Use of Project Development Security Buyer shall be entitled to draw upon the Project Development Security posted by Seller for Daily Delay Damages until such time as the Project Development Security is exhausted. Buyer shall also be entitled to draw upon the Project Development Security for any damages arising upon Buyer’s declaration of an Early Termination Date.
SMALL BUSINESS PARTICIPATION AND DVBE PARTICIPATION REPORTING REQUIREMENTS a. If for this Contract Contractor made a commitment to achieve small business participation, then Contractor must within 60 days of receiving final payment under this Contract (or within such other time period as may be specified elsewhere in this Contract) report to the awarding department the actual percentage of small business participation that was achieved. (Govt. Code § 14841.)
VISIBILITY OF FUNDING FROM THE OFFICIAL DEVELOPMENT ASSISTANCE Unless the SAIDC requests or agrees otherwise, any communication or publication made by the Final Beneficiary that relates to the action, including at conferences, seminars or in any information or promotional materials (such as brochures, leaflets, posters, presentations in electronic form, etc.), including tangible assets acquired from the project must: (a) indicate that the action has received funding from the Official Development Assistance, SlovakAid and (b) display the SlovakAid logo. When displayed in association with another logo, the SlovakAid logo must have appropriate prominence. The obligation to display the SlovakAid logo does not confer on the Final Beneficiary a right of exclusive use. The Final Beneficiary may not appropriate the SlovakAid logo or any similar trademark or logo, either by registration or by any other means. For the purposes of the first, second and third subparagraphs and under the conditions specified therein, the Final Beneficiary may use the SlovakAid logo without first obtaining permission from the SAIDC.
Temporary Credit for Unamortized Specified Road Construction Cost When, under B8.33, Contracting Officer orders a delay or interruption of Purchaser’s Operations for more than 30 days when scheduled operations would be occurring but for the order, the Contracting Officer shall credit the unamortized cost of Specified Roads to Purchaser’s Timber Sale Account, upon the written request of Purchaser or at the discretion of Contracting Officer. The amount credited to Purchaser shall be limited to stumpage paid above Base Rates. Any Specified Road construction cost credited to Purchaser pursuant to this Subsection may be refunded or transferred at the request of Purchaser. However, if Purchaser has outstanding debt owing the United States, Contracting Officer must apply the amount of credit that could be refunded to the debt owed in accordance with the Debt Collection Improvement Act of 1996, as amended. Upon written notice from Contracting Officer that the basis for the delay or interruption no longer exists, Purchaser shall pay for timber a per unit amount, in addition to Current Contract Rates, that is equal to the amount credited to Purchaser’s Timber Sale Account divided by 80 percent of the estimated remaining volume of the contract, until the full amount credited to Purchaser has been returned.
Please see the current Washtenaw Community College catalog for up-to-date program requirements Secondary / Post-Secondary Program Alignment Welding HIGH SCHOOL COURSE SEQUENCE 9th Grade 10th Grade 11th Grade 12th Grade English 9 Algebra I World History/Geography Biology World Language Phys Ed/Health English 10 Geometry U.S. History/Geography Physics or Chemistry World Language Visual/Performing/Applied Arts English 11 Algebra II Civics/Economics Welding English 12 Math Credit Science Credit Welding WASHTENAW COMMUNITY COLLEGE Welding Associate in Applied Science Semester 1 Math Elective(s)* 3 WAF 105 Introduction to Welding Processes 2 WAF 111 Oxy-fuel Welding 4 WAF 112 Shielded Metal Arc Welding 4 Semester Total 13 Semester 2 Speech Elective(s) 3 WAF 106 Blueprint Reading for Welders 3 WAF 123 Advanced Oxy-fuel Welding 4 WAF 124 Advanced Shielded Metal Arc Welding 4 Semester Total 14 Semester 3 Arts/Human. Elective(s) 3 Computer Lit. Elective(s) 3 WAF 215 Advanced Gas Tungsten Arc Welding 4 WAF 288 Gas Metal Arc Welding 4 Semester Total 14 Semester 4 WAF 200 Layout Theory Welding 3 WAF 210 Welding Metallurgy 3 Soc. Sci. Elective(s) 3 WAF 226 Specialized Welding Procedures 4 Semester Total 13 Semester 5 Nat. Sci. Elective(s) 4 WAF 227 Basic Fabrication 3 WAF 229 Shape Cutting Operations 3 Writing Elective(s) 3 Semester Total 13 Program Totals 67
Payment of Project Activities County will reimburse Subrecipient for eligible project-related costs only. Subrecipient shall submit requests for reimbursement to County on a monthly basis beginning on August 1, 2021, and must provide adequate documentation as required by County in accordance with the OC Community Resources Contract Reimbursement Policy, as set forth in Exhibit 1, attached hereto and incorporated herein by reference. In addition, Subrecipient will provide a progress Grantee Performance Report (“GPR Information Form”) for the time period covered, as prescribed by County. Failure to provide any of the required documentation and reporting will cause County to withhold all or a portion of a request for reimbursement, or return the entire reimbursement package to Subrecipient, until such documentation and reporting has been received and approved by County.
TERMINATION FOR NON-ADHERENCE OF COUNTY LOBBYIST ORDINANCE The Contractor, and each County Lobbyist or County Lobbying firm as defined in County Code Section 2.160.010 retained by the Contractor, shall fully comply with the County’s Lobbyist Ordinance, County Code Chapter
DEVELOPMENT OR ASSISTANCE IN DEVELOPMENT OF SPECIFICATIONS REQUIREMENTS/ STATEMENTS OF WORK Firms and/or individuals that assisted in the development or drafting of the specifications, requirements, statements of work, or solicitation documents contained herein are excluded from competing for this solicitation. This shall not be applicable to firms and/or individuals providing responses to a publicly posted Request for Information (RFI) associated with a solicitation.
Payment of Project Costs The Grantee agrees that it will provide for payment of its full share of Project costs and that all costs connected with the Project will be paid by the Grantee on a timely basis.
Treatment of Passthru Payments and Gross Proceeds The Parties are committed to work together, along with Partner Jurisdictions, to develop a practical and effective alternative approach to achieve the policy objectives of foreign passthru payment and gross proceeds withholding that minimizes burden.
