Common use of Furnished Information Marked with Restrictive Legends Clause in Contracts

Furnished Information Marked with Restrictive Legends. When clause G52.209- 008 is used, additional non-disclosure, confidentiality, proprietary information, or similar agreement may be required by the owner of the business data, but only on an exception basis, e.g., when such third party is or may be a direct competitor of the owner of the technical data or computer software. In the event an additional agreement is deemed necessary, the Contracting Officer shall be notified prior to its execution. (i) The Government and contractor agree to cooperate to ensure that execution of any additional agreements shall not delay or inhibit performance of this contract. Such agreements shall not otherwise restrict any rights due the Government under this contract; (d)

Furnished Information Marked with Restrictive Legends. When clause G52.209- G52.209-008 is used, additional non-non- disclosure, confidentiality, proprietary information, or similar agreement agreements may be required by the owner of the business datatechnical data or computer software, but only on an exception basis, e.g., when such third party is or may be a direct competitor of the owner of the technical data or computer software. In the event an additional agreement is deemed necessary, the Contracting Officer shall be notified prior to its execution. (iD) The Government and contractor agree to cooperate to ensure that execution of any additional agreements shall not delay or inhibit performance of this contract. Such agreements shall not otherwise restrict any rights due the Government under this contract; (d)E) The Government shall not permit the recipient to decompile, disassemble,