Delivery Delay The delivery of any certificate representing the Restricted Stock or other RS Property may be postponed by the Company for such period as may be required for it to comply with any applicable foreign, federal, state or provincial securities law, or any national securities exchange listing requirements and the Company is not obligated to issue or deliver any securities if, in the opinion of counsel for the Company, the issuance of such Shares shall constitute a violation by the Participant or the Company of any provisions of any applicable foreign, federal, state or provincial law or of any regulations of any governmental authority or any national securities exchange.
Additional Disruption Events Change in Law: Applicable; provided that Section 12.9(a)(ii) of the Equity Definitions is hereby amended by adding the words “(including, for the avoidance of doubt and without limitation, adoption or promulgation of new regulations authorized or mandated by existing statute)” after the word “regulation” in the second line thereof.
Excusable Delay The parties shall not be obligated to perform and shall not be deemed to be in default hereunder, if the performance of a non-monetary obligation required hereunder is prevented by the occurrence of any of the following, other than as the result of the financial inability of the party obligated to perform: acts of God, strikes, lock-outs, other industrial disturbances, acts of a public enemy, war or war-like action (whether actual, impending or expected and whether de jure or de facto), acts of terrorists, arrest or other restraint of government (civil or military), blockades, insurrections, riots, epidemics, landslides, lightning, earthquakes, fires, hurricanes, storms, floods, washouts, sink holes, civil disturbances, explosions, breakage or accident to equipment or machinery, confiscation or seizure by any government or public authority, nuclear reaction or radiation, radioactive contamination or other causes, whether of the kind herein enumerated or otherwise, that are not reasonably within the control of the party claiming the right to delay performance on account of such occurrence.
Excusable Delays Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.
Default under Specified Transaction The party, any Credit Support Provider of such party or any applicable Specified Entity of such party (1) defaults under a Specified Transaction and, after giving effect to any applicable notice requirement or grace period, there occurs a liquidation of, an acceleration of obligations under, or an early termination of, that Specified Transaction, (2) defaults, after giving effect to any applicable notice requirement or grace period, in making any payment or delivery due on the last payment, delivery or exchange date of, or any payment on early termination of, a Specified Transaction (or such default continues for at least three Local Business Days if there is no applicable notice requirement or grace period) or (3) disaffirms, disclaims, repudiates or rejects, in whole or in part, a Specified Transaction (or such action is taken by any person or entity appointed or empowered to operate it or act on its behalf);
Payment in the Event Losses Fail to Reach Expected Level On the date that is 45 days following the last day (such day, the “True-Up Measurement Date”) of the calendar month in which the tenth anniversary of the calendar day following the Bank Closing occurs, the Assuming Bank shall pay to the Receiver fifty percent (50%) of the excess, if any, of
(i) twenty percent (20%) of the Stated Threshold less (ii) the sum of (A) twenty-five percent (25%) of the asset premium (discount) plus (B) twenty-five percent (25%) of the Cumulative Shared-Loss Payments plus (C) the Cumulative Servicing Amount. The Assuming Bank shall deliver to the Receiver not later than 30 days following the True-Up Measurement Date, a schedule, signed by an officer of the Assuming Bank, setting forth in reasonable detail the calculation of the Cumulative Shared-Loss Payments and the Cumulative Servicing Amount.
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.
Effectiveness and Events Requiring Notice to the Underwriters The Company will use its best efforts to cause the Registration Statement to remain effective with a current prospectus until the later of nine (9) months from the Execution Date and the date on which the Warrants are no longer outstanding, and will notify the Underwriters and holders of the Warrants immediately and confirm the notice in writing: (i) of the effectiveness of the Registration Statement and any amendment thereto; (ii) of the issuance by the Commission of any stop order or of the initiation, or the threatening, of any proceeding for that purpose; (iii) of the issuance by any state securities commission of any proceedings for the suspension of the qualification of the Securities for offering or sale in any jurisdiction or of the initiation, or the threatening, of any proceeding for that purpose; (iv) of the mailing and delivery to the Commission for filing of any amendment or supplement to the Registration Statement or Prospectus; (v) of the receipt of any comments or request for any additional information from the Commission; and (vi) of the happening of any event during the period described in this Section 4.4 that, in the judgment of the Company, makes any statement of a material fact made in the Registration Statement or the Prospectus untrue or that requires the making of any changes in the Registration Statement or the Prospectus in order to make the statements therein, in light of the circumstances under which they were made, not misleading. If the Commission or any state securities commission shall enter a stop order or suspend such qualification at any time, the Company will make every reasonable effort to obtain promptly the lifting of such order.
Epidemic Failure Warranty Supplier warrants all Products against Epidemic Failure for a period of three years after DXC’s Acceptance. Epidemic Failure means the occurrence of the same failure, defect, or non-conformity with an Order in 2% or more of Products within any three-month period.
