Data Confidentiality All data, regardless of form, including originals, images and reproductions, prepared by, obtained by or transmitted to the Professional in connection with this Agreement is confidential, proprietary information owned by NBU. Except as specifically provided in this Agreement, the Professional shall not intentionally disclose data generated in the performance of the Services to any third party without the prior, written consent of NBU.
Staff Confidentiality Any confidential personal information about staff of the Employer, which is directly learned by the Employer in the normal course of business, will be treated as strictly confidential and the Employer will take all reasonable precautions to safeguard it.
RPS Confidentiality Notwithstanding Section 10.7(a) of this Agreement, at any time on or after the date on which the Buyer makes its advice filing letter seeking CPUC Approval of this Agreement, either Party shall be permitted to disclose the following terms with respect to such Transaction: Party names, the number of bids per company, Project size, resource type, Delivery Term, Project location, Capacity Factor and Contract Capacity, Commercial Operation Date, Expected Initial Energy Delivery Date, Contract Quantity, Delivery Point, and the achievement of Project development Milestones.
Confidentiality of Contractor Information The Contractor acknowledges and agrees that this Contract and any and all Contractor information obtained by the State in connection with this Contract are subject to the State of Vermont Access to Public Records Act, 1 V.S.A. § 315 et seq. The State will not disclose information for which a reasonable claim of exemption can be made pursuant to 1 V.S.A. § 317(c), including, but not limited to, trade secrets, proprietary information or financial information, including any formulae, plan, pattern, process, tool, mechanism, compound, procedure, production data, or compilation of information which is not patented, which is known only to the Contractor, and which gives the Contractor an opportunity to obtain business advantage over competitors who do not know it or use it. The State shall immediately notify Contractor of any request made under the Access to Public Records Act, or any request or demand by any court, governmental agency or other person asserting a demand or request for Contractor information. Contractor may, in its discretion, seek an appropriate protective order, or otherwise defend any right it may have to maintain the confidentiality of such information under applicable State law within three business days of the State’s receipt of any such request. Contractor agrees that it will not make any claim against the State if the State makes available to the public any information in accordance with the Access to Public Records Act or in response to a binding order from a court or governmental body or agency compelling its production. Contractor shall indemnify the State for any costs or expenses incurred by the State, including, but not limited to, attorneys’ fees awarded in accordance with 1 V.S.A. § 320, in connection with any action brought in connection with Contractor’s attempts to prevent or unreasonably delay public disclosure of Contractor’s information if a final decision of a court of competent jurisdiction determines that the State improperly withheld such information and that the improper withholding was based on Contractor’s attempts to prevent public disclosure of Contractor’s information. The State agrees that (a) it will use the Contractor information only as may be necessary in the course of performing duties, receiving services or exercising rights under this Contract; (b) it will provide at a minimum the same care to avoid disclosure or unauthorized use of Contractor information as it provides to protect its own similar confidential and proprietary information; (c) except as required by the Access to Records Act, it will not disclose such information orally or in writing to any third party unless that third party is subject to a written confidentiality agreement that contains restrictions and safeguards at least as restrictive as those contained in this Contract; (d) it will take all reasonable precautions to protect the Contractor’s information; and (e) it will not otherwise appropriate such information to its own use or to the use of any other person or entity. Contractor may affix an appropriate legend to Contractor information that is provided under this Contract to reflect the Contractor’s determination that any such information is a trade secret, proprietary information or financial information at time of delivery or disclosure.
Client Confidentiality Any information about clients of the Employer which is learned by an employee during the course of employment must, as a condition of continued employment, be treated as strictly confidential and each employee is expected to respect this confidentiality and to take all reasonable precautions to safeguard it.
Confidentiality & Proprietary Information The Consultant acknowledges that it will be necessary for the Client to disclose certain confidential and proprietary information to the Consultant in order for the Consultant to perform their duties under this Agreement. The Consultant acknowledges that disclosure to a third (3rd) party or misuse of this proprietary or confidential information would irreparably harm the Client. Accordingly, the Consultant will not disclose or use, either during or after the term of this Agreement, any proprietary or confidential information of the Client without the Client's prior written permission except to the extent necessary to perform the Services on the Client's behalf. Proprietary or confidential information includes, but is not limited to:
SECTION 7 – CONFIDENTIALITY 7.1 Employee shall well and faithfully serve Manitoba and use his best efforts to promote the interests thereof and shall not directly or indirectly disclose the private affairs of Manitoba or any secret of Manitoba, and shall not directly or indirectly use for his own purposes any confidential information which Employee may acquire with respect to Manitoba’s affairs. The restriction on the use of disclosure of information shall be in effect during the terms of the Agreement and at all times thereafter.
INFORMATION AND CONFIDENTIALITY 20.1 Each party recognises that under this Agreement it may receive Confidential Information belonging to the other.
Period of Confidentiality The obligations under this clause 17 continue, notwithstanding the expiry or termination of this Agreement:
Confidentiality and Safeguarding Information 1. Each Party may have access to confidential information made available by the other. The provisions of the Florida Public Records Act, Chapter 119, F.S., and other applicable state and federal laws will govern disclosure of any confidential information received by the State of Florida.
