Force Majeure Capacity Reduction Demand Reduction 38
Force Majeure Capacity Reduction Demand Reduction 38 Sample Clauses
Related to Force Majeure Capacity Reduction Demand Reduction 38
Available Relief for a Force Majeure Event 11.7.1 Subject to this Article 11: (a) no Party shall be in breach of its obligations pursuant to this Agreement except to the extent that the performance of its obligations was prevented, hindered or delayed due to a Force Majeure Event; (b) every Party shall be entitled to claim relief in relation to a Force Majeure Event in regard to its obligations, including but not limited to those specified under Article 4.5; (c) For avoidance of doubt, neither Party’s obligation to make payments of money due and payable prior to occurrence of Force Majeure events under this Agreement shall be suspended or excused due to the occurrence of a Force Majeure Event in respect of such Party. (d) Provided that no payments shall be made by either Party affected by a Force Majeure Event for the period of such event on account of its inability to perform its obligations due to such Force Majeure Event.
Staff Reduction 11.1 When a reduction within the District is needed, the affected employee(s) and the Association will be notified as to which position(s) will be eliminated or reduced at least fourteen (14) calendar days prior to the reduction. 11.2 When a reduction within the District is needed, the Board will determine which position(s) will be eliminated or reduced. An employee whose position will be eliminated or reduced shall have the right to displace an employee in his/her present job classification or another job classification in accordance with the following: a. The laid off or reduced employee has greater seniority than the employee to be displaced. b. The laid off or reduced employee had an equal or greater number of hours in his/her regular schedule than the employee to be displaced. c. The laid off or reduced employee presently has the necessary qualifications to perform the work. d. The laid off or reduced employee elects to exercise his/her displacement rights within five (5) working days of notification of his/her layoff or reduction. An employee displaced under this section is also entitled to displacement rights under this section. 11.3 When filling vacancies which occur after a reduction in staff, laid off bargaining unit members who have been released less than two (2) years, shall be recalled in the order of seniority, with the most senior member being recalled first to any position for which he/she is qualified. Effective July 1, 1991, newly hired bargaining unit members shall be subject to recall for two (2) years. If the employee fails to report to work within ten (10) working days from the receipt of the recall notice via certified or registered mail, that person shall be considered a voluntary terminated employee. However, if an employee is recalled to a position of lesser hours, he/she shall have the option to refuse the position and shall not be removed from the recall list as a result of this action. 11.4 An employee may elect to accept layoff rather than exercise his/her bumping rights. 11.5 For the purposes of this agreement, qualified shall be defined as capable of skillfully and efficiently performing the job duties as summarized in the job description in a competent manner with minimal instruction. The District reserves the right to test employees as needed. Qualified includes the following: a. Any licenses, certification and training necessary to perform the job, and b. demonstrated skills and merits. The most senior qualified employee shall be selected, excepting that a less senior candidate may be selected if he/she has greatly superior training and skills. The burden of proof of greatly superior training and skills shall be on the Board.
Force Majeure Notice In relation to any Relevant Force Majeure Event: (a) as soon as reasonably practicable after the Affected Party becomes aware, or ought reasonably to have become aware, that such Force Majeure Event qualifies for relief under this Clause 17 (and, in any event, within 72 hours of becoming aware of such circumstances), the Affected Party shall give a Force Majeure Notice; and (b) the Force Majeure Notice shall include detailed particulars (to the extent available) of the Relevant Force Majeure Event and its consequences, its effects on the Affected Party, the Relevant Obligations, the likely duration of such consequences and effects and the remedial measures proposed by the Affected Party to avoid or remove the Relevant Force Majeure Event or to mitigate its consequences and effects.
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Termination Notice for Force Majeure Event If a Force Majeure Event subsists for a period of 180 (one hundred and eighty) days or more within a continuous period of 365 (three hundred and sixty five) days, either Party may in its discretion terminate this Agreement by issuing a Termination Notice to the other Party without being liable in any manner whatsoever, save as provided in this Article 34, and upon issue of such Termination Notice, this Agreement shall, notwithstanding anything to the contrary contained herein, stand terminated forthwith; provided that before issuing such Termination Notice, the Party intending to issue the Termination Notice shall inform the other Party of such intention and grant 15 (fifteen) days time to make a representation, and may after the expiry of such 15 (fifteen) days period, whether or not it is in receipt of such representation, in its sole discretion issue the Termination Notice.
Reduction of Total Commitment The Borrower shall have the right at ----------------------------- any time and from time to time upon five (5) Business Days prior written notice to the Agent to reduce by $2,500,000 or an integral multiple of $500,000 in excess thereof or terminate entirely the Total Commitment, whereupon the Commitments of the Banks shall be reduced pro rata in accordance with their --- ---- respective Commitment Percentages of the amount specified in such notice or, as the case may be, terminated. Promptly after receiving any notice of the Borrower delivered pursuant to this (S)2.3, the Agent will notify the Banks of the substance thereof. Upon the effective date of any such reduction or termination, the Borrower shall pay to the Agent for the respective accounts of the Banks the full amount of any commitment fee then accrued on the amount of the reduction. No reduction or termination of the Commitments may be reinstated.
Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.
Termination or Reduction of Revolving Commitments The Borrower shall have the right, upon not less than three Business Days’ notice to the Administrative Agent, to terminate the Revolving Commitments or, from time to time, to reduce the amount of the Revolving Commitments; provided that no such termination or reduction of Revolving Commitments shall be permitted if, after giving effect thereto and to any prepayments of the Revolving Loans and Swingline Loans made on the effective date thereof, the Total Revolving Extensions of Credit would exceed the Total Revolving Commitments. Any such reduction shall be in an amount equal to $1,000,000, or a whole multiple thereof, and shall reduce permanently the Revolving Commitments then in effect.
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.
Termination Reduction or Increase of the Commitments (a) The Company shall have the right, upon at least three Business Days' notice to the Agent, to terminate in whole or reduce ratably in part the unused portions of the respective Commitments of the Lenders, provided that each partial reduction shall be in the aggregate amount of $5,000,000 or an integral multiple of $1,000,000 in excess thereof and provided further that (x) the aggregate amount of the Commitments of the Lenders shall not be reduced to an amount that is less than the aggregate principal amount of the Competitive Bid Advances then outstanding, and (y) once terminated, a portion of a Commitment shall not be reinstated except pursuant to Section 2.05(c). (b) If any Lender shall make a demand under Section 2.11 or 2.14 or if the obligation of any Lender to make Eurodollar Rate Advances shall have been suspended pursuant to Section 2.12, the Company shall have the right, upon at least ten Business Days' notice, to terminate in full the Commitment of such Lender or to demand that such Lender assign to one or more Persons all of its rights and obligations under this Agreement in accordance with Section 8.
