GRANT OF LICENSE AND LIMITATIONS License to Use the Licensed Software. In accordance with the terms and conditions hereof, the Licensor agrees to grant to Bianfeng Networking a license to install and operate the Licensed Software on the Designated Computers and to grant to its customers the right to use such software system.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
RELEASE OF GENERAL INFORMATION TO THE PUBLIC AND MEDIA NASA or Partner may, consistent with Federal law and this Agreement, release general information regarding its own participation in this Agreement as desired. Pursuant to Section 841(d) of the NASA Transition Authorization Act of 2017, Public Law 115-10 (the "NTAA"), NASA is obligated to publicly disclose copies of all agreements conducted pursuant to NASA's 51 U.S.C. §20113(e) authority in a searchable format on the NASA website within 60 days after the agreement is signed by the Parties. The Parties acknowledge that a copy of this Agreement will be disclosed, without redactions, in accordance with the NTAA.
Certification Regarding Prohibition of Boycotting Israel (Tex Gov. Code 2271)
Limitation on Out-of-State Litigation - Texas Business and Commerce Code § 272 This is a requirement of the TIPS Contract and is non-negotiable. Texas Business and Commerce Code § 272 prohibits a construction contract, or an agreement collateral to or affecting the construction contract, from containing a provision making the contract or agreement, or any conflict arising under the contract or agreement, subject to another state’s law, litigation in the courts of another state, or arbitration in another state. If included in Texas construction contracts, such provisions are voidable by a party obligated by the contract or agreement to perform the work. By submission of this proposal, Vendor acknowledges this law and if Vendor enters into a construction contract with a Texas TIPS Member under this procurement, Vendor certifies compliance.
Ownership and License in Deliverables Unless otherwise specified in a specific Purchase Order concerning procurement of a SaaS product:
Vendor’s Specific Warranties, Terms, and License Agreements Because TIPS serves public entities and non-profits throughout the nation all of which are subject to specific laws and policies of their jurisdiction, as a matter of standard practice, TIPS does not typically accept a Vendor’s specific “Sale Terms” (warranties, license agreements, master agreements, terms and conditions, etc.) on behalf of all TIPS Members. TIPS may permit Vendor to attach those to this Agreement to display to interested customers what terms may apply to their Supplemental Agreement with Vendor (if submitted by Vendor for that purpose). However, unless this term of the Agreement is negotiated and modified to state otherwise, those specific Sale Terms are not accepted by TIPS on behalf of all TIPS Members and each Member may choose whether to accept, negotiate, or reject those specific Sale Terms, which must be reflected in a separate agreement between Vendor and the Member in order to be effective.
License of Data; Warranty; Termination of Rights A. The valuation information and evaluations being provided to the Trust by USBFS pursuant hereto (collectively, the “Data”) are being licensed, not sold, to the Trust. The Trust has a limited license to use the Data only for purposes necessary to valuing the Trust’s assets and reporting to regulatory bodies (the “License”). The Trust does not have any license nor right to use the Data for purposes beyond the intentions of this Agreement including, but not limited to, resale to other users or use to create any type of historical database. The License is non-transferable and not sub-licensable. The Trust’s right to use the Data cannot be passed to or shared with any other entity. The Trust acknowledges the proprietary rights that USBFS and its suppliers have in the Data.
B. THE TRUST HEREBY ACCEPTS THE DATA AS IS, WHERE IS, WITH NO WARRANTIES, EXPRESS OR IMPLIED, AS TO MERCHANTABILITY OR FITNESS FOR ANY PURPOSE OR ANY OTHER MATTER.
C. USBFS may stop supplying some or all Data to the Trust if USBFS’s suppliers terminate any agreement to provide Data to USBFS. Also, USBFS may stop supplying some or all Data to the Trust if USBFS reasonably believes that the Trust is using the Data in violation of the License, or breaching its duties of confidentiality provided for hereunder, or if any of USBFS’s suppliers demand that the Data be withheld from the Trust. USBFS will provide notice to the Trust of any termination of provision of Data as soon as reasonably possible.
CERTIFICATION PROHIBITING DISCRIMINATION AGAINST FIREARM AND AMMUNITION INDUSTRIES (Texas law as of September 1, 2021) By submitting a proposal to this Solicitation, you certify that you agree, when it is applicable, to the following required by Texas law as of September 1, 2021: If (a) company is not a sole proprietorship; (b) company has at least ten (10) full-time employees; (c) this contract has a value of at least $100,000 that is paid wholly or partly from public funds; (d) the contract is not excepted under Tex. Gov’t Code § 2274.003 of SB 19 (87th leg.); and (e) governmental entity has determined that company is not a sole-source provider or governmental entity has not received any bids from a company that is able to provide this written verification, the following certification shall apply; otherwise, this certification is not required. Pursuant to Tex. Gov’t Code Ch. 2274 of SB 19 (87th session), the company hereby certifies and verifies that the company, or association, corporation, partnership, joint venture, limited partnership, limited liability partnership, or limited liability company, including a wholly owned subsidiary, majority-owned subsidiary parent company, or affiliate of these entities or associations, that exists to make a profit, does not have a practice, policy, guidance, or directive that discriminates against a firearm entity or firearm trade association and will not discriminate during the term of this contract against a firearm entity or firearm trade association. For purposes of this contract, “discriminate against a firearm entity or firearm trade association” shall mean, with respect to the entity or association, to: “
(1) refuse to engage in the trade of any goods or services with the entity or association based solely on its status as a firearm entity or firearm trade association; (2) refrain from continuing an existing business relationship with the entity or association based solely on its status as a firearm entity or firearm trade association; or (3) terminate an existing business relationship with the entity or association based solely on its status as a firearm entity or firearm trade association. See Tex. Gov’t Code § 2274.001(3) of SB 19. “Discrimination against a firearm entity or firearm trade association” does not include: “
(1) the established policies of a merchant, retail seller, or platform that restrict or prohibit the listing or selling of ammunition, firearms, or firearm accessories; and (2) a company’s refusal to engage in the trade of any goods or services, decision to refrain from continuing an existing business relationship, or decision to terminate an existing business relationship to comply with federal, state, or local law, policy, or regulations or a directive by a regulatory agency, or for any traditional business reason that is specific to the customer or potential customer and not based solely on an entity’s or association’s status as a firearm entity or firearm trade association.” See Tex. Gov’t Code § 2274.001(3) of SB 19.
RESERVATION OF RIGHTS AND OWNERSHIP PFU or its suppliers own the title, copyright, and other intellectual property rights in the Software. The Software is protected by copyright and other intellectual property laws and treaties. Except as expressly stated herein, this XXXX does not grant you any intellectual property rights in the Software. All rights not expressly granted are reserved by PFU and its suppliers.
