Governing Law; Construction This Agreement and any claim, counterclaim or dispute of any kind or nature whatsoever arising out of or in any way relating to this Agreement (“Claim”), directly or indirectly, shall be governed by, and construed in accordance with, the laws of the State of New York. The section headings in this Agreement have been inserted as a matter of convenience of reference and are not a part of this Agreement.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
Governing Law; Severability; Rules of Construction This Security Instrument is governed by federal law and the law of the State of Ohio. All rights and obligations contained in this Security Instrument are subject to any requirements and limitations of Applicable Law. If any provision of this Security Instrument or the Note conflicts with Applicable Law (i) such conflict will not affect other provisions of this Security Instrument or the Note that can be given effect without the conflicting provision, and (ii) such conflicting provision, to the extent possible, will be considered modified to comply with Applicable Law. Applicable Law might explicitly or implicitly allow the parties to agree by contract or it might be silent, but such silence should not be construed as a prohibition against agreement by contract. Any action required under this Security Instrument to be made in accordance with Applicable Law is to be made in accordance with the Applicable Law in effect at the time the action is undertaken. As used in this Security Instrument: (a) words in the singular will mean and include the plural and vice versa; (b) the word “may” gives sole discretion without any obligation to take any action; (c) any reference to “Section” in this document refers to Sections contained in this Security Instrument unless otherwise noted; and (d) the headings and captions are inserted for convenience of reference and do not define, limit, or describe the scope or intent of this Security Instrument or any particular Section, paragraph, or provision.
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians. (ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked. (iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority. (iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.
Certain Matters of Construction The terms “herein,” “hereof,” “hereunder” and other words of similar import refer to this Agreement as a whole and not to any particular section, paragraph or subdivision. Any pronoun used shall be deemed to cover all genders. In the computation of periods of time from a specified date to a later specified date, “from” means “from and including,” and “to” and “until” each mean “to but excluding.” The terms “including” and “include” shall mean “including, without limitation” and, for purposes of each Loan Document, the parties agree that the rule of ejusdem generis shall not be applicable to limit any provision. Section titles appear as a matter of convenience only and shall not affect the interpretation of any Loan Document. All references to (a) laws or statutes include all related rules, regulations, interpretations, amendments and successor provisions; (b) any document, instrument or agreement include any amendments, waivers and other modifications, extensions or renewals (to the extent permitted by the Loan Documents); (c) any section mean, unless the context otherwise requires, a section of this Agreement; (d) any exhibits or schedules mean, unless the context otherwise requires, exhibits and schedules attached hereto, which are hereby incorporated by reference; (e) any Person include successors and assigns; (f) time of day mean time of day at Lenders’ notice addresses under Section 13.3.1; or (g) discretion of any Lender mean the sole and absolute discretion of such Person. All calculations of fundings of the Loans, and payments of Obligations shall be in Dollars and, unless the context otherwise requires, all determinations made from time to time under the Loan Documents shall be made in light of the circumstances existing at such time. Borrowers shall have the burden of establishing any alleged negligence, misconduct or lack of good faith by any Lender under any Loan Documents. No provision of any Loan Documents shall be construed against any party by reason of such party having, or being deemed to have, drafted the provision.
Standard of Care; Reliance on Records and Instructions; Indemnification BISYS shall use its best efforts to ensure the accuracy of all services performed under this Agreement, but shall not be liable to the Trust for any action taken or omitted by BISYS in the absence of bad faith, willful misfeasance, negligence or from reckless disregard by it of its obligations and duties. The Trust agrees to indemnify and hold harmless BISYS, its employees, agents, directors, officers and nominees from and against any and all claims, demands, actions and suits, whether groundless or otherwise, and from and against any and all judgments, liabilities, losses, damages, costs, charges, counsel fees and other expenses of every nature and character arising out of or in any way relating to BISYS' actions taken or nonactions with respect to the performance of services under this Agreement or based, if applicable, upon reasonable reliance on information, records, instructions or requests given or made to BISYS by the Trust, the investment adviser and on any records provided by any fund accountant or custodian thereof; provided that this indemnification shall not apply to actions or omissions of BISYS in cases of its own bad faith, willful misfeasance, negligence or from reckless disregard by it of its obligations and duties; and further provided that prior to confessing any claim against it which may be the subject of this indemnification, BISYS shall give the Trust written notice of and reasonable opportunity to defend against said claim in its own name or in the name of BISYS.
EVENTS CONSTITUTING MATERIAL BREACH OF AGREEMENT The Applicant shall be in Material Breach of this Agreement if it commits one or more of the following acts or omissions (each a “Material Breach”): A. The Application, any Application Supplement, or any Application Amendment on which this Agreement is approved is determined to be inaccurate as to any material representation, information, or fact or is not complete as to any material fact or representation or such application; B. The Applicant failed to complete Qualified Investment as required by Section 2.5.A. of this Agreement during the Qualifying Time Period; C. The Applicant failed to create and maintain the number of New Qualifying Jobs required by the Act; D. The Applicant failed to create and maintain the number of New Qualifying Jobs specified in Schedule C of the Application; E. The Applicant failed to pay at least the average weekly wage of all jobs in the county in which the jobs are located for all New Non-Qualifying Jobs created by the Applicant; F. The Applicant failed to provide payments to the District sufficient to protect future District revenues through payment of revenue offsets and other mechanisms as more fully described in Article IV of this Agreement; G. The Applicant failed to provide the payments to the District that protect the District from the payment of extraordinary education-related expenses related to the project to the extent and in the amounts that the Applicant agreed to provide such payments in Article V of this Agreement; H. The Applicant failed to provide the Supplemental Payments to the extent and in the amounts that the Applicant agreed to provide such Supplemental Payments in Article VI of this Agreement; I. The Applicant failed to create and Maintain Viable Presence on or with the Qualified Property as more fully specified in Article VIII of this Agreement; J. The Applicant failed to submit the reports required to be submitted by Section 8.2 to the satisfaction of the Comptroller; K. The Applicant failed to provide the District or the Comptroller with all information reasonably necessary for the District or the Comptroller to determine whether the Applicant is in compliance with its obligations, including, but not limited to, any employment obligations which may arise under this Agreement; L. The Applicant failed to allow authorized employees of the District, the Comptroller, the Appraisal District, or the State Auditor’s Office to have access to the Applicant’s Qualified Property or business records in order to inspect the project to determine compliance with the terms hereof or as necessary to properly appraise the Taxable Value of the Applicant’s Qualified Property under Sections 8.5 and 8.6; M. The Applicant failed to comply with a request by the State Auditor’s office to review and audit the Applicant’s compliance with this Agreement; N. The Applicant has made any payments to the District or to any other person or persons in any form for the payment or transfer of money or any other thing of value in recognition of, anticipation of, or consideration for this Agreement for limitation on Appraised Value made pursuant to Chapter 313 of the TEXAS TAX CODE, in excess of the amounts set forth in Articles IV, V and VI of this Agreement; O. The Applicant failed to comply with the conditions included in the certificate for limitation issued by the Comptroller.
Waiver of Rule of Construction Each Party has had the opportunity to consult with counsel in connection with the review, drafting and negotiation of this Agreement. Accordingly, the rule of construction that any ambiguity in this Agreement shall be construed against the drafting Party shall not apply.
Interpretation and Rules of Construction In this Agreement, except to the extent otherwise provided or that the context otherwise requires: (a) when a reference is made in this Agreement to an Article, Section, Exhibit or Schedule, such reference is to an Article or Section of, or an Exhibit or Schedule to, this Agreement unless otherwise indicated; (b) the table of contents and headings for this Agreement are for reference purposes only and do not affect in any way the meaning or interpretation of this Agreement; (c) whenever the words “include,” “includes” or “including” are used in this Agreement, they are deemed to be followed by the words “without limitation”; (d) the words “hereof,” “herein” and “hereunder” and words of similar import, when used in this Agreement, refer to this Agreement as a whole and not to any particular provision of this Agreement; (e) all terms defined in this Agreement have the defined meanings when used in any certificate or other document made or delivered pursuant hereto, unless otherwise defined therein; (f) the definitions contained in this Agreement are applicable to the singular as well as the plural forms of such terms; (g) references to a Person are also to its successors and permitted assigns; and (h) the use of “or” is not intended to be exclusive unless expressly indicated otherwise.
Terms of AAU; Certain Definitions; Construction Each AAU will relate to an Offering, and will identify: (i) the securities to be offered in the Offering (the “Securities”), their principal terms, the issuer or issuers (each, an “Issuer”) and any guarantor (each, a “Guarantor”) thereof, and, if different from the Issuer, the seller or sellers (each, a “Seller”) of the Securities, (ii) the underwriting agreement, purchase agreement, standby underwriting agreement, distribution agreement, or similar agreement (as identified in such AAU and as amended or supplemented, including a terms agreement or pricing agreement pursuant to any of the foregoing, collectively, the “Underwriting Agreement”) providing for the purchase, on a several and not joint basis, of the Securities by the several underwriters, initial purchasers, or others acting in a similar capacity (the “Underwriters”) on whose behalf the Manager (as defined below) executes the Underwriting Agreement, and whether such agreement provides for: (x) an option to purchase Additional Securities (as defined below) to cover sales of shares in excess of the number of Firm Securities (as defined below), or (y) an offering in multiple jurisdictions or markets involving two or more syndicates (an “International Offering”), each of which will offer and sell Securities subject to such restrictions as may be specified in any Intersyndicate Agreement (as defined below) referred to in such AAU, (iii) the price at which the Securities are to be purchased by the several Underwriters from any Issuer or Seller thereof (the “Purchase Price”), (iv) the offering terms, including, if applicable, the price or prices at which the Securities initially will be offered by the Underwriters (the “Offering Price”), any selling concession to dealers (the “Selling Concession”), reallowance (the “Reallowance”), management fee, global coordinators’ fee, praecipium, or other similar fees, discounts, or commissions (collectively, the “Fees and Commissions”) with respect to the Securities, and (v) other principal terms of the Offering, which may include, without limitation: (A) the proposed or actual pricing date (“Pricing Date”) and settlement date (the “Settlement Date”), (B) any contractual restrictions on the offer and sale of the Securities pursuant to the Underwriting Agreement, Intersyndicate Agreement, or otherwise, (C) any co-managers for such Offering (the “Co-Managers”), (D) your proposed participation in the Offering, and (E) any trustee, fiscal agent, or similar agent (the “Trustee”) for the indenture, trust agreement, fiscal agency agreement, or similar agreement (the “Indenture”) under which such Securities will be issued.
