Failure of Allottee to take Possession of Apartment Upon receiving a written intimation from the Promoter as per para 7.2, the Allottee shall take possession of the Apartment from the Promoter by executing necessary indemnities, undertakings and such other documentation as prescribed in this Agreement and the Promoter shall give possession of the Apartment to the Allottee. In case the Allottee fails to take possession within the time provided in para 7.1 such Allottee shall continue to be liable to pay interest on due payments and maintenance charges as specified in para 7.2.
PROVISIONS OF THIS AGREEMENT APPLICABLE ON ALLOTTEE / SUBSEQUENT ALLOTTEES It is clearly understood and so agreed by and between the Parties hereto that all the provisions contained herein and the obligations arising hereunder in respect of the Project shall equally be applicable to and enforceable against any subsequent Allottees of the [Apartment/Plot], in case of a transfer, as the said obligations go along with the [Apartment/Plot] for all intents and purposes.
RIGHT OF ALLOTTEE TO USE COMMON AREAS AND FACILITIES SUBJECT TO PAYMENT OF TOTAL MAINTENANCE CHARGES
Purchaser's Election to Commence Foreclosure Proceedings (a) In connection with any Mortgage Loan identified in a report under Section 2.01(a)(i)(B), the Purchaser may elect to instruct the Company to cause, to the extent that the Company as Master Servicer is granted such authority in the related Servicing Agreement, the related Servicer to proceed with the Commencement of Foreclosure as soon as practicable. Such election must be evidenced by written notice received by the Company by 5:00 p.m., New York City time, on the third Business Day following the delivery of such report under Section 2.01(a)(i).
(b) Within two Business Days of making any Election to Foreclose, the Purchaser shall remit to the Company, for deposit in the Collateral Fund, an amount, as calculated by the Company, equal to 125% of the current unpaid principal balance of the Mortgage Loan and three months interest on the Mortgage Loan at the applicable Mortgage Interest Rate. If and when any such Mortgage Loan is brought current by the mortgagor, all amounts in the Collateral Fund in respect of such Mortgage Loan (after adjustment for all permitted withdrawals and deposits pursuant to this Agreement) shall be released to the Purchaser if and to the extent that reimbursement therefor from amounts paid by the mortgagor is not prohibited pursuant to the Pooling and Servicing Agreement or the related Servicing Agreement, applicable law or the related mortgage note. The terms of this Agreement will no longer apply to the servicing of any Mortgage Loan upon the failure of the Purchaser to deposit the above amounts relating to the Mortgage Loan within two Business Days of the Election to Foreclose subject to Section 3.01.
(c) With respect to any Mortgage Loan as to which the Purchaser has made an Election to Foreclose, the related Servicer shall continue to service the Mortgage Loan in accordance with its customary procedures (other than Commencement of Foreclosure as provided herein). In connection therewith, the Company shall have the same rights to make withdrawals for Monthly Advances and Liquidations Expenses from the Collateral Fund as are provided under Section 2.02(e), and the Company shall make reimbursements thereto to the limited extent provided under such subsection in accordance with its customary procedures. The Company shall not be required to cause, to the extent that the Company as Master Servicer is granted such authority in the related Servicing Agreement, the related Servicer to proceed with the Commencement of Foreclosure if (i) the same is stayed as a result of the mortgagor's bankruptcy or is otherwise barred by applicable law, or to the extent that all legal conditions precedent thereto have not yet been complied with, or (ii) the Company believes there is a breach of representations or warranties by the Company, a Servicer, or a Seller, which may result in a repurchase or substitution of such Mortgage Loan, or (iii) the Company or related Servicer reasonably believes the Mortgaged Property may be contaminated with or affected by hazardous wastes or hazardous substances (and, without limiting the related Servicer's right not to proceed with the Commencement of Foreclosure, the Company supplies the Purchaser with information supporting such belief). Any foreclosure that has been initiated may be discontinued (x) without notice to the Purchaser if the Mortgage Loan has been brought current or if a refinancing or prepayment occurs with respect to the Mortgage Loan (including by means of a short payoff approved by the Purchaser) or (y) with notice to the Purchaser if the related Servicer has reached the terms of a forbearance agreement unless instructed otherwise by the Purchaser within two Business Days of such notification. Any such instruction shall be based upon a decision that such forbearance agreement is not in conformity with reasonable servicing practices.
(d) Upon the occurrence of a liquidation with respect to any Mortgage Loan as to which the Purchaser made an Election to Foreclose and as to which the related Servicer proceeded with the Commencement of Foreclosure in accordance with subsection (c) above, the Company shall calculate the amount, if any, by which the unpaid principal balance of the Mortgage Loan at the time of liquidation (plus all unreimbursed interest and servicing advances and Liquidation Expenses in connection therewith other than those paid from the Collateral Fund) exceeds the actual sales price obtained for the related Mortgaged Property, and the Company shall withdraw the amount of such excess from the Collateral Fund, shall remit the same to the Trust Estate and in its capacity as Master Servicer shall apply such amount as additional Liquidation Proceeds pursuant to the Pooling and Servicing Agreement. After making such withdrawal, all amounts remaining in the Collateral Fund (after adjustment for all withdrawals and deposits pursuant to subsection (c) in respect of such Mortgage Loan shall be released to the Purchaser.
Failure to Charge Not Subsequent Waiver Any decision by the Administrative Agent or any Lender not to require payment of any interest (including interest arising under Section 3.7), fee, cost or other amount payable under any Loan Document, or to calculate any amount payable by a particular method, on any occasion shall in no way limit or be deemed a waiver of the Administrative Agent’s or such Lender’s right to require full payment of any interest (including interest arising under Section 3.7), fee, cost or other amount payable under any Loan Document, or to calculate an amount payable by another method that is not inconsistent with this Agreement, on any other or subsequent occasion, except as provided in Sections 3.5 and 3.6.
Purchaser's Election to Delay Foreclosure Proceedings (a) The Purchaser shall be deemed to direct the Company to direct (to the extent that the Company as Master Servicer is granted such authority in the related Servicing Agreement) the related Servicer that in the event that the Company does not receive written notice of the Purchaser's election pursuant to subsection (b) below within 24 hours (exclusive of any intervening non-Business Days) of transmission of the notice provided by the Company under Section 2.01 (a) (ii) subject to extension as set forth in Section 2.02(b), the related Servicer may proceed with the Commencement of Foreclosure in respect of such Mortgage Loan in accordance with its normal foreclosure policies without further notice to the Purchaser. Any foreclosure that has been initiated may be discontinued (i) without notice to the Purchaser if the Mortgage Loan has been brought current or if a refinancing or prepayment occurs with respect to the Mortgage Loan (including by means of a short payoff approved by the related Servicer) or (ii) if the related Servicer has reached the terms of a forbearance agreement with the borrower. In the latter case, the related Servicer may complete such forbearance agreement unless instructed otherwise by the Purchaser within two Business Days notification.
(b) In connection with any Mortgage Loan with respect to which a notice under Section 2.01(a)(ii) has been given to the Purchaser, the Purchaser may elect to instruct the Company to cause, to the extent that the Company as Master Servicer is granted such authority in the related Servicing Agreement, the related Servicer to delay the Commencement of Foreclosure until such time as the Purchaser determines that the related Servicer may proceed with the Commencement of Foreclosure. Such election must be evidenced by written notice received within 24 hours (exclusive of any intervening non-Business Days) of transmission of the notice provided by the Company under Section 2.01(a)(ii). Such 24 hour period shall be extended for no longer than an additional four Business Days after the receipt of the information if the Purchaser requests additional information related to such foreclosure; provided, however, that the Purchaser will have at least one Business Day to respond to any requested additional information. Any such additional information shall be provided only to the extent it (i) is not confidential in nature and (ii) is obtainable by the related Servicer from existing reports, certificates or statements or is otherwise readily accessible to its servicing personnel. The Purchaser agrees that it has no right to deal with the mortgagor during such period. However, if such servicing activities include acceptance of a deed-in-lieu of foreclosure or short payoff, the Purchaser will be notified and given two Business Days to respond.
(c) With respect to any Mortgage Loan as to which the Purchaser has made an Election to Delay Foreclosure, the Purchaser shall obtain a Current Appraisal as soon as practicable, but in no event more than 15 business days thereafter, and shall provide the Company with a copy of such Current Appraisal.
(d) Within two Business Days of making any Election to Delay Foreclosure, the Purchaser shall remit by wire transfer to the Company, for deposit in the Collateral Fund, an amount, as calculated by the Company, equal to the sum of (i) 125% of the greater of the unpaid principal balance of the Mortgage Loan and the value shown in the Current Appraisal referred to in subsection (c) above (or, if such Current Appraisal has not yet been obtained, the Company's estimate thereof, in which case the required deposit under this subsection shall be adjusted upon obtaining such Current Appraisal), and (ii) three months' interest on the Mortgage Loan at the applicable Mortgage Interest Rate. If any Election to Delay Foreclosure extends for a period in excess of three months (such excess period being referred to herein as the "Excess Period"), within two Business Days the Purchaser shall remit by wire transfer in advance to the Company for deposit in the Collateral Fund the amount of each additional month's interest, as calculated by the Company, equal to interest on the Mortgage Loan at the applicable Mortgage Interest Rate for the Excess Period. The terms of this Agreement will no longer apply to the servicing of any Mortgage Loan upon the failure of the Purchaser to deposit any of the above amounts relating to the Mortgage Loan within two Business Days of the Election to Delay Foreclosure or within two Business Days of the commencement of the Excess Period subject to Section 3.01.
(e) With respect to any Mortgage Loan as to which the Purchaser has made an Election to Delay Foreclosure, the Company may withdraw from the Collateral Fund from time to time amounts necessary to reimburse the related Servicer for all related Monthly Advances and Liquidation Expenses thereafter made by such Servicer in accordance with the Pooling and Servicing Agreement and the related Servicing Agreement. To the extent that the amount of any such Liquidation Expenses is determined by the Company based on estimated costs, and the actual costs are subsequently determined to be higher, the Company may withdraw the additional amount from the Collateral Fund. In the event that the Mortgage Loan is brought current by the mortgagor and the foreclosure action is discontinued, the amounts so withdrawn from the Collateral Fund shall be redeposited if and to the extent that reimbursement therefor from amounts paid by the mortgagor is not prohibited pursuant to the Pooling and Servicing Agreement or the related Servicing Agreement, applicable law or the related mortgage note. Except as provided in the preceding sentence, amounts withdrawn from the Collateral Fund to cover Monthly Advances and Liquidation Expenses shall not be redeposited therein or otherwise reimbursed to the Purchaser. If and when any such Mortgage Loan is brought current by the mortgagor, all amounts remaining in the Collateral Fund in respect of such Mortgage Loan (after adjustment for all permitted withdrawals and deposits pursuant to this subsection) shall be released to the Purchaser.
(f) With respect to any Mortgage Loan as to which the Purchaser has made an Election to Delay Foreclosure, the related Servicer shall continue to service the Mortgage Loan in accordance with its customary procedures (other than the delay in Commencement of Foreclosure as provided herein). If and when the Purchaser shall notify the Company that it believes that it is appropriate to do so, the related Servicer may proceed with the Commencement of Foreclosure. In any event, if the Mortgage Loan is not brought current by the mortgagor by the time the loan becomes 6 months delinquent, the Purchaser's election shall no longer be effective and at the Purchaser's option, either (i) the Purchaser shall purchase the Mortgage Loan from the related Trust Estate at a purchase price equal to the fair market value as shown on the Current Appraisal, to be paid by (x) applying any balance in the Collateral Fund to such to such purchase price, and (y) to the extent of any deficiency, by wire transfer of immediately available funds from the Purchaser to the Company for deposit in the related Certificate Account; or (ii) the related Servicer shall proceed with the Commencement of Foreclosure.
(g) Upon the occurrence of a liquidation with respect to any Mortgage Loan as to which the Purchaser made an Election to Delay Foreclosure and as to which the related Servicer proceeded with the Commencement of Foreclosure in accordance with subsection (f) above, the Company shall calculate the amount, if any, by which the value shown on the Current Appraisal obtained under subsection (c) exceeds the actual sales price obtained for the related Mortgaged Property (net of Liquidation Expenses and accrued interest related to the extended foreclosure period), and the Company shall withdraw the amount of such excess from the Collateral Fund, shall remit the same to the Trust Estate and in its capacity as Master Servicer shall apply such amount as additional Liquidation Proceeds pursuant to the Pooling and Servicing Agreement. After making such withdrawal, all amounts remaining in the Collateral Fund in respect of such Mortgage Loan (after adjustment for all permitted withdrawals and deposits pursuant to this Agreement) shall be released to the Purchaser.
Documents, Records and Funds in Possession of the Servicer to be Held for the Trustee The Servicer shall transmit to the Trustee or, at the direction of the Trustee, the Custodian as required by this Agreement all documents and instruments in respect of a Mortgage Loan coming into the possession of the Servicer from time to time and shall account fully to the Trustee for any funds received by the Servicer or which otherwise are collected by the Servicer as Liquidation Proceeds or Insurance Proceeds in respect of any Mortgage Loan. The documents constituting the Servicing File shall be held by the Servicer as custodian and bailee for the Trustee. All Mortgage Files and funds collected or held by, or under the control of, the Servicer in respect of any Mortgage Loans, whether from the collection of principal and interest payments or from Liquidation Proceeds, including but not limited to, any funds on deposit in the Servicer Custodial Account, shall be held by the Servicer for and on behalf of the Trustee and shall be and remain the sole and exclusive property of the Trustee, subject to the applicable provisions of this Agreement. The Servicer also agrees that it shall not knowingly create, incur or subject any Mortgage File or any funds that are deposited in the Servicer Custodial Account, Certificate Account or any Escrow Account, or any funds that otherwise are or may become due or payable to the Trustee for the benefit of the Certificateholders, to any claim, lien, security interest, judgment, levy, writ of attachment or other encumbrance created by the Servicer, or assert by legal action or otherwise any claim or right of setoff against any Mortgage File or any funds collected on, or in connection with, a Mortgage Loan, except, however, that the Servicer shall be entitled to set off against and deduct from any such funds any amounts that are properly due and payable to the Servicer under this Agreement.
Trustee to Retain Possession of Certain Insurance Policies and Documents The Trustee (or the Custodian, as directed by the Trustee), shall retain possession and custody of the originals (to the extent available) of any Primary Mortgage Insurance Policies, or certificate of insurance if applicable, and any certificates of renewal as to the foregoing as may be issued from time to time as contemplated by this Agreement. Until all amounts distributable in respect of the Certificates have been distributed in full and the Master Servicer otherwise has fulfilled its obligations under this Agreement, the Trustee (or its Custodian, if any, as directed by the Trustee) shall also retain possession and custody of each Mortgage File in accordance with and subject to the terms and conditions of this Agreement. The Master Servicer shall promptly deliver or cause to be delivered to the Trustee (or the Custodian, as directed by the Trustee), upon the execution or receipt thereof the originals of any Primary Mortgage Insurance Policies, any certificates of renewal, and such other documents or instruments that constitute portions of the Mortgage File that come into the possession of the Master Servicer from time to time.
Documents Records and Funds in Possession of Master Servicer to be Held for the Trustee Notwithstanding any other provisions of this Agreement, the Master Servicer shall transmit to the Trustee as required by this Agreement all documents and instruments in respect of a Mortgage Loan coming into the possession of the Master Servicer from time to time and shall account fully to the Trustee for any funds received by the Master Servicer or which otherwise are collected by the Master Servicer as Liquidation Proceeds or Insurance Proceeds in respect of any Mortgage Loan. All Mortgage Files and funds collected or held by, or under the control of, the Master Servicer in respect of any Mortgage Loans, whether from the collection of principal and interest payments or from Liquidation Proceeds, including but not limited to, any funds on deposit in the Certificate Account, shall be held by the Master Servicer for and on behalf of the Trustee and shall be and remain the sole and exclusive property of the Trustee, subject to the applicable provisions of this Agreement. The Master Servicer also agrees that it shall not create, incur or subject any Mortgage File or any funds that are deposited in the Certificate Account, Distribution Account or any Escrow Account, or any funds that otherwise are or may become due or payable to the Trustee for the benefit of the Certificateholders, to any claim, lien, security interest, judgment, levy, writ of attachment or other encumbrance, or assert by legal action or otherwise any claim or right of setoff against any Mortgage File or any funds collected on, or in connection with, a Mortgage Loan, except, however, that the Master Servicer shall be entitled to set off against and deduct from any such funds any amounts that are properly due and payable to the Master Servicer under this Agreement.
POSSESSION OF THE APARTMENT PLOT
8.1 Schedule for possession of the said Apartment: The Promoter agrees and understands that timely delivery of possession of the Apartment to the Allottee and the Common Areas to the Association of the Allottees , is the essence of the Agreement. Provided that the Promoter shall be entitled to reasonable extension of time as agreed by and between the Allottee and the Promoter for giving possession of the Apartment on the aforesaid date and the same shall not include the period of extension given by the Authority for registration. The Promoter, based on the approved plans and specifications, assures to hand over possession of the Apartment on …………,with a grace period of twelve months (Completion date) in case the Promoter fails to complete the Project. unless there is a delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity or order, rule, notification of the Government and/or other public or competent authority/court and/or caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Apartment, Provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. Promoter will be entitled to give block-wise and phase-wise possession upon obtaining the Completion Certificate/ Partial Completion Certificate of a building block or a particular phase as the case may be irrespective of the fact that construction of other Blocks and/or other phases and/or provision of facilities may be incomplete. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 45 days from that date.After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement. It is clarified that all amounts collected as taxes, charges, levies, cess, assessments and impositions and deposited with the appropriate authorities concerned shall not be returned by the Promoter and the Allottee shall be free to approach the authorities concerned for refund of such taxes, charges, levies, cess, assessments and impositions.
8.2 The right of the Allottee shall remain restricted to the respective Apartment and the properties appurtenant thereto and the Allottee shall have no right, title or interest nor shall claim any right, title or interest of any kind whatsoever over and in respect of any other Apartment or space and/or any other portions of the Project or Complex.
8.3 The Promoter has provided to the Allottee a time schedule for construction progress based on the milestones on which payment is due. The dates provided are only tentative and for the purpose of dealing with contractors and will also make efforts to complete various stages as per the time schedule upto completion of the Project including the provisions of civic infrastructure like water, electricity, sanitation and all other above mentioned internal/external development works but the Promoter knows there will definitely be delays in the timelines provided but the Promoter assures the Allottee that the Project will be completed within the ‘Completion date’ provided in Clause 8.1 above.
