Forecasting Requirements 19.5.1 The Parties shall exchange technical descriptions and forecasts of their Interconnection and traffic requirements in sufficient detail necessary to establish the Interconnections necessary for traffic completion to and from all Customers in their respective designated service areas.
Minimum Requirements Consultant shall, at its expense, procure and maintain for the duration of the Agreement insurance against claims for injuries to persons or damages to property which may arise from or in connection with the performance of the Agreement by the Consultant, its agents, representatives, employees or subconsultants. Consultant shall also require all of its subconsultants to procure and maintain the same insurance for the duration of the Agreement. Such insurance shall meet at least the following minimum levels of coverage:
Testing Requirements 12.1. Workplaces - 12.2. On workplaces where the value of the Commonwealth’s contribution to the project that includes the building work is at least $5,000,000, and represents at least 50% of the total construction project value or the Commonwealth’s contribution to the project that includes the building work is at least $10,000,000 (irrespective of its proportion of the total construction project value) the following minimum testing requirements must be adhered to.
W-9 Requirement Alongside a signed copy of this Agreement, Grantee will provide Florida Housing with a properly completed Internal Revenue Service (“IRS”) Form W-9. The purpose of the W-9 form is to document the SS# or FEIN# per the IRS. Note: W-9s submitted for any other entity name other than the Grantee’s will not be accepted.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Reporting Requirement (1) In the event the Contractor identifies covered telecommunications equipment or services used as a substantial or essential component of any system, or as critical technology as part of any system, during contract performance, or the Contractor is notified of such by a subcontractor at any tier or by any other source, the Contractor shall report the information in paragraph (d)(2) of this clause to the Contracting Officer, unless elsewhere in this contract are established procedures for reporting the information; in the case of the Department of Defense, the Contractor shall report to the website at xxxxx://xxxxxx.xxx.xxx. For indefinite delivery contracts, the Contractor shall report to the Contracting Officer for the indefinite delivery contract and the Contracting Officer(s) for any affected order or, in the case of the Department of Defense, identify both the indefinite delivery contract and any affected orders in the report provided at xxxxx://xxxxxx.xxx.xxx. (2) The Contractor shall report the following information pursuant to paragraph (d)(1) of this clause (i) Within one business day from the date of such identification or notification: the contract number; the order number(s), if applicable; supplier name; supplier unique entity identifier (if known); supplier Commercial and Government Entity (CAGE) code (if known); brand; model number (original equipment manufacturer number, manufacturer part number, or wholesaler number); item description; and any readily available information about mitigation actions undertaken or recommended. (ii) Within 10 business days of submitting the information in paragraph (d)(2)(i) of this clause: any further available information about mitigation actions undertaken or recommended. In addition, the Contractor shall describe the efforts it undertook to prevent use or submission of covered telecommunications equipment or services, and any additional efforts that will be incorporated to prevent future use or submission of covered telecommunications equipment or services.
Reporting Requirements The Company, during the period when the Prospectus is required to be delivered under the 1933 Act or the 1934 Act, will file all documents required to be filed with the Commission pursuant to the 1934 Act within the time periods required by the 1934 Act and the 1934 Act Regulations.
Operating Requirements Any operating and technical requirements that may be applicable due to Regional Transmission Organization, Independent System Operator, control area, or the Connecting Transmission Owner’s requirements, including those set forth in the Small Generator Interconnection Agreement. Operating Requirements shall include Applicable Reliability Standards.
Child Abuse Reporting Requirements A. Grantees shall comply with child abuse and neglect reporting requirements in Texas Family Code Chapter 261. This section is in addition to and does not supersede any other legal obligation of the Grantee to report child abuse. B. Grantee shall use the Texas Abuse Hotline Website located at xxxxx://xxx.xxxxxxxxxxxxxx.xxx/Login/Default.aspx as required by the System Agency. Grantee shall retain reporting documentation on site and make it available for inspection by the System Agency.
Child Abuse Reporting Requirement Grantee will: a. comply with child abuse and neglect reporting requirements in Texas Family Code Chapter 261. This section is in addition to and does not supersede any other legal obligation of the Grantee to report child abuse. b. develop, implement and enforce a written policy that includes at a minimum the System Agency’s Child Abuse Screening, Documenting, and Reporting Policy for Grantees/Providers and train all staff on reporting requirements. c. use the System Agency Child Abuse Reporting Form located at xxxxx://xxx.xxxx.xxxxx.xx.xx/Contact Us/report abuse.asp as required by the System Agency. d. retain reporting documentation on site and make it available for inspection by the System Agency.
