Failure to Timely Proceed with Work Sample Clauses

Failure to Timely Proceed with Work. In the event Construction Contractor is not progressing with its Work in accordance with the Construction Schedule, and, as a result, the progression of the Work is at a stage that is more than thirty (30) days behind schedule as provided in the Construction Schedule, then Landlord shall cause Construction Contractor to take such measures as are reasonably necessary to accelerate the progression of its Work to bring the progression of the Work into compliance with the Construction Schedule. In the event Construction Contractor is not progressing with its Work in accordance with the Construction Schedule, and, as a result, the progression of the Work is at a stage that is more than ninety (90) days behind schedule as provided in the Construction Schedule, then, immediately upon Tenant's notice and demand, Landlord shall cause such Construction Contractor to be removed and shall replace such Construction Contractor with a new Construction Contractor approved in writing by Tenant, in Tenant's reasonable discretion. In the event Engineer is not progressing with its Work in accordance with the Construction Schedule, and, as a result, the progression of the Work is at a stage that is more than thirty (30) days behind schedule as provided in the Construction Schedule, then Landlord shall cause Engineer to take such measures as are reasonably necessary to accelerate the progression of its Work to bring the progression of the Work into compliance with the Construction Schedule. In the event Engineer is not progressing with its Work in accordance with the Construction Schedule, and, as a result, the progression of the Work is at a stage that is more than ninety (90) days behind schedule as provided in the Construction Schedule, then, immediately upon Tenant's notice and demand, Landlord shall cause such Engineer to be removed and shall replace such Engineer with a new Engineer approved in writing by Tenant, in Tenant's reasonable discretion.
Sample 1
AutoNDA by SimpleDocs

Related to Failure to Timely Proceed with Work

  • Company’s Failure to Timely Convert If the Company shall fail to issue a certificate to the Holder or credit the Holder's balance account with DTC for the number of shares of Common Stock to which the Holder is entitled upon conversion of any Conversion Amount on or prior to the date which is five Business Days after the Conversion Date (a “Conversion Failure”), then the Company shall pay to the Holder payments (“Conversion Default Payments”) for a Conversion Failure in the amount of (i) (N/365), multiplied by (ii) an amount equal to the amount by which (x) the highest Closing Sale Price of the Common Stock during the period beginning on the date the Conversion Notice giving rise to the Conversion Failure in accordance with this Section 3(c)(ii) is transmitted (the “Conversion Failure Date”) and ending on the date immediately preceding the date on which the applicable Conversion Default Payment is made exceeds (y) the Conversion Price in respect of such Conversion Amount, multiplied by (iii) the number of shares of Common Stock the Company failed to so deliver in such Conversion Failure, multiplied by (iv) .18, where N equals the number of days from the Conversion Failure Date to the date that the Company effects the full conversion of the Conversion Amount which gave rise to the Conversion Failure. The accrued Conversion Default Payments for each calendar month shall be paid in cash to the Holder by the fifth day of the month following the month in which it has accrued. In addition to the foregoing, if within five Trading Days after the Company's receipt of the facsimile copy of a Conversion Notice the Company shall fail to issue and deliver a certificate to the Holder or credit the Holder's balance account with DTC for the number of shares of Common Stock to which the Holder is entitled upon such Holder's conversion of any Conversion Amount, and if on or after such Trading Day the Holder purchases (in an open market transaction or otherwise) Common Stock to deliver in satisfaction of a sale by the Holder of Common Stock issuable upon such conversion that the Holder anticipated receiving from the Company (a “Buy-In”), then the Company shall, within three Business Days after the Holder's request and in the Holder's discretion, either (i) pay cash to the Holder in an amount equal to the Holder's total purchase price (including brokerage commissions and other out-of-pocket expenses, if any) for the shares of Common Stock so purchased (the “Buy-In Price”), at which point the Company's obligation to deliver such certificate (and to issue such Common Stock) shall terminate, or (ii) promptly honor its obligation to deliver to the Holder a certificate or certificates representing such Common Stock and pay cash to the Holder in an amount equal to the excess (if any) of the Buy-In Price over the product of (A) such number of shares of Common Stock times (B) the Closing Sale Price on the Conversion Date. Nothing herein shall limit the Holder’s right to pursue actual damages for the Company’s failure to maintain a sufficient number of authorized shares of Common Stock or to otherwise issue shares of Common Stock upon conversion of this Note in accordance with the terms hereof, and the Holder shall have the right to pursue all remedies available at law or in equity (including a decree of specific performance and/or injunctive relief).

  • No Release; Return or Destruction Each Party agrees not to release or disclose, or permit to be released or disclosed, any information addressed in Section 6.9(a) to any other Person, except its Representatives who need to know such information in their capacities as such (who shall be advised of their obligations hereunder with respect to such information), and except in compliance with Section 6.10. Without limiting the foregoing, when any such information is no longer needed for the purposes contemplated by this Agreement or any Ancillary Agreement, and is no longer subject to any legal hold or other document preservation obligation, each Party will promptly after request of the other Party either return to the other Party all such information in a tangible form (including all copies thereof and all notes, extracts or summaries based thereon) or notify the other Party in writing that it has destroyed such information (and such copies thereof and such notes, extracts or summaries based thereon); provided, that the Parties may retain electronic back-up versions of such information maintained on routine computer system backup tapes, disks or other backup storage devices; provided further, that any such information so retained shall remain subject to the confidentiality provisions of this Agreement or any Ancillary Agreement.

  • Purchaser's Election to Commence Foreclosure Proceedings (a) In connection with any Mortgage Loan identified in a report under Section 2.01(a)(i)(B), the Purchaser may elect to instruct the Company to cause, to the extent that the Company as Master Servicer is granted such authority in the related Servicing Agreement, the related Servicer to proceed with the Commencement of Foreclosure as soon as practicable. Such election must be evidenced by written notice received by the Company by 5:00 p.m., New York City time, on the third Business Day following the delivery of such report under Section 2.01(a)(i). (b) Within two Business Days of making any Election to Foreclose, the Purchaser shall remit to the Company, for deposit in the Collateral Fund, an amount, as calculated by the Company, equal to 125% of the current unpaid principal balance of the Mortgage Loan and three months interest on the Mortgage Loan at the applicable Mortgage Interest Rate. If and when any such Mortgage Loan is brought current by the mortgagor, all amounts in the Collateral Fund in respect of such Mortgage Loan (after adjustment for all permitted withdrawals and deposits pursuant to this Agreement) shall be released to the Purchaser if and to the extent that reimbursement therefor from amounts paid by the mortgagor is not prohibited pursuant to the Pooling and Servicing Agreement or the related Servicing Agreement, applicable law or the related mortgage note. The terms of this Agreement will no longer apply to the servicing of any Mortgage Loan upon the failure of the Purchaser to deposit the above amounts relating to the Mortgage Loan within two Business Days of the Election to Foreclose subject to Section 3.01. (c) With respect to any Mortgage Loan as to which the Purchaser has made an Election to Foreclose, the related Servicer shall continue to service the Mortgage Loan in accordance with its customary procedures (other than Commencement of Foreclosure as provided herein). In connection therewith, the Company shall have the same rights to make withdrawals for Monthly Advances and Liquidations Expenses from the Collateral Fund as are provided under Section 2.02(e), and the Company shall make reimbursements thereto to the limited extent provided under such subsection in accordance with its customary procedures. The Company shall not be required to cause, to the extent that the Company as Master Servicer is granted such authority in the related Servicing Agreement, the related Servicer to proceed with the Commencement of Foreclosure if (i) the same is stayed as a result of the mortgagor's bankruptcy or is otherwise barred by applicable law, or to the extent that all legal conditions precedent thereto have not yet been complied with, or (ii) the Company believes there is a breach of representations or warranties by the Company, a Servicer, or a Seller, which may result in a repurchase or substitution of such Mortgage Loan, or (iii) the Company or related Servicer reasonably believes the Mortgaged Property may be contaminated with or affected by hazardous wastes or hazardous substances (and, without limiting the related Servicer's right not to proceed with the Commencement of Foreclosure, the Company supplies the Purchaser with information supporting such belief). Any foreclosure that has been initiated may be discontinued (x) without notice to the Purchaser if the Mortgage Loan has been brought current or if a refinancing or prepayment occurs with respect to the Mortgage Loan (including by means of a short payoff approved by the Purchaser) or (y) with notice to the Purchaser if the related Servicer has reached the terms of a forbearance agreement unless instructed otherwise by the Purchaser within two Business Days of such notification. Any such instruction shall be based upon a decision that such forbearance agreement is not in conformity with reasonable servicing practices. (d) Upon the occurrence of a liquidation with respect to any Mortgage Loan as to which the Purchaser made an Election to Foreclose and as to which the related Servicer proceeded with the Commencement of Foreclosure in accordance with subsection (c) above, the Company shall calculate the amount, if any, by which the unpaid principal balance of the Mortgage Loan at the time of liquidation (plus all unreimbursed interest and servicing advances and Liquidation Expenses in connection therewith other than those paid from the Collateral Fund) exceeds the actual sales price obtained for the related Mortgaged Property, and the Company shall withdraw the amount of such excess from the Collateral Fund, shall remit the same to the Trust Estate and in its capacity as Master Servicer shall apply such amount as additional Liquidation Proceeds pursuant to the Pooling and Servicing Agreement. After making such withdrawal, all amounts remaining in the Collateral Fund (after adjustment for all withdrawals and deposits pursuant to subsection (c) in respect of such Mortgage Loan shall be released to the Purchaser.

  • Termination Due To Lack Of Funding Appropriation If, in the judgment of the Director of Accounts and Reports, Department of Administration, sufficient funds are not appropriated to continue the function performed in this agreement and for the payment of the charges hereunder, State may terminate this agreement at the end of its current fiscal year. State agrees to give written notice of termination to contractor at least 30 days prior to the end of its current fiscal year, and shall give such notice for a greater period prior to the end of such fiscal year as may be provided in this contract, except that such notice shall not be required prior to 90 days before the end of such fiscal year. Contractor shall have the right, at the end of such fiscal year, to take possession of any equipment provided State under the contract. State will pay to the contractor all regular contractual payments incurred through the end of such fiscal year, plus contractual charges incidental to the return of any such equipment. Upon termination of the agreement by State, title to any such equipment shall revert to contractor at the end of the State's current fiscal year. The termination of the contract pursuant to this paragraph shall not cause any penalty to be charged to the agency or the contractor.

  • Contract Renegotiation, Suspension, or Termination Due to Change in Funding If the funds DSHS relied upon to establish this Contract or Program Agreement are withdrawn, reduced or limited, or if additional or modified conditions are placed on such funding, after the effective date of this contract but prior to the normal completion of this Contract or Program Agreement: a. At DSHS’s discretion, the Contract or Program Agreement may be renegotiated under the revised funding conditions. b. At DSHS’s discretion, DSHS may give notice to Contractor to suspend performance when DSHS determines that there is reasonable likelihood that the funding insufficiency may be resolved in a timeframe that would allow Contractor’s performance to be resumed prior to the normal completion date of this contract. (1) During the period of suspension of performance, each party will inform the other of any conditions that may reasonably affect the potential for resumption of performance. (2) When DSHS determines that the funding insufficiency is resolved, it will give Contractor written notice to resume performance. Upon the receipt of this notice, Contractor will provide written notice to DSHS informing DSHS whether it can resume performance and, if so, the date of resumption. For purposes of this subsubsection, “written notice” may include email. (3) If the Contractor’s proposed resumption date is not acceptable to DSHS and an acceptable date cannot be negotiated, DSHS may terminate the contract by giving written notice to Contractor. The parties agree that the Contract will be terminated retroactive to the date of the notice of suspension. DSHS shall be liable only for payment in accordance with the terms of this Contract for services rendered prior to the retroactive date of termination. c. DSHS may immediately terminate this Contract by providing written notice to the Contractor. The termination shall be effective on the date specified in the termination notice. DSHS shall be liable only for payment in accordance with the terms of this Contract for services rendered prior to the effective date of termination. No penalty shall accrue to DSHS in the event the termination option in this section is exercised.

  • Company’s Failure to Timely Deliver Securities If the Company shall fail, for any reason or for no reason, on or prior to the Share Delivery Date, if the Transfer Agent is not participating in FAST or such shares of Common Stock may not be issued without legends under the Securities Act, to issue and deliver to the Holder (or its designee) a certificate for the number of Warrant Shares to which the Holder is entitled and register such Warrant Shares on the Company’s share register or, if the Transfer Agent is participating in FAST and such shares of Common Stock may not be issued without legends under the Securities Act, to credit the balance account of the Holder or the Holder’s designee with DTC for such number of Warrant Shares to which the Holder is entitled upon the Holder’s exercise of this Warrant (as the case may be) (a “Delivery Failure”), then, in addition to all other remedies available to the Holder, (X) the Company shall pay in cash to the Holder on each day after the Share Delivery Date and during such Delivery Failure an amount in cash, as liquidated damages and not as a penalty, equal to 2.0% of the product of (A) the sum of the number of shares of Common Stock not issued to the Holder on or prior to the Share Delivery Date and to which the Holder is entitled, and (B) any trading price of the Common Stock selected by the Holder in writing as in effect at any time during the period beginning on the applicable exercise date and ending on the applicable Share Delivery Date, and (Y) the Holder, upon written notice to the Company, may void its Exercise Notice with respect to, and retain or have returned, as the case may be, any portion of this Warrant that has not been exercised pursuant to such Exercise Notice; provided that the voiding of an Exercise Notice shall not affect the Company’s obligations to make any payments which have accrued prior to the date of such notice pursuant to this Section 1(c) or otherwise. In addition to the foregoing, if on or after such Share Delivery Date the Holder purchases (in an open market transaction or otherwise) shares of Common Stock to deliver in satisfaction of a sale by the Holder of all or any portion of the number of shares of Common Stock issuable upon such exercise that the Holder is entitled to receive from the Company (a “Buy-In”), then, in addition to all other remedies available to the Holder, the Company shall, within three (3) Business Days after the Holder’s request and in the Holder’s discretion, either (i) pay cash to the Holder in an amount equal to the Holder’s total purchase price (including brokerage commissions and other out-of-pocket expenses, if any) for the shares of Common Stock so purchased (including, without limitation, by any other Person in respect, or on behalf, of the Holder) (the “Buy-In Price”), at which point the Company’s obligation to so issue and deliver such certificate (and to issue such shares of Common Stock) or credit the balance account of such Holder or such Holder’s designee, as applicable, with DTC for the number of Warrant Shares to which the Holder is entitled upon the Holder’s exercise hereunder (as the case may be) (and to issue such Warrant Shares) shall terminate, or (ii) promptly honor its obligation to so issue and deliver to the Holder a certificate or certificates representing such Warrant Shares or credit the balance account of such Holder or such Holder’s designee, as applicable, with DTC for the number of Warrant Shares to which the Holder is entitled upon the Holder’s exercise hereunder (as the case may be) and pay cash to the Holder in an amount equal to the excess (if any) of the Buy-In Price over the product of (A) such number of Warrant Shares multiplied by (B) the Closing Sale Price of the Common Stock on the Share Delivery Date with respect to the related Exercise Notice (the “Buy-In Payment Amount”). The Holder shall provide the Company written notice indicating the amounts payable to the Holder in respect of the Buy-In and, upon request of the Company, evidence of the amount of such loss. Nothing shall limit the Holder’s right to pursue any other remedies available to it hereunder, at law or in equity, including, without limitation, a decree of specific performance and/or injunctive relief with respect to the Company’s failure to timely deliver certificates representing shares of Common Stock (or to electronically deliver such shares of Common Stock) upon the exercise of this Warrant as required pursuant to the terms hereof.

  • Failure to Return Failure of the employee to return pursuant to the date determined in this Section will constitute grounds for termination by the School District unless the School District and the employee mutually agree to an extension of the leave.

  • Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.

  • Purchaser's Election to Delay Foreclosure Proceedings (a) The Purchaser shall be deemed to direct the Company to direct (to the extent that the Company as Master Servicer is granted such authority in the related Servicing Agreement) the related Servicer that in the event that the Company does not receive written notice of the Purchaser's election pursuant to subsection (b) below within 24 hours (exclusive of any intervening non-Business Days) of transmission of the notice provided by the Company under Section 2.01 (a) (ii) subject to extension as set forth in Section 2.02(b), the related Servicer may proceed with the Commencement of Foreclosure in respect of such Mortgage Loan in accordance with its normal foreclosure policies without further notice to the Purchaser. Any foreclosure that has been initiated may be discontinued (i) without notice to the Purchaser if the Mortgage Loan has been brought current or if a refinancing or prepayment occurs with respect to the Mortgage Loan (including by means of a short payoff approved by the related Servicer) or (ii) if the related Servicer has reached the terms of a forbearance agreement with the borrower. In the latter case, the related Servicer may complete such forbearance agreement unless instructed otherwise by the Purchaser within two Business Days notification. (b) In connection with any Mortgage Loan with respect to which a notice under Section 2.01(a)(ii) has been given to the Purchaser, the Purchaser may elect to instruct the Company to cause, to the extent that the Company as Master Servicer is granted such authority in the related Servicing Agreement, the related Servicer to delay the Commencement of Foreclosure until such time as the Purchaser determines that the related Servicer may proceed with the Commencement of Foreclosure. Such election must be evidenced by written notice received within 24 hours (exclusive of any intervening non-Business Days) of transmission of the notice provided by the Company under Section 2.01(a)(ii). Such 24 hour period shall be extended for no longer than an additional four Business Days after the receipt of the information if the Purchaser requests additional information related to such foreclosure; provided, however, that the Purchaser will have at least one Business Day to respond to any requested additional information. Any such additional information shall be provided only to the extent it (i) is not confidential in nature and (ii) is obtainable by the related Servicer from existing reports, certificates or statements or is otherwise readily accessible to its servicing personnel. The Purchaser agrees that it has no right to deal with the mortgagor during such period. However, if such servicing activities include acceptance of a deed-in-lieu of foreclosure or short payoff, the Purchaser will be notified and given two Business Days to respond. (c) With respect to any Mortgage Loan as to which the Purchaser has made an Election to Delay Foreclosure, the Purchaser shall obtain a Current Appraisal as soon as practicable, but in no event more than 15 business days thereafter, and shall provide the Company with a copy of such Current Appraisal. (d) Within two Business Days of making any Election to Delay Foreclosure, the Purchaser shall remit by wire transfer to the Company, for deposit in the Collateral Fund, an amount, as calculated by the Company, equal to the sum of (i) 125% of the greater of the unpaid principal balance of the Mortgage Loan and the value shown in the Current Appraisal referred to in subsection (c) above (or, if such Current Appraisal has not yet been obtained, the Company's estimate thereof, in which case the required deposit under this subsection shall be adjusted upon obtaining such Current Appraisal), and (ii) three months' interest on the Mortgage Loan at the applicable Mortgage Interest Rate. If any Election to Delay Foreclosure extends for a period in excess of three months (such excess period being referred to herein as the "Excess Period"), within two Business Days the Purchaser shall remit by wire transfer in advance to the Company for deposit in the Collateral Fund the amount of each additional month's interest, as calculated by the Company, equal to interest on the Mortgage Loan at the applicable Mortgage Interest Rate for the Excess Period. The terms of this Agreement will no longer apply to the servicing of any Mortgage Loan upon the failure of the Purchaser to deposit any of the above amounts relating to the Mortgage Loan within two Business Days of the Election to Delay Foreclosure or within two Business Days of the commencement of the Excess Period subject to Section 3.01. (e) With respect to any Mortgage Loan as to which the Purchaser has made an Election to Delay Foreclosure, the Company may withdraw from the Collateral Fund from time to time amounts necessary to reimburse the related Servicer for all related Monthly Advances and Liquidation Expenses thereafter made by such Servicer in accordance with the Pooling and Servicing Agreement and the related Servicing Agreement. To the extent that the amount of any such Liquidation Expenses is determined by the Company based on estimated costs, and the actual costs are subsequently determined to be higher, the Company may withdraw the additional amount from the Collateral Fund. In the event that the Mortgage Loan is brought current by the mortgagor and the foreclosure action is discontinued, the amounts so withdrawn from the Collateral Fund shall be redeposited if and to the extent that reimbursement therefor from amounts paid by the mortgagor is not prohibited pursuant to the Pooling and Servicing Agreement or the related Servicing Agreement, applicable law or the related mortgage note. Except as provided in the preceding sentence, amounts withdrawn from the Collateral Fund to cover Monthly Advances and Liquidation Expenses shall not be redeposited therein or otherwise reimbursed to the Purchaser. If and when any such Mortgage Loan is brought current by the mortgagor, all amounts remaining in the Collateral Fund in respect of such Mortgage Loan (after adjustment for all permitted withdrawals and deposits pursuant to this subsection) shall be released to the Purchaser. (f) With respect to any Mortgage Loan as to which the Purchaser has made an Election to Delay Foreclosure, the related Servicer shall continue to service the Mortgage Loan in accordance with its customary procedures (other than the delay in Commencement of Foreclosure as provided herein). If and when the Purchaser shall notify the Company that it believes that it is appropriate to do so, the related Servicer may proceed with the Commencement of Foreclosure. In any event, if the Mortgage Loan is not brought current by the mortgagor by the time the loan becomes 6 months delinquent, the Purchaser's election shall no longer be effective and at the Purchaser's option, either (i) the Purchaser shall purchase the Mortgage Loan from the related Trust Estate at a purchase price equal to the fair market value as shown on the Current Appraisal, to be paid by (x) applying any balance in the Collateral Fund to such to such purchase price, and (y) to the extent of any deficiency, by wire transfer of immediately available funds from the Purchaser to the Company for deposit in the related Certificate Account; or (ii) the related Servicer shall proceed with the Commencement of Foreclosure. (g) Upon the occurrence of a liquidation with respect to any Mortgage Loan as to which the Purchaser made an Election to Delay Foreclosure and as to which the related Servicer proceeded with the Commencement of Foreclosure in accordance with subsection (f) above, the Company shall calculate the amount, if any, by which the value shown on the Current Appraisal obtained under subsection (c) exceeds the actual sales price obtained for the related Mortgaged Property (net of Liquidation Expenses and accrued interest related to the extended foreclosure period), and the Company shall withdraw the amount of such excess from the Collateral Fund, shall remit the same to the Trust Estate and in its capacity as Master Servicer shall apply such amount as additional Liquidation Proceeds pursuant to the Pooling and Servicing Agreement. After making such withdrawal, all amounts remaining in the Collateral Fund in respect of such Mortgage Loan (after adjustment for all permitted withdrawals and deposits pursuant to this Agreement) shall be released to the Purchaser.

  • Failure to Timely Deliver; Buy-In If the Company fails to (i) issue and deliver (or cause to be delivered) to the Investor by the Required Delivery Date a certificate representing the Securities so delivered to the Company by such Investor that is free from all restrictive and other legends or (ii) credit the balance account of such Investor’s or such Investor’s nominee with DTC for such number of Conversion Shares so delivered to the Company, then, in addition to all other remedies available to such Investor, the Company shall pay in cash to such Investor on each day after the Required Delivery Date that the issuance or credit of such shares is not timely effected an amount equal to 2% of the original principal amount of such Investor’s Note. In addition to the foregoing, if the Company fails to so properly deliver such unlegended certificates or so properly credit the balance account of such Investor’s or such Investor’s nominee with DTC by the Required Delivery Date, and if on or after the Required Delivery Date such Investor (or any other Person in respect, or on behalf, of such Investor) purchases (in an open market transaction or otherwise) shares of Common Stock to deliver in satisfaction of a sale by such Investor of all or any portion of the number of shares of Common Stock, or a sale of a number of shares of Common Stock equal to all or any portion of the number of shares of Common Stock, that such Investor so anticipated receiving from the Company without any restrictive legend, then, in addition to all other remedies available to such Investor, the Company shall, within three (3) Trading Days after such Investor’s request and in such Investor’s sole discretion, either (i) pay cash to such Investor in an amount equal to such Investor’s total purchase price (including brokerage commissions and other out-of-pocket expenses, if any) for the shares of Common Stock so purchased (including brokerage commissions and other out-of-pocket expenses, if any) (the “Buy-In Price”), at which point the Company’s obligation to so deliver such certificate or credit such Investor’s balance account shall terminate and such shares shall be cancelled, or (ii) promptly honor its obligation to so deliver to such Investor a certificate or certificates or credit such Investor’s DTC account representing such number of shares of Common Stock that would have been so delivered if the Company timely complied with its obligations hereunder and pay cash to such Investor in an amount equal to the excess (if any) of the Buy-In Price over the product of (A) such number of shares of Conversion Shares that the Company was required to deliver to such Investor by the Required Delivery Date multiplied by (B) the lowest Closing Sale Price (as define in the Note) of the Common Stock on any Trading Day during the period commencing on the date of the delivery by such Investor to the Company of the applicable Conversion Shares and ending on the date of such delivery and payment under this clause (ii).

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!