Expiry, change or revocation of an Order Sample Clauses

Expiry, change or revocation of an Order. An order will expire automatically if the Trading Venue's trading sys-tem removes the Order which has already been saved in the trading system due to, for example, the share trading exdividend or ex-rights, the share being split, a share issue being executed, share classes or shares being combined, or a merger or demerger being executed. An Order concerning a convertible bond does not expire once the Security trades ex-coupon. Next page The Customer has the right to change or revoke an Order before making a binding offer that leads to a trade or making the trade. The change or revocation will enter into force once the Bank has received it and it has been saved in the Trading Venue's trading system. Increasing or decreasing the amount of the object of the Order, and changing the price, are regarded as revocation of the Order and simultaneous issuing of a new Order. Changing an Order can affect its priority status. If the Bank has already taken measures to execute the Order, a revocation requires that the Customer com- pensate any expenses and loss that the Bank may incur. An Order cannot be changed or revoked in so far as it has already been exe- cuted.
Sample 1
AutoNDA by SimpleDocs

Related to Expiry, change or revocation of an Order

  • Term of an Order Form or Service Each Order Form and Service shall be effective on the effective date set forth in that Order Form, and shall remain in effect until end of term or completion of the Services in accordance with the Order Form, the respective Scope Document, or terminated earlier by either party in accordance with this Section 7. For the avoidance of doubt, the termination of any particular Service in accordance with this Section 7 shall not cause or result in the termination of any other Services ordered under the same Order Form nor reduce Prime Contractor’s liability for payments to SAP.

  • Termination of an Order Form for Convenience Except as otherwise agreed in an Order Form, each Order Form (excluding fixed-price Services and excluding subscription or monthly reoccurring Services) may be terminated by either party subject to thirty (30) days’ prior written notice to the other party.

  • Sole Source as Grounds for Rejection of a Change Order If a Change Order is submitted to Contractor for the purposes of adding a Bulletin to this Contract and said Bulletin designates a Sole Source from which Contractor is required to procure goods or services necessary to perform the Work, which Sole Source has not been designated previously, Contractor shall be entitled to reject the proposed Change Order if the designated Sole Source refuses to provide to Contractor the warranties, bonds, terms or schedule required under the Contract Documents, including any warranty or terms or schedule required by Bulletins referenced in the proposed Change Order. In such event, Contractor shall give written notice to the Owner rejecting the proposed Change Order and, if possible, shall accompany said written notice with a proposal from Contractor for changes or modifications to the Bulletin so as to eliminate the Sole Source designation but to achieve goods or services equal in quality or function. The Owner may then require the Design Professional to revise the subject Bulletin so as to eliminate the designation of the Sole Source by incorporation of Contractor's proposal or otherwise. Upon revision of the Bulletin by the Design Professional and approval thereof by the Owner, the Owner shall again submit to the Contractor a proposed Change Order for the purpose of adding the revised Bulletin to this Contract. If the Owner decides to retain the Sole Source in the Change Order and Contractor cannot acquire the full contractually required warranties from the Sole Source, Contractor shall be held only to the warranty terms and schedule obtainable from the Sole Source.

  • The Change Order The Change Order is the instrument by which adjustments in the Contract Sum and the Contract Time are effected. The Change Order shall be accompanied by a breakdown as set forth in Paragraph 3.2.7.4. The breakdown is for the purpose of enabling the Design Professional and the Owner to make a judgment on the dollar amount of the adjustment in the Contract Sum and is not a part of the Change Order. No condition, term, qualification, limitation, exception, exemption, modification, or proviso, except as set forth in this Part, shall appear in the breakdown. Only such conditions, terms, qualifications, limitations, exceptions, exemptions, modifications, and provisos as are permitted under this Part are valid. The Design Professional shall certify to the dollar amount and description of the adjustments permitted by the Change Order.

  • For Lump Sum Change Order The payment and extension of time (if any) provided by this Change Order constitutes compensation in full to the Contractor and its Subcontractors and Suppliers for all costs and markups directly and indirectly attributable to the Change Order herein, for all delays related thereto and for performance of changes within the time stated.

  • Examination of an application for an industrial design 1. A formal examination of the application for an industrial design received by the federal executive authority for intellectual property is carried out which includes checks on presence of the documents specified in clause 2 of Article 1377 of the Civil Code of the Russian Federation and its compliance with the established requirements. If the result of the formal examination is positive, then a substantive examination of an application for an industrial design is carried out, which includes: information search in relation to the claimed industrial design to determine the publicly available information, which shall be taken into account when examining the design patentability; examination of the claimed industrial design for the compliance with the requirements under Article 1231.1, clause 4 of Article 1349 of the Civil Code of the Russian Federation, and the patentability criteria under the first paragraph of clause 1, clause 5 of Article 1352 of the Civil Code of the Russian Federation; examination of the claimed industrial design for the compliance with the patentability criteria under the second paragraph of clause 1 of Article 1352 of the Civil Code of the Russian Federation. An information search in relation to the objects specified in sub-clause 4 of clause 4 of Article 1349 of the Civil Code of the Russian Federation shall not be carried out, and the federal executive authority on intellectual property notifies the applicant about it. 2. If, as a result of the substantive examination of an application for an industrial design, it is found that the claimed industrial design represented on the reproductions of an external appearance of the article does not relate to the objects specified in Article 1231.1 or clause 4 of Article 1349 of the Civil Code of the Russian Federation and meets the patentability criteria under Article 1352 of the Civil Code of the Russian Federation, the federal executive authority for intellectual property makes a decision to grant a patent for an industrial design. The date of filing of the application for the industrial design and the priority date of the industrial design shall be specified in the decision. If, during the process of substantive examination of an application for an industrial design, it is found that the claimed object does not meet at least one of the requirements or patentability criteria specified in paragraph one of this clause, the federal executive authority for intellectual property makes a decision to refuse the issuance of a patent.

  • Change Order (5) The Change Order is then submitted to the Project Manager who immediately processes the CO with OPC as required by Bulletin 3.5 and BGS’ Contracting Plan.

  • NOTICE OF CHANGE OR CANCELLATION There shall be no cancellation, material change, exhaustion of aggregate limits, or intent not to renew insurance coverage, either in whole or in part, without at least sixty (60) days prior written Legal Notice by Contractor to Enterprise Services. Failure to provide such notice, as required, shall constitute default by Contractor. Any such written notice shall include the Master Contract number stated on the cover of this Master Contract.

  • Construction Change Directive A written order prepared and issued by the District, the Construction Manager, and/or the Architect and signed by the District and the Architect, directing a change in the Work.

  • METHOD OF AWARD AND PROCEDURE FOR AWARDING A SOW AGREEMENT 5.1. Contractor selection, or the determination to terminate the SOW-RFP without award, shall be done in the best interest of the State.

Time is Money Join Law Insider Premium to draft better contracts faster.