Certified and Minority Business Enterprises Reports Upon Customer request, the Contractor shall report to the requesting Customer the Contractor’s spend with certified and other minority business enterprises in the provision of commodities or services related to the Customer’s orders. These reports shall include the period covered, the name, minority code, and Federal Employer Identification Number of each minority business utilized during the period; commodities and services provided by the minority business enterprise, and the amount paid to each minority business enterprise on behalf of the Customer.
Conditions Applicable to Insurance All policies of insurance required by this solicitation or any Contract resulting from this solicitation must meet the following requirements:
Provisions Applicable to Certain Agreements The provisions in this section are applicable only to the types of orders specified in the first sentence of each subsection. If this Agreement is not of the type described in the first sentence of a subsection, then that subsection does not apply to the Agreement.
General provisions applicable to payments The holder of a Global Note shall be the only person entitled to receive payments in respect of Notes represented by such Global Note and the Issuer will be discharged by payment to, or to the order of, the holder of such Global Note in respect of each amount so paid. Each of the persons shown in the records of Euroclear or Clearstream, Luxembourg as the beneficial holder of a particular nominal amount of Notes represented by such Global Note must look solely to Euroclear or Clearstream, Luxembourg, as the case may be, for his share of each payment so made by the Issuer to, or to the order of, the holder of such Global Note. Notwithstanding the foregoing provisions of this Condition, if any amount of principal and/or interest in respect of Notes is payable in U.S. dollars, such U.S. dollar payments of principal and/or interest in respect of such Notes will be made at the specified office of a Paying Agent in the United States if:
Unallowable Costs Defined All costs (as defined in the Federal Acquisition Regulation, 48 C.F.R. § 31.205-47; and in Titles XVIII and XIX of the Social Security Act, 42 U.S.C. §§ 1395-1395lll and 1396-1396w-5; and the regulations and official program directives promulgated thereunder) incurred by or on behalf of Defendants, their present or former officers, directors, employees, shareholders, and agents in connection with:
Additional Procedures Applicable to High Value Accounts 1. If a Preexisting Individual Account is a High Value Account as of December 31, 2013, the Reporting [FATCA Partner] Financial Institution must complete the enhanced review procedures described in paragraph D of this section with respect to such account by December 31, 2014. If based on this review, such account is identified as a U.S. Reportable Account, the Reporting [FATCA Partner] Financial Institution must report the required information about such account with respect to 2013 and 2014 in the first report on the Account. For all subsequent years, information about the account should be reported on an annual basis.
COMPLIANCE WITH EPA REGULATIONS APPLICABLE TO GRANTS SUBGRANTS, COOPERATIVE AGREEMENTS, AND CONTRACTS Contractor certifies compliance with all applicable standards, orders, regulations, and/or requirements issued pursuant to the Clean Air Act of 1970, as amended (42 U.S.C. 1857(h)), Section 508 of the Clean Water Act, as amended (13 U.S.C. 1368), Executive Order 117389 and Environmental Protection Agency Regulation, 40 CFR Part 15.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Payment Limited to Satisfactory Services Contractor is not entitled to any payments from City until [insert name of department] approves Services, including any furnished Deliverables, as satisfying all of the requirements of this Agreement. Payments to Contractor by City shall not excuse Contractor from its obligation to replace unsatisfactory Deliverables, including equipment, components, materials, or Services even if the unsatisfactory character of such Deliverables, equipment, components, materials, or Services may not have been apparent or detected at the time such payment was made. Deliverables, equipment, components, materials and Services that do not conform to the requirements of this Agreement may be rejected by City and in such case must be replaced by Contractor without delay at no cost to the City.
Divestment costs etc 34.5.1 The Concessionaire shall bear and pay all costs incidental to divestment of all of the rights, title and interest of the Concessionaire in the Project in favour of the Authority upon Termination, save and except that all stamp duties payable on any deeds or Documents executed by the Concessionaire in connection with such divestment shall be borne by the Authority.
