Casualty Damage 18.1 Tenant shall give immediate notice (by telephone, confirmed in writing) to Landlord of any damage caused to the Premises by fire or other casualty, and if Landlord does not elect to terminate this Lease as provided in Section 18.2, Landlord shall proceed with reasonable diligence and at its sole cost and expense to rebuild and repair the Building and/or the Premises, as the case may be, but Landlord shall not be obligated to expend for such rebuilding and repair any amount in excess of the amount of the insurance proceeds actually recovered by Landlord and made available by any Superior Lessor or Superior Mortgagee as a result of such loss. 18.2 If the Building or the Premises shall be destroyed or substantially damaged by a casualty not covered by Landlord’s insurance, or if 25% or more of the Premises is damaged or rendered untenantable by a casualty covered by Landlord’s insurance, or if the Premises are not affected but 25% of the Building or such portion of the Common Facilities as shall render the Premises or the Building untenantable is damaged or rendered untenantable, then in any such event Landlord may elect either to terminate this Lease or to proceed to rebuild and repair the Premises or that portion of the Building so damaged. Landlord shall give written notice to Tenant of such election within 90 days after the occurrence of such casualty, or within 30 days after the adjustment of the insurance settlement, whichever is later. In the event that such notice of termination shall be given, this Lease shall terminate as of the date provided in such notice of termination (whether or not the Term shall have commenced) with the same effect as if that date were the Expiration Date, without prejudice, however, to Landlord’s rights and remedies against Tenant under the terms of this Lease. If at any time prior to Landlord giving the aforesaid notice of termination or commencing the repair pursuant to Section 18.1, there shall be a Successor Landlord, such Successor Landlord shall have a further period of 60 days from the date of so taking possession to terminate this Lease by notice to Tenant and in the event that such a notice of termination shall be given, this Lease shall terminate as of the date provided in such notice of termination (whether or not the Term shall have been commenced) if Tenant is not occupying any portion of the Premises or otherwise as of the date provided in such notice, with the same effect as if that date were the Expiration Date, without prejudice, however, to Landlord’s rights against Tenant under the terms of this Lease. 18.3 Subject to the provisions of Section 18.1, Landlord’s obligation to rebuild and repair under this Article XVIII shall in any event be limited to restoring Landlord’s Work, as described in the Work Letter, to substantially the condition in which the same existed prior to the casualty, and to proceed, at the sole cost and expense of Tenant, to rebuild, repair and restore Tenant’s Work and any additional Improvements made by Tenant during the Term, all to substantially the condition existing prior to such casualty. 18.4 During the period from the occurrence of the casualty until Landlord’s repairs are completed, the Basic Rent payable pursuant to Article V and Additional Rent payable pursuant to Articles VI and VII shall be abated in that proportion which the Premises area rendered untenantable bears to the entire Premises area; provided, however, there shall be no abatement of any other charges or items of Additional Rent provided for herein to be paid by Tenant; and further provided, however, that should Tenant or anyone claiming through or under Tenant occupy a portion of the Premises during the period the repair work is taking place and prior to the date the Premises are no longer untenantable, the Rent allocable to such reoccupied portion, based upon the proportion which the reoccupied portion of the Premises bears to the total area of the Premises, shall be payable by Tenant from the date of such occupancy. 18.5 Landlord shall not the liable for any inconvenience or annoyance to Tenant or injury to the business of Tenant resulting in any way from any such damage by fire or other casualty or the repair thereof. 18.6 Notwithstanding any of the foregoing provisions of this Article, if, by reason of any negligence or willful act on the part of Tenant or any of its employees, agents, licensees, invitees or contractors, either (a) Landlord or the Superior Lessor or the Superior Mortgagee shall be unable to collect all of the insurance proceeds (including rent insurance proceeds) applicable to damage or destruction of the Premises or the Building or the Project by fire or other casualty or (b) the Premises or the Building or the Project shall be damaged or destroyed or rendered completely or partially untenantable on account of fire or other casualty then, without prejudice to any other remedy which may be available against Tenant, the abatement of rent provided for in Section 18.4 shall not be effective to the extent of the uncollected insurance proceeds.
Property Damage Lessee shall obtain and maintain insurance coverage on all of Lessee's personal property, Trade Fixtures, and Lessee Owned Alterations and Utility Installations. Such insurance shall be full replacement cost coverage with a deductible of not to exceed $1,000 per occurrence. The proceeds from any such insurance shall be used by Lessee for the replacement of personal property, Trade Fixtures and Lessee Owned Alterations and Utility Installations. Lessee shall provide Lessor with written evidence that such insurance is in force.
Termination Damages If the Term of this Lease is terminated for default, unless and until Landlord elects lump sum liquidated damages described in the next paragraph, Tenant covenants, as an additional, cumulative obligation after any such termination, to pay punctually to Landlord all the sums and perform all of its obligations in the same manner as if the Term had not been terminated. In calculating such amounts Tenant will be credited with the net proceeds of any rent then actually received by Landlord from a reletting of the Premises after deducting all Rent that has not then been paid by Tenant, provided that Tenant shall never be entitled to receive any portion of the re-letting proceeds, even if the same exceed the Rent originally due hereunder.
Delay Damages If the Commercial Operation Date is not achieved by the date set forth therefor in Section 3.1(a) (as extended pursuant to Section 3.1(c)), Seller shall pay to Buyer damages for each month from and after such date until the Commercial Operation Date at the rate of $1.50 per kwh of Contract Maximum Amount up to a maximum of twelve (12) months of delay, pro rated for partial months (“Delay Damages”). Delay Damages shall be due under this Section 3.2(a) without regard to whether Buyer exercises its right to terminate this Agreement pursuant to Section 9.3; provided, however, that if Buyer exercises its right to terminate this Agreement under Section 9.3, Delay Damages shall be due and owing to the extent that such Delay Damages were due and owing at the date of such termination. If the Facility has not achieved the Commercial Operation by the date set forth therefor in Section 3.1(a) (as the same may be extended in accordance with Section 3.1(c)), for any reason, Seller shall have the right to terminate this Agreement at any time after that deadline date (as so extended) until either the Facility achieves the Commercial Operation Date or Buyer terminates this Agreement under Section 9.3 (regardless of whether or not Seller elected to continue to construct the Project). In the event Seller so terminates this Agreement, Seller shall be liable to Buyer on the date of such termination for (x) the entire amount of Delay Damages that would otherwise accrue (or have accrued) by such date plus (y) the undrawn amount of any Development Period Security provided to Buyer by Seller; provided, however, that if Seller terminates this Agreement on the deadline set forth for the Commercial Operation Date in Section 3.1(a) (as the same may be extended in accordance with Section 3.1(c)), Seller shall not be required to pay any Delay Damages hereunder but shall forfeit the Development Period Security. Subject to the foregoing sentence, neither Party shall have any liability to the other Party with respect to a termination of this Agreement by Seller under this Section 3.2(b). Each Party agrees and acknowledges that (i) the damages that Buyer would incur due to Seller’s delay in achieving the Commercial Operation Date would be difficult or impossible to predict with certainty, and (ii) it is impractical and difficult to assess actual damages in the circumstances stated, and therefore the Delay Damages and other damages as agreed to by the Parties and set forth herein are a fair and reasonable calculation of such damages. Notwithstanding the foregoing, this Article shall not limit the amount of damages payable to Buyer if this Agreement is terminated by Buyer as a result of Seller’s failure to achieve the Commercial Operation Date. Any such termination damages shall be determined in accordance with Article 9. By the tenth (10th) day following the end of the calendar month in which Delay Damages first become due and continuing by the tenth (10th) day of each calendar month during the period in which Delay Damages accrue (and the following months if applicable), Buyer shall deliver to Seller an invoice showing Buyer’s computation of such damages and any amount due Buyer in respect thereof for the preceding calendar month. No later than ten (10) days after receiving such an invoice, Seller shall pay to Buyer, by wire transfer of immediately available funds to an account specified in writing by Buyer or by any other means agreed to by the Parties in writing from time to time, the amount set forth as due in such invoice. If Seller fails to pay such amounts when due, Buyer may draw upon the Development Period Security for payment of such Delay Damages, and Buyer may exercise any other remedies available for Seller’s default hereunder.
Breach of Contract Claims [Option (Include if University prefers an abbreviated Breach of Contract Claims provision): To the extent that Chapter 2260, Texas Government Code, is applicable to this Agreement and is not preempted by other applicable law, the dispute resolution process provided for in Chapter 2260 and the related rules adopted by the Texas Attorney General pursuant to Chapter 2260, will be used by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor that cannot be resolved in the ordinary course of business. The chief business officer of University will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims. The parties specifically agree (i) neither execution of this Agreement by University nor any other conduct, action or inaction of any representative of University relating to this Agreement constitutes or is intended to constitute a waiver of University’s or the state's sovereign immunity to suit; and (ii) University has not waived its right to seek redress in the courts.] 19.1 To the extent that Chapter 2260, Texas Government Code, as it may be amended from time to time (Chapter 2260), is applicable to this Agreement and is not preempted by other Applicable Laws, the dispute resolution process provided for in Chapter 2260 will be used, as further described herein, by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor: 12.19.1.1 Contractor’s claims for breach of this Agreement that the parties cannot resolve pursuant to other provisions of this Agreement or in the ordinary course of business will be submitted to the negotiation process provided in subchapter B of Chapter 2260. To initiate the process, Contractor will submit written notice, as required by subchapter B of Chapter 2260, to University in accordance with the notice provisions in this Agreement. Contractor's notice will specifically state that the provisions of subchapter B of Chapter 2260 are being invoked, the date and nature of the event giving rise to the claim, the specific contract provision that University allegedly breached, the amount of damages Contractor seeks, and the method used to calculate the damages. Compliance by Contractor with subchapter B of Chapter 2260 is a required prerequisite to Contractor's filing of a contested case proceeding under subchapter C of Chapter 2260. The chief business officer of University, or another officer of University as may be designated from time to time by University by written notice to Contractor in accordance with the notice provisions in this Agreement, will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims. 12.19.1.2 If the parties are unable to resolve their disputes under Section 12.19.1.1, the contested case process provided in subchapter C of Chapter 2260 is Contractor’s sole and exclusive process for seeking a remedy for any and all of Contractor's claims for breach of this Agreement by University. 12.19.1.3 Compliance with the contested case process provided in subchapter C of Chapter 2260 is a required prerequisite to seeking consent to xxx from the Legislature under Chapter 107,
Major Damage In the event of Major Damage to a Property prior to the Closing Date, then the applicable Seller shall have no obligation to repair such Major Damage and shall notify Purchaser in writing of such damage or destruction (the “Damage Notice”). Within ten (10) days after Purchaser’s receipt of the Damage Notice, Purchaser may elect at its option to give a Termination Notice for the damaged Property to Seller’s Representative. If Purchaser does not elect to terminate this Agreement with respect to the damaged Property, this transaction shall be closed in accordance with the terms of this Agreement either, at the election of the applicable Seller, (a) for the full Purchase Price for the damaged Property notwithstanding any such damage or destruction, and Purchaser shall, at Closing, execute and deliver an assignment and assumption (in a form reasonably required by the applicable Seller) of such Seller’ rights and obligations with respect to the insurance claim and related to such casualty, and thereafter Purchaser shall receive all remaining insurance proceeds pertaining to such claim (plus a credit against the applicable Purchase Price at Closing in the amount of any deductible payable by the applicable Seller in connection therewith and not spent by such Seller for demolition, site cleaning, restoration or other repairs); or (b) Purchaser shall receive a credit against the Base Purchase Price for the damaged Property for the full replacement costs of repair to the subject Property, plus, to the extent covered by such Seller’s insurance policy, any costs required pursuant to local code or zoning requirements, as determined by an independent third party reasonably acceptable to such Seller and Purchaser. In the event a Seller elects to assign such Seller's rights and obligations with respect to the insurance claim and related casualty to Purchaser as provided above, and if an AIMCO employee is the adjuster for the claim related thereto, Sellers covenant and agree that the adjuster shall act in accordance with standard insurance industry protocols in processing such claim (including, without limitation, the time taken to process such claim).
Indemnity Consequential Damages and Insurance 18.1 Indemnity 18.1.1 Indemnified Party 18.1.2 Indemnifying Party 18.1.3 Indemnity Procedures 18.2 Consequential Damages 18.3 Insurance 18.3.1 18.3.2 18.3.3 18.3.4 18.3.5 18.3.6 18.3.7 18.3.8 18.3.9 18.3.10 18.3.11
Expenses; Indemnity; Damage Waiver (a) The Borrower shall pay (i) all reasonable out-of-pocket expenses incurred by the Administrative Agent, and its Affiliates, including the reasonable fees, charges and disbursements of counsel for the Administrative Agent in connection with the syndication of the credit facilities provided for herein, the preparation and administration of this Agreement or any amendments, modifications or waivers of the provisions hereof (whether or not the transactions contemplated hereby or thereby shall be consummated) and (ii) all reasonable out-of-pocket expenses incurred by the Administrative Agent or any Lender, including the fees, charges and disbursements of any counsel for the Administrative Agent or any Lender, in connection with the enforcement or protection of its rights in connection with this Agreement, including its rights under this Section, or in connection with the Loans made hereunder, including in connection with any workout, restructuring or negotiations in respect thereof including, without limitation, actions in connection with this Agreement or the Loans, arising, occurring or continuing subsequent to the Maturity Date (other than any such expenses directly related to a court enforcement action in which the Borrower prevails on the merits in a final and nonappealable judgment). (b) The Borrower shall indemnify the Administrative Agent and each Lender, and each Related Party of any of the foregoing Persons (each such Person being called an "Indemnitee") against, and hold each Indemnitee harmless from, any and all losses, claims, damages, liabilities and related expenses, including the fees, charges and disbursements of any counsel for any Indemnitee, incurred by or asserted against any Indemnitee arising out of, in connection with, or as a result of (i) the execution or delivery of this Agreement or any agreement or instrument contemplated hereby, the performance by the parties hereto of their respective obligations hereunder or the consummation of the Transactions or any other transactions contemplated hereby, (ii) any Loan or the use of the proceeds therefrom, (iii) any actual or alleged presence or release of Hazardous Materials on or from any property owned or operated by the Borrower or any of its Subsidiaries, or any Environmental Liability related in any way to the Borrower or any of its Subsidiaries, or (iv) any actual or prospective claim, litigation, investigation or proceeding relating to any of the foregoing, whether based on contract, tort or any other theory and regardless of whether any Indemnitee is a party thereto; provided that such indemnity shall not, as to any Indemnitee, be available to the extent that such losses, claims, damages, liabilities or related expenses are determined by a court of competent jurisdiction by final and nonappealable judgment to have resulted from the gross negligence or wilful misconduct of such Indemnitee. (c) To the extent that the Borrower fails to pay any amount required to be paid by it to the Administrative Agent under paragraph (a) or (b) of this Section, each Lender severally agrees to pay to the Administrative Agent such Lender's Applicable Percentage (determined as of the time that the applicable unreimbursed expense or indemnity payment is sought) of such unpaid amount; provided that the unreimbursed expense or indemnified loss, claim, damage, liability or related expense, as the case may be, was incurred by or asserted against the Administrative Agent in its capacity as such. (d) To the extent permitted by applicable law, the Borrower shall not assert, and hereby waives, any claim against any Indemnitee, on any theory of liability, for special, indirect, consequential or punitive damages (as opposed to direct or actual damages) arising out of, in connection with, or as a result of, this Agreement or any agreement or instrument contemplated hereby, the Transactions, any Loan or the use of the proceeds thereof. (e) All amounts due under this Section shall be payable promptly after written demand therefor.
FIRE AND CASUALTY DAMAGE If the Premises are so injured or damaged by fire or other cause as to be uninhabitable for more than 120 days, then the Tenant may terminate this Lease upon written notice to the Landlord. A total destruction of the Premises shall automatically terminate this Lease. If this Lease is not so terminated, then the Landlord shall diligently restore the damaged Premises at its sole cost and expense as soon as is reasonably practical, but in all events less than 120 days from the date of such damage or casualty, and if the Landlord fails to do so, then the Tenant may terminate this Lease by delivering written notice to the Landlord. The Tenant will be entitled to an abatement of Rent for the period of time that all or any portion of the Premises are not useable for the Tenant’s business due to such casualty based on the portion of the Premises that the Tenant is unable to use. If any such damage occurs before closing but after the Tenant has exercised its Option to Purchase, then the Tenant may, within 30 days after the date of such damage, by delivery of written notice to the Landlord, cancel and rescind the Tenant’s exercise of the Option to Purchase. Each of the Landlord and the Tenant hereby releases the other (and the other’s employees, officers, shareholders, directors, and members) from any and all liability or responsibility to the other or any claiming through or under them by way of subrogation or otherwise for any loss or damage to property caused by fire or any other perils which may be insurable in policies of insurance covering such property and required to be carried within this Lease, even if such loss or damage shall have been caused by the fault or negligence of the other party, or anyone for whom such party may be responsible. Each party shall cause its insurance policies to contain a clause or endorsement to the effect that such release shall not adversely affect or impair said policies or prejudice the right of the releasor to recover thereunder and to the effect that such insurer waives its rights of subrogation as to such released or waived claim.
Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.
