement Exhibit B – Respondent’s Pricing and Delivery Proposal & Exhibit C – Execution of Offer Exhibit C – Attachment “A” Minimum Wage Rate Determination Exhibit D – Rider 105; Contractor’s Affirmations and Warranties Vendor Affirmation Exhibit E – Rider 106; Premises Rules Exhibit F – Rider 107; Travel Policy Exhibit G – Rider 116; Invoice Payment Requirements Payments Exhibit H – Rider 104; Policy on Utilization Historically Underutilized Businesses Exhibit I – Approved HUB Subcontracting Plan Exhibit J - Rider 1 to the Agreement, Quality Assurance Exhibit K - Tax Exemption Certification Exhibit L - Rider 117; Compliance with Institutional Policies BY SIGNING BELOW, the Contractor has executed and bound itself to this Agreement as of the day and year first above written. The Agreement shall become effective only upon the execution of the Agreement by both partiesparties and the issuance of a Purchase Order by Owner to the Contractor. Change orders, additional services, amendments, modifications, deletions or other changes to the Agreement, if any, shall become effective only upon the issuance of a signed Notice to Proceed Purchase Order by Owner to the Contractor. Subsequent Only Supply Chain Services is authorized to the issuance of a signed Notice to Proceed, Owner will award official agreements and issue a Purchase Order Revision reflecting the changes in scope, additional services, amendments, modifications, deletions or other changes to the Agreement. Contractor must receive the Purchase Order revision prior to Contractor submitting invoice for payment for the associated Agreement changeOrders binding on Owner. (SEAL) ([Contractor’s Name) ] ATTEST: By: (original signature) By: (original signature) (name and title typed) (name and title typed) Date: CONTENT APPROVED: THE UNIVERSITY OF TEXAS M. D. XXXXXXXX CANCER CENTER (Owner) Office of Vice President Operations & Facilities Management By: (original signature) Name: Xxxxxxx X. Xxxxxxxx Title: V.P. Operations & Facilities Management Date: Office of the Associate Vice President Supply Chain Management By: (original signature) Name: Xxxx Xx. Xxxxx Title: Associate V.P. Supply Chain Management Date: Surety Bond No. STATE OF TEXAS § KNOW ALL MEN BY THESE PRESENTS: COUNTY OF § That we, , as Principal, and Texas as Obligee in the penal sum of ($ ) for payment whereof the said Principal and Surety bind themselves, their heirs, executors, administrators, and successors, jointly and severally, firmly by these presents. The conditions of this obligation are such that whereas the Principal entered into a certain contract, hereto attached, and made a part hereof, with the State of Texas, acting by and through the Board of Regents of The University of Texas System for and on behalf of , , dated , , for (Project No. ).

EXHIBITS TO THIS AGREEMENT. The documents below are attached to and fully incorporated into this Agreement as substantive parts of this Agreement. Exhibit A – Rider 1 to the Agreement Exhibit B – Contract Sum Breakdown Exhibit C – Respondent’s Pricing and Delivery Proposal Exhibit D – Execution of Offer Exhibit E – Rider 105; Vendor Affirmation Exhibit F – Rider 106; Premises Rules Exhibit G – Rider 107; Travel Policy Exhibit H – Rider 116; Invoice Payments Exhibit I – Policy on Utilization Historically Underutilized Businesses Exhibit J – Approved HUB Plan Exhibit K - Rider 117; Institutional Policies Exhibit L – 2010 Uniform General and Supplementary General Conditions for the University of Texas System Building Construction Contracts (UGC) Exhibit B – Respondent’s Pricing and Delivery Proposal & Execution of Offer Exhibit C – Attachment “A” Minimum Wage Rate Determination Exhibit D – Rider 105; Contractor’s Affirmations and Warranties Exhibit E – Rider 106; Premises Rules Exhibit F – Rider 107; Travel Policy Exhibit G – Rider 116; Invoice Payment Requirements Exhibit H – Rider 104; Policy on Utilization Historically Underutilized Businesses Exhibit I – Approved HUB Subcontracting Plan Exhibit J - Rider 1 to the Agreement, Quality Assurance Exhibit K - Tax Exemption Certification Exhibit L - Rider 117; Compliance with Institutional Policies BY SIGNING BELOW, the Contractor has executed and bound itself to this Agreement as of the day and year first above written. The Agreement shall become effective only upon the execution of the Agreement by both parties. Change orders, additional services, amendments, modifications, deletions or other changes to the Agreement, if any, shall become effective upon the issuance of a signed Notice to Proceed by Owner to the Contractor. Subsequent to the issuance of a signed Notice to Proceed, Owner will issue a Purchase Order Revision reflecting the changes in scope, additional services, amendments, modifications, deletions or other changes to the Agreement. Contractor must receive the Purchase Order revision prior to Contractor submitting invoice for payment for the associated Agreement change. (SEAL) (ATTEST: [Contractor’s Name) ATTEST: ] By: (original signature) By: (original signature) (name and title typedtitle) (name and title typedtitle) Date: CONTENT APPROVED: THE UNIVERSITY OF TEXAS M. D. XXXXXXXX CANCER CENTER (Owner) Office of Vice President Operations & Facilities Management By: (original signature) Name: Xxxxxxx X. Xxxxxxxx Title: V.P. Operations & Facilities Management Date: Office of the Associate Vice President Supply Chain Management By: (original signature) Name: Xxxx Xx. Xxxxxxx Xxxxx Title: Associate V.P. Supply Chain Vice President for Operations and Facilities Management Date: Name: Title: Date: Surety Bond No. STATE OF TEXAS § KNOW ALL MEN BY THESE PRESENTS: COUNTY OF § That we, , as Principal, and Texas as Obligee in the penal sum of ($ ) for payment whereof the said Principal and Surety bind themselves, their heirs, executors, administrators, and successors, jointly and severally, firmly by these presents. The conditions of this obligation are such that whereas the Principal entered into a certain contract, hereto attached, and made a part hereof, with the State of Texas, acting by and through the Board of Regents of The University of Texas System for and on behalf of , , dated , , for (Project No. ).

EXHIBITS TO THIS AGREEMENT. The documents below are attached to and fully incorporated into this Agreement as substantive parts of this Agreement. Exhibit A – Uniform General and Supplementary General Conditions for University of Texas System Building Construction Contracts (UGC) Rider 1 to the Agreement Exhibit B – Respondent’s Pricing and Delivery Proposal & Exhibit C – Execution of Offer Exhibit C – Attachment “A” Minimum Wage Rate Determination Exhibit D – Rider 105; Contractor’s Affirmations and Warranties Vendor Affirmation Exhibit E – Rider 106; Premises Rules Exhibit F – Rider 107; Travel Policy Exhibit G – Rider 116; Invoice Payment Requirements Payments Exhibit H – Rider 104; Policy on Utilization Historically Underutilized Businesses Exhibit I – Approved HUB Subcontracting Plan Exhibit J - Rider 1 to the Agreement, Quality Assurance Exhibit K - Tax Exemption Certification Exhibit L - Rider 117; Compliance with Institutional Policies BY SIGNING BELOW, the Contractor has executed and bound itself to this Agreement as of the day and year first above written. The Agreement shall become effective only upon the execution of the Agreement by both parties. Change orders, additional services, amendments, modifications, deletions or other changes to the Agreement, if any, shall become effective upon the issuance of a signed Notice to Proceed by Owner to the Contractor. Subsequent to the issuance of a signed Notice to Proceed, Owner will issue a Purchase Order Revision reflecting the changes in scope, additional services, amendments, modifications, deletions or other changes to the Agreement. Contractor must receive the Purchase Order revision prior to Contractor submitting invoice for payment for the associated Agreement change. (SEAL) (ATTEST: [Contractor’s Name) ATTEST: ] By: (original signature) By: (original signature) (name and title typed) (name and title typed) Date: CONTENT APPROVED: THE UNIVERSITY OF TEXAS M. D. XXXXXXXX CANCER CENTER (Owner) Office of Vice President Operations & Facilities Management By: (original signature) By: (original signature) Name: Xxxxxxx X. Xxxxxxxx Title: V.P. Operations & Facilities Management Date: Office of the Associate Vice President Supply Chain Management By: (original signature) Name: Xxxx Xx. Xxxxx ___________________ Title: Associate V.P. Supply Chain Management _________________ Date: Surety Bond No. ________________ STATE OF TEXAS § KNOW ALL MEN BY THESE PRESENTS: COUNTY OF __________________§ That we, _________________________________________________, as Principal, and __________________________________________________________________________________________________________ as Surety, are hereby held and firmly bound unto the State of Texas as Obligee in the penal sum of ___________________________________________________ ($ $_____________) for payment whereof the said Principal and Surety bind themselves, their heirs, executors, administrators, and successors, jointly and severally, firmly by these presents. The conditions of this obligation are such that whereas the Principal entered into a certain contract, hereto attached, and made a part hereof, with the State of Texas, acting by and through the Board of Regents of The University of Texas System for and on behalf of ________________________________________________________, _______________, dated ________________, _______, for __________________________________________________ (Project No. _______).

EXHIBITS TO THIS AGREEMENT. The documents below are attached to and fully incorporated into this Agreement as substantive parts of this Agreement. Exhibit A – 2013 Uniform General and Supplementary General Conditions for University of Texas System Building Construction Contracts (UGC) Contracts, Rev. 06/14/2018 Exhibit B – RespondentOwner’s Pricing Division 00 (Conditions of the Contract) and Delivery Proposal & Execution of Offer Division 01 (General Requirements) Specifications Exhibit C – Attachment “A” Minimum Wage Rate Determination List of Drawings, Specifications Addenda, details and other documents developed by the Project Architect Engineer that describe the Project with the date they were issued. Exhibit D – Rider 104-C Policy on Utilization Historically Underutilized Businesses Exhibit E – Contractor’s Approved HUB Subcontracting Plan Exhibit F – Rider 105; Contractor’s Affirmations and Warranties Exhibit E G – Rider 106; Premises Rules Exhibit F H – Rider 107; Travel Policy Exhibit G I – Rider 116; Invoice Payment Requirements Exhibit H J – Rider 104; Policy on Utilization Historically Underutilized Businesses Exhibit I – Approved HUB Subcontracting Plan Exhibit J - Rider 1 to the Agreement, Quality Assurance Exhibit K - Tax Exemption Certification Exhibit L - Rider 117; Compliance with Institutional Policies BY SIGNING BELOW, Exhibit K – Respondent’s Pricing and Delivery Proposal and Execution of Offer Exhibit L – Performance and Payment Bonds Changes in the terms and conditions under which the Contractor has executed and bound itself must perform the Work to be completed under this Agreement as of the day and year first above written. The Agreement shall become effective only upon the execution of a written Amendment to this Agreement. Changes in the Agreement by both parties. Change ordersWork, additional servicesthe Contract Sum, amendments, modifications, deletions or other changes to the Agreement, if any, Contract Time shall become effective upon the issuance execution of a Change Order, signed by duly authorized representatives of the parties. Contractor shall be authorized to proceed with the change as of the Notice to Proceed by Owner to date set forth in the ContractorChange Order. Subsequent to the issuance of a signed Notice to ProceedChange Order, Owner MD Xxxxxxxx will issue a revised Purchase Order Revision reflecting the changes in scope, additional services, amendments, modifications, deletions or other changes to the AgreementContractor. Contractor must receive the revised Purchase Order revision prior to requesting compensation for Work to be completed under the Change Order in its Application for Payment. Only duly authorized representatives of MD Anderson’s Supply Chain Management department are authorized to execute amendments to this Agreement and issue Purchase Orders to bind MD Xxxxxxxx for any payment to be made to Contractor submitting invoice for payment for pursuant to the associated terms of this Agreement. Having agreed to the foregoing terms, and with the intention of being bound, the parties have caused this Agreement changeto be executed by their duly authorized representatives as of the Effective Date. (SEAL) ([Contractor’s Name) ATTEST: ] By: (original signature) ByName: (original signature) (name and title typed) (name and title typed) Title: Date: CONTENT APPROVED: THE UNIVERSITY OF TEXAS M. D. XXXXXXXX CANCER CENTER (Owner) Office of Vice President Operations & Facilities Management By: (original signature) Sourcing and Contract Management By: (signature) Name: Xxxxxxx X. Xxxxxxxx Xxxxx Title: V.P. Operations & Vice President and Chief Facilities Officer Date: Name: Xxxx Xxxxxx Title: Director, Sourcing and Contract Management Date: Office of the Associate Vice President Supply Chain Management By: (original signature) Name: Xxxx Xx. Xxxxx Title: Associate V.P. Supply Chain Management Date: Surety Bond No. STATE OF TEXAS § KNOW ALL MEN BY THESE PRESENTS: COUNTY OF § That we, , as Principal, and Texas as Obligee in the penal sum of ($ ) for payment whereof the said Principal and Surety bind themselves, their heirs, executors, administrators, and successors, jointly and severally, firmly by these presents. The conditions of this obligation are such that whereas the Principal entered into a certain contract, hereto attached, and made a part hereof, with the State of Texas, acting by and through the Board of Regents of The University of Texas System for and on behalf of , , dated , , for (MD Xxxxxxxx Project No. ).UNIFORM GENERAL CONDITIONS FOR UNIVERSITY OF TEXAS SYSTEM BUILDING CONSTRUCTION CONTRACTS Article 1. Definitions

EXHIBITS TO THIS AGREEMENT. The documents below are attached to and fully incorporated into this Agreement as substantive parts of this Agreement. Exhibit A – Uniform General and Supplementary General Conditions for University of Texas System Building Construction Contracts (UGC) Rider 1 to the Agreement Exhibit B – Respondent’s Pricing and Delivery Proposal & Exhibit C – Execution of Offer Exhibit C – Attachment “A” Minimum Wage Rate Determination Exhibit D – Rider 105; Contractor’s Affirmations Affirmation and Warranties Exhibit E – Rider 106; Premises Rules Exhibit F – Rider 107; Travel Policy Exhibit G – Rider 116; Invoice Payment Requirements Exhibit H – Rider 104; Policy on Utilization Historically Underutilized Businesses Exhibit I – Contractor’s Approved HUB Subcontracting Plan Exhibit J - Rider 1 to the Agreement, Quality Assurance 117; Institutional Policies Exhibit K - Tax Exemption Certification Attachment “A” Minimum Wage Rate Determination Exhibit L - Rider 117; Compliance with Institutional Policies 2013 Uniform General Conditions for University of Texas System Building Construction Contracts BY SIGNING BELOW, the Contractor has executed and bound itself to this Agreement as of the day and year first above written. The Agreement shall become effective only upon the execution of the Agreement by both parties. Change orders, additional services, amendments, modifications, deletions or other changes to the Agreement, if any, shall become effective upon the issuance of a signed Notice to Proceed by Owner to the Contractor. Subsequent to the issuance of a signed Notice to Proceed, Owner will issue a Purchase Order Revision reflecting the changes in scope, additional services, amendments, modifications, deletions or other changes to the Agreement. Contractor must receive the Purchase Order revision prior to Contractor submitting invoice for payment for the associated Agreement change. (SEAL) ATTEST: (Contractor’s Name) ATTEST: By: (original signature) By: (original signature) (name and title typed) (name and title typed) Date: CONTENT APPROVED: THE UNIVERSITY OF TEXAS M. D. X. X. XXXXXXXX CANCER CENTER (Owner) Office of Vice President the VP & Chief Facilities Office Operations & Facilities Management By: (original signature) Name: Xxxxxxx X. Xxxxxxxx Title: V.P. Operations & Facilities Management Date: Office of the Associate Vice President Supply Chain Management By: (original signature) Name: Xxxxxxx Xxxxx Title: Vice President and Chief Facilities Officer Operations and Facilities Management Date: Name: Xxxx Xx. Xxxxx Amant Title: Associate V.P. Vice President Supply Chain Management Date: Surety Bond No. STATE OF TEXAS § KNOW ALL MEN BY THESE PRESENTS: COUNTY OF § That we, , as Principal, and Texas as Obligee in the penal sum of ($ ) for payment whereof the said Principal and Surety bind themselves, their heirs, executors, administrators, and successors, jointly and severally, firmly by these presents. The conditions of this obligation are such that whereas the Principal entered into a certain contract, hereto attached, and made a part hereof, with the State of Texas, acting by and through the Board of Regents of The University of Texas System for and on behalf of , , dated , , for (Project No. ).

EXHIBITS TO THIS AGREEMENT. The documents below are attached to and fully incorporated into this Agreement as substantive parts of this Agreement. Exhibit A – Uniform General and Supplementary General Conditions for University of Texas System Building Construction Contracts (UGC) Rider 1 to the Agreement Exhibit B – Respondent’s Pricing and Delivery Proposal & Exhibit C – Execution of Offer Exhibit C – Attachment “A” Minimum Wage Rate Determination Exhibit D – Rider 105; Contractor’s Affirmations and Warranties Vendor Affirmation Exhibit E – Rider 106; Premises Rules Exhibit F – Rider 107; Travel Policy Exhibit G – Rider 116; Invoice Payment Requirements Payments Exhibit H – Rider 104; Policy on Utilization Historically Underutilized Businesses Exhibit I – Contractor’s Approved HUB Subcontracting Plan Exhibit J - Rider 1 to the Agreement, Quality Assurance Exhibit K - Tax Exemption Certification Exhibit L - – Rider 117; Compliance with Institutional Policies Exhibit K – Attachment “A” Minimum Wage Rate Determination Exhibit L – 2013 Uniform General Conditions for University of Texas System Building Construction Contracts BY SIGNING BELOW, the Contractor has executed and bound itself to this Agreement as of the day and year first above written. The Agreement shall become effective only upon the execution of the Agreement by both parties. Change orders, additional services, amendments, modifications, deletions or other changes to the Agreement, if any, shall become effective upon the issuance of a signed Notice to Proceed by Owner to the Contractor. Subsequent to the issuance of a signed Notice to Proceed, Owner will issue a Purchase Order Revision reflecting the changes in scope, additional services, amendments, modifications, deletions or other changes to the Agreement. Contractor must receive the Purchase Order revision prior to Contractor submitting invoice for payment for the associated Agreement change. (SEAL) ([Contractor’s Name) ] ATTEST: By: By: (original signature) By: (original signature) (name and title typedtitle) Date: (name and title typedtitle) Date: CONTENT APPROVED: THE UNIVERSITY OF TEXAS M. D. XXXXXXXX CANCER CENTER (Owner) Office of Vice President & Chief Facilities Officer Operations & Facilities Management By: (original signature) Name: Xxxxxxx X. Xxxxxxxx Title: V.P. Operations & Facilities Management Date: Office of the Associate Vice President Supply Chain Management By: (original signature) Name: Xxxx Xx. Xxxxxxx Xxxxx Title: Associate V.P. Supply Chain Vice President & Chief Facilities Officer Operations and Facilities Management Date: Name: Title: Date: Surety Bond No. STATE OF TEXAS § KNOW ALL MEN BY THESE PRESENTS: COUNTY OF § That we, , as Principal, and Texas as Obligee in the penal sum of ($ ) for payment whereof the said Principal and Surety bind themselves, their heirs, executors, administrators, and successors, jointly and severally, firmly by these presents. The conditions of this obligation are such that whereas the Principal entered into a certain contract, hereto attached, and made a part hereof, with the State of Texas, acting by and through the Board of Regents of The University of Texas System for and on behalf of , , dated , , for (Project No. ).and

EXHIBITS TO THIS AGREEMENT. The documents below are attached to and fully incorporated into this Agreement as substantive parts of this Agreement. Exhibit A – 2013 Uniform General and Supplementary General Conditions for University of Texas System Building Construction Contracts (UGC) Contracts, Rev. 06/14/2018 Exhibit B – RespondentOwner’s Pricing Division 00 (Conditions of the Contract) and Delivery Proposal & Execution of Offer Division 01 (General Requirements) Specifications Exhibit C – Attachment “A” Minimum Wage Rate Determination List of Drawings, Specifications Addenda, details and other documents developed by the Project Architect Engineer that describe the Project with the date they were issued. Exhibit D – Rider 104-C Policy on Utilization Historically Underutilized Businesses Exhibit E – Contractor’s Approved HUB Subcontracting Plan Exhibit F – Rider 105; Contractor’s Affirmations and Warranties Exhibit E G – Rider 106; Premises Rules Exhibit F H – Rider 107; Travel Policy Exhibit G I – Rider 116; Invoice Payment Requirements Exhibit H J – Rider 104; Policy on Utilization Historically Underutilized Businesses Exhibit I – Approved HUB Subcontracting Plan Exhibit J - Rider 1 to the Agreement, Quality Assurance Exhibit K - Tax Exemption Certification Exhibit L - Rider 117; Compliance with Institutional Policies BY SIGNING BELOW, Exhibit K – Respondent’s Pricing and Delivery Proposal and Execution of Offer Exhibit L – Performance and Payment Bonds Changes in the terms and conditions under which the Contractor has executed and bound itself must perform the Work to be completed under this Agreement as of the day and year first above written. The Agreement shall become effective only upon the execution of a written Amendment to this Agreement. Changes in the Agreement by both parties. Change ordersWork, additional servicesthe Contract Sum, amendments, modifications, deletions or other changes to the Agreement, if any, Contract Time shall become effective upon the issuance execution of a Change Order, signed by duly authorized representatives of the parties. Contractor shall be authorized to proceed with the change as of the Notice to Proceed by Owner to date set forth in the ContractorChange Order. Subsequent to the issuance of a signed Notice to ProceedChange Order, Owner MD Xxxxxxxx will issue a revised Purchase Order Revision reflecting the changes in scope, additional services, amendments, modifications, deletions or other changes to the AgreementContractor. Contractor must receive the revised Purchase Order revision prior to requesting compensation for Work to be completed under the Change Order in its Application for Payment. Only duly authorized representatives of MD Anderson’s Supply Chain Management department are authorized to execute amendments to this Agreement and issue Purchase Orders to bind MD Xxxxxxxx for any payment to be made to Contractor submitting invoice for payment for pursuant to the associated terms of this Agreement. Having agreed to the foregoing terms, and with the intention of being bound, the parties have caused this Agreement changeto be executed by their duly authorized representatives as of the Effective Date. (SEAL) ([Contractor’s Name) ATTEST: ] By: (original signature) By: (original signature) (name and title typed) (name and title typedtitle) Date: CONTENT APPROVED: THE UNIVERSITY OF TEXAS M. D. XXXXXXXX CANCER CENTER (Owner) Office of Vice President Operations & Facilities Management By: (original signature) By: Name: Xxxxxxx X. Xxxxxxxx Title: V.P. Operations & Facilities Management Date: Office of the Associate Vice President Supply Chain Management By: (original signature) Name: Xxxx Xx. Xxxxx Title: Associate V.P. Supply Chain Management Vice President and Chief Facilities Officer Date: Surety Bond No. STATE Name: Title: Date: UNIFORM GENERAL CONDITIONS FOR UNIVERSITY OF TEXAS § KNOW ALL MEN BY THESE PRESENTS: COUNTY OF § That we, , as Principal, and Texas as Obligee in the penal sum of ($ ) for payment whereof the said Principal and Surety bind themselves, their heirs, executors, administrators, and successors, jointly and severally, firmly by these presentsSYSTEM BUILDING CONSTRUCTION CONTRACTS Article 1. The conditions of this obligation are such that whereas the Principal entered into a certain contract, hereto attached, and made a part hereof, with the State of Texas, acting by and through the Board of Regents of The University of Texas System for and on behalf of , , dated , , for (Project No. ).Definitions