STANDARD CLAUSES FOR NYS CONTRACTS The parties to the attached contract, license, lease, amendment or other agreement of any kind (hereinafter, "the contract" or "this contract") agree to be bound by the following clauses which are hereby made a part of the contract (the word "Contractor" herein refers to any party other than the State, whether a contractor, licenser, licensee, lessor, lessee or any other party):
Other Service Contracts The Trustees may authorize the engagement of a principal underwriter, transfer agent, administrator, custodian, and similar service providers.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
CONTINGENT ASSIGNMENT OF SUBCONTRACTS In the event of any suspension or termination of the Construction Contract, Contractor is hereby deemed to have offered to assign to City all its interest in contracts with Subcontractors now or hereafter entered into by Contractor for performance of any part of the Work. The assignment will be effective upon acceptance by City in writing and only as to those contracts which City designates in writing. City may accept, at its sole election, said assignment at any time during the course of the Work and prior to Final Completion in the event of a suspension or termination of Contractor's rights under the Contract Documents. Such assignment is part of the consideration to City for entering into the Contract with Contractor and may not be withdrawn prior to Final Completion.
Performance and Compliance with Contracts and Credit and Collection Policy The Seller shall (and shall cause the Servicer to), at its expense, timely and fully perform and comply with all material provisions, covenants and other promises required to be observed by it under the Contracts related to the Receivables, and timely and fully comply in all material respects with the applicable Credit and Collection Policies with regard to each Receivable and the related Contract.
Tax Service Contract; Flood Certification Contract Each Mortgage Loan is covered by a paid in full, life of loan, tax service contract and a paid in full, life of loan, flood certification contract and each of these contracts is assignable to the Purchaser;
Subcontracting for Medicaid Services Notwithstanding any permitted subcontracting of services to be performed under this Agreement, Party shall remain responsible for ensuring that this Agreement is fully performed according to its terms, that subcontractor remains in compliance with the terms hereof, and that subcontractor complies with all state and federal laws and regulations relating to the Medicaid program in Vermont. Subcontracts, and any service provider agreements entered into by Party in connection with the performance of this Agreement, must clearly specify in writing the responsibilities of the subcontractor or other service provider and Party must retain the authority to revoke its subcontract or service provider agreement or to impose other sanctions if the performance of the subcontractor or service provider is inadequate or if its performance deviates from any requirement of this Agreement. Party shall make available on request all contracts, subcontracts and service provider agreements between the Party, subcontractors and other service providers to the Agency of Human Services and any of its departments as well as to the Center for Medicare and Medicaid Services.
Performance and Compliance with Receivables and Contracts At its expense, timely and fully perform and comply with all material provisions, covenants and other promises, if any, required to be observed by the Issuer under the Contracts related to the Receivables.
Price Adjustments for OGS Centralized Contracts Periodic price adjustments will occur no more than twice per year on a schedule to be established solely by OGS. Pricing offered shall be fixed for the first twelve (12) months of the Contract term. Such price increases will only apply to the OGS Centralized Contracts and shall not be applied retroactively to Authorized User Agreements or any Mini-bids already submitted to an Authorized User. Price decreases may be made at any time. Additionally, some price decreases shall be calculated in accordance with Appendix B, section 17, Pricing.
Appointment of Subservicer or Subcontractor (a) The Servicer may at any time appoint a subservicer to perform all or any portion of its obligations as Servicer hereunder; provided, however, that the Servicer shall remain obligated and be liable to the Issuer, the Owner Trustee, the Delaware Trustee, the Indenture Trustee, the Certificateholders and the Noteholders for the servicing and administering of the Receivables in accordance with the provisions hereof without diminution of such obligation and liability by virtue of the appointment of such subservicer and to the same extent and under the same terms and conditions as if the Servicer alone were servicing and administering the Receivables. The fees and expenses of the subservicer shall be as agreed between the Servicer and its subservicer from time to time, and none of the Issuer, the Owner Trustee, the Delaware Trustee, the Indenture Trustee, the Certificateholders or the Noteholders shall have any responsibility therefor.
(b) The Servicer shall cause any Subservicer used by the Servicer (or by any Subservicer) for the benefit of the Issuer to comply with the reporting and compliance provisions of this Agreement to the same extent as if such Subservicer were the Servicer, and to provide the information required with respect to such Subservicer as is required to file all required reports with the Commission. The Servicer shall be responsible for obtaining from each Subservicer and delivering to the Issuer and the Administrator any servicer compliance statement required to be delivered by such Subservicer under Section 3.11, any assessment of compliance and attestation required to be delivered by such Subservicer under Section 3.12 and any certification required to be delivered to the Person that will be responsible for signing the Sarbanes Certification under Section 3.12(a)(iv) as and when required to be delivered.
(c) The Servicer shall promptly upon request provide to the Issuer or the Administrator, acting on behalf of the Issuer, a written description (in form and substance satisfactory to the Issuer and the Administrator) of the role and function of each Subcontractor utilized by the Servicer or any Subservicer, specifying (i) the identity of each such Subcontractor, (ii) which, if any, of such Subcontractors are “participating in the servicing function” within the meaning of Item 1122 of Regulation AB, and (iii) which, if any, elements of the Servicing Criteria will be addressed in assessments of compliance provided by each Subcontractor identified pursuant to clause (ii) of this paragraph. As a condition to the utilization of any Subcontractor determined to be “participating in the servicing function” within the meaning of Item 1122 of Regulation AB, the Servicer shall cause any such Subcontractor used by the Servicer (or by any Subservicer) for the benefit of the Issuer and the Depositor to comply with the reporting and compliance provisions of Section 3.12(a) of this Agreement to the same extent as if such Subcontractor were the Servicer. The Servicer shall be responsible for obtaining from each Subcontractor and delivering to the Issuer and the Administrator any assessment of compliance and attestation required to be delivered by such Subcontractor, in each case as and when required to be delivered.
