Waiver of Personal Liability No member, officer, agent or employee of the Issuer or any of its program participants or any director, officer, agent or employee of the Borrower shall be individually or personally liable for the payment of any principal (or redemption price) or interest on the Bonds or any other sum hereunder or be subject to any personal liability or accountability by reason of the execution and delivery of this Loan Agreement; but nothing herein contained shall relieve any such member, director, officer, agent or employee from the performance of any official duty provided by law or by this Loan Agreement.
Limitation of Personal Liability All the parties hereto acknowledge and agree that all liabilities of the Trust arising, directly or indirectly, under this Agreement, of any and every nature whatsoever, shall be satisfied solely out of the assets of the Fund and that no Trustee, officer or holder of shares of beneficial interest of the Trust shall be personally liable for any of the foregoing liabilities. The Trust Instrument describes in detail the respective responsibilities and limitations on liability of the Trustees, officers and holders of shares of beneficial interest of the Trust.
Potential Conflicts and Compliance With Mixed and Shared Funding Exemptive Order 7.1. The Board of Trustees of the Fund (the “Board”) will monitor the Fund for the existence of any material irreconcilable conflict between the interests of the Contract owners of all separate accounts investing in the Fund. An irreconcilable material conflict may arise for a variety of reasons, including: (a) an action by any state insurance regulatory authority; (b) a change in applicable federal or state insurance, tax, or securities laws or regulations, or a public ruling, private letter ruling, no-action or interpretative letter, or any similar action by insurance, tax, or securities regulatory authorities; (c) an administrative or judicial decision in any relevant proceeding; (d) the manner in which the investments of any Portfolio is being managed; (e) a difference in voting instructions given by variable annuity contract and variable life insurance contract owners or by contract owners of different Participating Insurance Companies; or (f) a decision by a Participating Insurance Company to disregard the voting instructions of Contract owners. The Board shall promptly inform the Company if it determines that an irreconcilable material conflict exists and the implications thereof. 7.2. The Company will report any potential or existing conflicts of which it is aware to the Board. The Company will assist the Board in carrying out its responsibilities under the Mixed and Shared Funding Exemptive Order, by providing the Board with all information reasonably necessary for the Board to consider any issues raised. This includes, but is not limited to, an obligation by the Company to inform the Board whenever Contract owner voting instructions are to be disregarded. Such responsibilities shall be carried out by the Company with a view only to the interests of its Contract owners. 7.3. If it is determined by a majority of the Board, or a majority of its directors who are not interested persons of the Fund, the Distributor, the Adviser or any subadviser to any of the Portfolios (the “Independent Directors”), that a material irreconcilable conflict exists, the Company and other Participating Insurance Companies shall, at their expense and to the extent reasonably practicable (as determined by a majority of the Independent Directors), take whatever steps are necessary to remedy or eliminate the irreconcilable material conflict, up to and including: (1) withdrawing the assets allocable to some or all of the separate accounts from the Fund or any Portfolio and reinvesting such assets in a different investment medium, including (but not limited to) another Portfolio, or submitting the question whether such segregation should be implemented to a vote of all affected Contract owners and, as appropriate, segregating the assets of any appropriate group (i.e., annuity contract owners, life insurance contract owners, or variable contract owners of one or more Participating Insurance Companies) that votes in favor of such segregation, or offering to the affected contract owners the option of making such a change; and (2) establishing a new registered management investment company or managed separate account. The Company’s responsibility to take remedial action shall be carried out by the Company with a view only to the interests of Contract owners. 7.4. If a material irreconcilable conflict arises because of a decision by the Company to disregard Contract owner voting instructions and that decision represents a minority position or would preclude a majority vote, the Company may be required, at the Fund’s election, to withdraw the Account’s investment in the Fund and terminate this Agreement; provided, however, that such withdrawal and termination shall be limited to the extent required by the foregoing material irreconcilable conflict as determined by a majority of the Independent Directors. Any such withdrawal and termination must take place within six (6) months after the Fund gives written notice that this provision is being implemented, and until the end of that six-month period the Adviser, the Distributor and the Fund shall continue to accept and implement orders by the Company for the purchase (and redemption) of shares of the Fund, subject to the terms of the Fund’s then-current prospectus. 7.5. If a material irreconcilable conflict arises because a particular state insurance regulator’s decision applicable to the Company conflicts with the majority of other state regulators, then the Company will withdraw the Account’s investment in the Fund and terminate this Agreement within six months after the Board informs the Company in writing that it has determined that such decision has created an irreconcilable material conflict; provided, however, that such withdrawal and termination shall be limited to the extent required by the foregoing material irreconcilable conflict as determined by a majority of the Independent Directors. Until the end of the foregoing six-month period, the Fund shall continue to accept and implement orders by the Company for the purchase (and redemption) of shares of the Fund, subject to the terms of the Fund’s then-current prospectus. 7.6. For purposes of Sections 7.3 through 7.5 of this Agreement, a majority of the Independent Directors shall determine whether any proposed action adequately remedies any irreconcilable material conflict, but in no event will the Fund be required to establish a new funding medium for the Contracts. The Company shall not be required by Section 7.3 to establish a new funding medium for the Contracts if an offer to do so has been declined by vote of a majority of Contract owners affected by the irreconcilable material conflict. In the event that the Board determines that any proposed action does not adequately remedy any irreconcilable material conflict, then the Company will withdraw the Account’s investment in the Fund and terminate this Agreement within six (6) months after the Board informs the Company in writing of the foregoing determination; provided, however, that such withdrawal and termination shall be limited to the extent required by any such material irreconcilable conflict as determined by a majority of the Independent Directors. 7.7. If and to the extent that Rule 6e-2 and Rule 6e-3(T) are amended, or Rule 6e-3 is adopted, to provide exemptive relief from any provision of the 1940 Act or the rules promulgated thereunder with respect to mixed or shared funding (as defined in the Mixed and Shared Funding Exemptive Order) on terms and conditions materially different from those contained in the Mixed and Shared Funding Exemptive Order, then (a) the Fund and/or the Participating Insurance Companies, as appropriate, shall take such steps as may be necessary to comply with Rules 6e-2 and 6e-3(T), as amended, and Rule 6e-3, as adopted, to the extent such rules are applicable: and (b) Sections 3.5, 3.6, 3.7, 7.1, 7.2, 7.3, 7.4, and 7.5 of this Agreement shall continue in effect only to the extent that terms and conditions substantially identical to such Sections are contained in such Rule(s) as so amended or adopted.
Condition of Personal Property All tangible personal property, equipment, fixtures and inventories included within the assets of the Company are in good, merchantable or in reasonably repairable condition and are suitable for the purposes for which they are used. No value in excess of applicable reserves has been given to any inventory with respect to obsolete or discontinued products. To the best of the Company's knowledge, all of the inventories and equipment, including equipment leased to others, are well maintained and in good operating condition.
Use of Personal Leave An employee may use personal leave credits to conduct personal business that cannot be conducted outside of normal working hours and for personal emergencies.
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians. (ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked. (iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority. (iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.
Lobbying Activities - Standard Form - LLL No response Do not upload this form unless Vendor has reportable lobbying activities. There are Attributes entitled, “2 CFR Part 200 or Federal Provision - Xxxx Anti-Lobbying Amendment – Continued.” Properly respond to those Attributes and only upload this form if applicable/instructed. If upload is required based on your response to those Attributes, the Disclosure of Lobbying Activities – Standard Form - LLL must be downloaded from the “Attachments” section of the IonWave eBid System, reviewed, properly completed, and uploaded to this location.
Section 1542 Waiver In giving the general release herein, which includes claims which may be unknown to me at present, I acknowledge that I have read and understand Section 1542 of the California Civil Code, which reads as follows: “A general release does not extend to claims which the creditor does not know or suspect to exist in his or her favor at the time of executing the release, which if known by him or her must have materially affected his or her settlement with the debtor.” I hereby expressly waive and relinquish all rights and benefits under that section and any law of any other jurisdiction of similar effect with respect to my release of claims, including but not limited to any unknown or unsuspected claims herein.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
SCOPE, WAIVER AND ALTERATION OF AGREEMENT (1) No agreement, alteration, understanding, variation, waiver or modification of any of the terms and conditions or covenants herein shall be made by any employee or group of employees with the Board unless executed in writing between the parties hereto and the same has been ratified by the Union and the Board. (2) The waiver of any breach or condition of this Agreement by either party shall not constitute a precedent in the future enforcement of the terms and conditions herein. (3) If any Article or Section of this Agreement or any supplement thereto should be held invalid by operation of law or by any tribunal of competent jurisdiction, or if compliance with or enforcement of any Article or Section should be restrained by such tribunal, the remainder of this Agreement and supplements shall not be affected thereby and the parties shall enter into immediate collective bargaining negotiations for the purpose of arriving at a mutually satisfactory replacement for such Article or Section.
