Failure to Notify If Contractor fails to specify in writing any problem or circumstance that materially affects the costs of its delivery of services or products, including a material breach by the Department, about which Contractor knew or reasonably should have known with respect to the period during the term covered by Contractor's status report, Contractor shall not be entitled to rely upon such problem or circumstance as a purported justification for an increase in the price for the agreed upon scope.
Notice to the Authority No later than [45 (forty five)] days prior to commencement of the Construction Period or the Operation Period, as the case may be, the Concessionaire shall by notice furnish to the Authority, in reasonable detail, information in respect of the insurances that it proposes to effect and maintain in accordance with this Article 27. Within [30 (thirty)] days of receipt of such notice, the Authority may require the Concessionaire to effect and maintain such other insurances as may be necessary pursuant hereto, and in the event of any difference or disagreement relating to any such insurance, the Dispute Resolution Procedure in Article 39 shall apply.
Failure to Act Within Time Limits If the Griever or the Union fails to process a grievance to the next step in the grievance procedure within the time limits specified, they shall not be deemed to have prejudiced their position on any future grievance.
Failure to Act Except for action expressly required of Agent hereunder and under the other Financing Agreements, Agent shall in all cases be fully justified in failing or refusing to act hereunder and thereunder unless it shall receive further assurances to its satisfaction from Lenders of their indemnification obligations under Section 12.5 hereof against any and all liability and expense that may be incurred by it by reason of taking or continuing to take any such action.
Notice of Breach The Authorized User shall promptly notify the Contactor and the Commissioner in writing of any claim of breach of any warranty provided herein.
Failure to Agree If the Contractor claims entitlement to a change in the Contract, and the Department does not agree that any action or event has occurred to justify any change in time or compensation, or if the parties fail to agree upon the appropriate amount of the adjustment in time or compensation, the Department will unilaterally make such changes, if any, to the Contract, as it determines are appropriate pursuant to the Contract. The Contractor shall proceed with the Work and the Department's directives, without interruption or delay, and shall make a claim as provided in Article 12. Failure to proceed due to a dispute over a change request shall constitute a material breach of the Contract and entitle the Department to all available remedies for such breach, including, without limitation, termination for default.
Failure to Defend If the Indemnifying Party, within a reasonable time after notice of any such Claim, fails to defend such Claim actively and in good faith, the Indemnified Party will (upon further notice) have the right to undertake the defense, compromise or settlement of such Claim or consent to the entry of a judgment with respect to such Claim, on behalf of and for the account and risk of the Indemnifying Party, and the Indemnifying Party shall thereafter have no right to challenge the Indemnified Party's defense, compromise, settlement or consent to judgment.
Failure to Provide Notice A failure to give timely Notice or to include any specified information in any Notice as provided in this Section 15.3 will not affect the rights or obligations of any Party hereunder except and only to the extent that, as a result of such failure, any Party which was entitled to receive such Notice was deprived of its right to recover any payment under its applicable insurance coverage or was otherwise materially damaged as a direct result of such failure and, provided further, the Indemnitor is not obligated to indemnify the Indemnitee for the increased amount of any Indemnifiable Loss which would otherwise have been payable to the extent that the increase resulted from the failure to deliver timely a Notice of Claim.
Notice of Decision The Plan Administrator shall notify the claimant in writing of its decision on review. The Plan Administrator shall write the notification in a manner calculated to be understood by the claimant. The notification shall set forth:
Failure to Provide Notice of Expiry If the HSP fails to provide the required 6 months’ Notice that it intends to allow this Agreement to expire, or fails to provide a Transition Plan along with any such Notice, this Agreement shall automatically be extended and the HSP will continue to provide the Services under this Agreement for so long as the Funder may reasonably require to enable all clients of the HSP to transition to new service providers.
