Expiration of Termination Right. Notwithstanding the foregoing, Customer’s right to terminate this Agreement pursuant to Articles 26.1 through 26.3 shall expire upon Final Acceptance of the last Deliverable Item.
Expiration of Termination Right Sample Clauses
Related to Expiration of Termination Right
Expiration of Term During the Initial Term or Renewal Term, whichever currently is in effect, should either party exercise its right to terminate, all out-of-pocket expenses or costs associated with the movement of records and material will be borne by the Fund. Additionally, the Transfer Agent reserves the right to charge for any other reasonable expenses associated with such termination.
Termination Right The Representative shall have the right to terminate this Agreement at any time prior to any Closing Date, (i) if any domestic or international event or act or occurrence has materially disrupted, or in its opinion will in the immediate future materially disrupt, general securities markets in the United States; or (ii) if trading on any Trading Market shall have been suspended or materially limited, or minimum or maximum prices for trading shall have been fixed, or maximum ranges for prices for securities shall have been required by FINRA or by order of the Commission or any other government authority having jurisdiction, or (iii) if the United States shall have become involved in a new war or an increase in major hostilities, or (iv) if a banking moratorium has been declared by a New York State or federal authority, or (v) if a moratorium on foreign exchange trading has been declared which materially adversely impacts the United States securities markets, or (vi) if the Company shall have sustained a material loss by fire, flood, accident, hurricane, earthquake, theft, sabotage or other calamity or malicious act which, whether or not such loss shall have been insured, will, in the Representative’s opinion, make it inadvisable to proceed with the delivery of the Securities, or (vii) if the Company is in material breach of any of its representations, warranties or covenants hereunder, or (viii) if the Representative shall have become aware after the date hereof of such a material adverse change in the conditions or prospects of the Company, or such adverse material change in general market conditions as in the Representative’s judgment would make it impracticable to proceed with the offering, sale and/or delivery of the Securities or to enforce contracts made by the Underwriters for the sale of the Securities.
Waiver of Termination Rights The Employee waives any and all rights to compensation or damages as a result of a Termination, insofar as those rights result or may result from: (a) the loss or diminution in value of such rights or entitlements under the Program; or (b) the Employee ceasing to have rights, or ceasing to be entitled to any Awards under the Program as a result of such Termination.
Right of Termination This Agreement and the transactions contemplated hereby may be completely terminated at any time at or prior to the Closing: (a) by mutual written consent of the Parties; (b) by either Seller or Buyer if the Closing shall not have occurred on or before October 31, 2013; provided, however, that (i) no Party shall have the right to terminate this Agreement pursuant to this clause (b) if such Party is at such time in material breach of its representations and warranties set forth in this Agreement or negligently or willfully failed to perform or observe its covenants and agreements herein in any material respect and (ii) such date shall be postponed to the extent necessary to resolve all disputes being arbitrated pursuant to Section 8.8 under this Agreement or under any of the Cinco Purchase Agreements; (c) by either Seller or Buyer if any Governmental Authority shall have issued an order, judgment or decree or taken any other action challenging, delaying, restraining, enjoining, prohibiting or invalidating the consummation of any of the transactions contemplated herein; or (d) If the sum of (i) the Aggregate Title Defect Value (which shall include any unresolved disputed Title Defects and any unCured Title Defects, whether or not Seller has elected to attempt to Cure), plus (ii) the Aggregate Environmental Defect Value (which shall include any unresolved disputed Environmental Defects and any unRemediated Environmental Defects, whether or not Seller has elected to attempt to Remediate), plus (iii) the aggregate costs to repair or restore any portion of the Assets subject to a Casualty Loss (or condemnation or eminent domain, the Allocated Value of such Assets) and any other Damages related thereto, exceeds 15% of the unadjusted Purchase Price, then either Seller or Buyer may terminate this Agreement upon written notice to the other parties hereto; provided, however, that Buyer may not terminate pursuant to this Section 12.1(d) until such time as Seller shall have had a reasonable opportunity to Cure any Title Defect or Remediate any Environmental Defect.
Term; Termination; Rights on Termination The term of this Agreement shall begin on the date hereof and continue for three (3) years, and, unless terminated sooner as herein provided, shall continue thereafter on a year-to-year basis on the same terms and conditions contained herein in effect as of the time of renewal (such initial three year period and any extensions thereof being referred to herein as the "Term"). This Agreement and Employee's employment may be terminated in any one of the following ways:
Expiration/Termination Upon expiration of the Service Period or termination pursuant to Section 7 of the General Terms, Customer shall immediately cease use of the Service and return or destroy (in accordance with Avaya’s instructions) any Deliverables provided to Customer in connection with the Service, including any Avaya’s Intellectual Property. Upon request, Customer shall certify in writing to Avaya that Customer has complied with this provision and Avaya may provide such certification to its suppliers.
Notification of Termination 22.3.2.1 Upon the occurrence at District's sole determination of any of the above conditions, or upon Developer’s failure to perform any material covenant, condition or agreement in this Facilities Lease, District may, without prejudice to any other right or remedy, serve written notice upon Developer and its Surety of District's termination of this Facilities Lease and/or Developer’s right to perform the Work of this Facilities Lease. This notice will contain the reasons for termination. 22.3.2.2 Unless, within fifteen (15) days after the service of the notice, any and all condition(s) shall cease, and any and all violation(s) shall cease, or arrangement satisfactory to District for the correction of the condition(s) and/or violation(s) be made, this Facilities Lease and the Site Lease shall cease and terminate; provided, however, if the failure stated in the notice cannot be corrected within fifteen (15) days after the service of notice, District may consent to an extension of time, provided Developer instituted and diligently pursued corrective action within the applicable fifteen (15)-day period and until the violation is corrected. Upon District determination, Developer shall not be entitled to receive any further payment until the entire Work is finished. 22.3.2.3 Upon Termination, District may immediately serve written notice of tender upon Surety whereby Surety shall have the right to take over and perform this Facilities Lease only if Surety: 22.3.2.3.1 Within three (3) days after service upon it of the notice of tender, gives District written notice of Surety’s intention to take over and perform this Facilities Lease; and 22.3.2.3.2 Commences performance of this Facilities Lease within three (3) days from date of serving of its notice to District. 22.3.2.4 Surety shall not utilize Developer in completing the Project if the District notifies Surety of the District’s objection to Developer’s further participation in the completion of the Project. Surety expressly agrees that any developer which Xxxxxx proposes to fulfill Surety’s obligations is subject to District’s approval. 22.3.2.5 If Surety fails to notify District or begin performance as indicated herein, District may take over the Work and execute the Work to completion by any method it may deem advisable at the expense of Developer and/or its Surety. Developer and its Surety shall be liable to District for any excess cost or other damages the District incurs thereby. Time is of the essence in this Facilities Lease. If the District takes over the Work as herein provided, District may, without liability for so doing, take possession of and utilize in completing the Work all materials, appliances, plan, and other property belonging to Developer as may be on the Site of the Work, in bonded storage, or previously paid for.
Additional Termination Rights (a) BMS has the right to terminate this License Agreement upon delivery of written notice to MPP upon the occurrence of any of the following: (i) the failure of MPP to ensure a sufficient supply of the Licensed Products in the formulations and strengths listed in Schedule A to meet substantially the needs in the Territory, other than isolated, temporary shortages of less than 90 days if such shortage is not cured (other than by means of a reallocation of Licensed Products that has the effect of creating shortage elsewhere) with 90 days after written notice to MPP by BMS; (ii) the failure of MPP to comply with BMS's reasonable requests under Sections 5(b) through (c) of this License Agreement; (iii) any failure by the MPP of ensuring compliance with relevant OFAC regulations under Section 2.8 of this License Agreement; (iv) if in the reasonable opinion of BMS, control (through ownership or otherwise) or MPP changes; (b) either of BMS and MPP will have the right to terminate any Sublicense Agreement, upon delivery of written notice to the relevant Sublicensee(s) upon the occurrence of any of the following; (i) the occurrence of any material safety issue that BMS reasonably believes makes it inadvisable to proceed or continue with the commercialization of the Licensed Product in the Territory; (ii) without prejudice to Section 2.7(c), a cross-border diversion of the Licensed Compound and/or Licensed Products whereby any Sublicensee (directly or indirectly or through a Third Party, located in or out of the Territory) uses, offers for sale, sells, has sold Licensed Compound and/or Licensed Products for use in any country outside of the Territory; (iii) any failure by the Sublicensees to comply with the quality requirements under Section 6.2 of this License Agreement; (iv) the failure by the respective Sublicensee to file for registration all of the Licensed Products in the the Territory for all of the formulation and strengths listed in Schedule A within thirty (30) months of the Effective Date of each Sublicense Agreement Agreement; (v) the occurrence of a direct or indirect change of control of Sublicensee that has not been consented to by BMS and MPP in writing; and/or (vi) in the event of any serious or intentional violation of any laws and regulations or misappropriation of a Third Party’s intellectual property rights by a Sublicensee anywhere in the world, which in BMS’s and MPP’s judgment, may reflect unfavorably on BMS, MPP, their reputation or the Licensed Products.
Termination Prior to Expiration of Term This Section shall govern any termination of this Contract except as specifically provided in the following Section for termination for cause. The City reserves the right to terminate this Contract at any time, with or without cause, upon thirty (30) days’ written notice to Consultant, except that where termination is due to the fault of the Consultant, the period of notice may be such shorter time as may be determined by the Contract Officer. In addition, the Consultant reserves the right to terminate this Contract at any time, with or without cause, upon sixty (60) days’ written notice to City, except that where termination is due to the fault of the City, the period of notice may be such shorter time as the Consultant may determine. Upon receipt of any notice of termination, Consultant shall immediately cease all services hereunder except such as may be specifically approved by the Contract Officer. Except where the Consultant has initiated termination, the Consultant shall be entitled to compensation for all services rendered prior to the effective date of the notice of termination and for any services authorized by the Contract Officer thereafter in accordance with the Schedule of Compensation or such as may be approved by the Contract Officer, except as provided in Section 7.3. In the event the Consultant has initiated termination, the Consultant shall be entitled to compensation only for the reasonable value of the work product actually produced hereunder. In the event of termination without cause pursuant to this Section, the terminating party need not provide the non-terminating party with the opportunity to cure pursuant to Section 7.2.
Continued Employment Following Expiration of Term Nothing in this Agreement shall mandate or prohibit a continuation of Executive’s employment following the expiration of the term of this Agreement, upon such terms and conditions as the Bank and Executive may mutually agree.
