NOTICE OF THIRD PARTY CLAIMS Pursuant to Public Contract Code Section 9201, District shall provide Contractor timely notification of the receipt of any third-party claim relating to this Contract. District shall be entitled to recover its reasonable costs incurred in providing such notification.
Indemnification for Suits or Claims for Intellectual Property Infringement The Contractor shall indemnify and hold the Owner harmless from any suits or claims of infringement of any patent rights, trademarks or copyrights arising out of any patented, trademarked, or copyrighted materials, methods, or systems used by the Contractor.
Claims Submission We will submit your claims and assist you in any way we reasonably can to help get your claims paid. Your insurance company may need you to supply certain information directly. It is your responsibility to comply with their request. Please be aware that the balance of your claim is your responsibility whether or not your insurance company pays your claim. Your insurance benefit is a contract between you and your insurance company; we are not party to that contract.
RESPONDENT LIABILITY FOR DAMAGE TO GOVERNMENT PROPERTY The Respondent shall be liable for all damages to government-owned, leased, or occupied property and equipment caused by the Respondent and its employees, agents, subcontractors, and suppliers, including any delivery or cartage company, in connection with any performance pursuant to the Contract. The Respondent shall notify the City of Xxxxxx Procurement Manager in writing of any such damage within one (1) calendar day.
Third Party Claims If any Indemnified Party receives notice of the assertion or commencement of any Action made or brought by any Person who is not a party to this Agreement or an Affiliate of a party to this Agreement or a Representative of the foregoing (a “Third-Party Claim”) against such Indemnified Party with respect to which the Indemnifying Party is obligated to provide indemnification under this Agreement, the Indemnified Party shall give the Indemnifying Party reasonably prompt written notice thereof, but in any event not later than thirty (30) calendar days after receipt of such notice of such Third-Party Claim. The failure to give such prompt written notice shall not, however, relieve the Indemnifying Party of its indemnification obligations, except and only to the extent that the Indemnifying Party forfeits rights or defenses by reason of such failure. Such notice by the Indemnified Party shall describe the Third-Party Claim in reasonable detail, shall include copies of all material written evidence thereof and shall indicate the estimated amount, if reasonably practicable, of the Loss that has been or may be sustained by the Indemnified Party. The Indemnifying Party shall have the right to participate in, or by giving written notice to the Indemnified Party, to assume the defense of any Third-Party Claim at the Indemnifying Party’s expense and by the Indemnifying Party’s own counsel, and the Indemnified Party shall cooperate in good faith in such defense. In the event that the Indemnifying Party assumes the defense of any Third-Party Claim, subject to Section 8.03(b), it shall have the right to take such action as it deems necessary to avoid, dispute, defend, appeal or make counterclaims pertaining to any such Third-Party Claim in the name and on behalf of the Indemnified Party. The Indemnified Party shall have the right to participate in the defense of any Third-Party Claim with counsel selected by it subject to the Indemnifying Party’s right to control the defense thereof, provided that the fees and disbursements of such counsel shall be at the expense of the Indemnified Party.
Notice of Potential Claims The Contractor shall not be entitled to additional compensation or to extension of time for (1) any act or failure to act by the County Project Manager or the County, or (2) the happening of any event or occurrence, unless the Contractor has given the County a written Notice of Potential Claim within ten (10) days of the commencement of the act, failure, or event giving rise to the claim, and before final payment by the County. The written Notice of Potential Claim shall set forth the reasons for which the Contractor believes additional compensation or extension of time is due, the nature of the cost involved, and insofar as possible, the amount of the potential claim. Contractor shall keep full and complete daily records of the work performed, labor and material used, and all costs and additional time claimed to be additional.
Defense of Third Party Claims Upon receipt by the Indemnifying Party of a notice from the Indemnified Party with respect to any claim of a third party against the Indemnified Party, for which the Indemnified Party seeks indemnification hereunder, the Indemnifying Party shall have the right to assume the defense of such claim, and the Indemnified Party shall cooperate to the extent reasonably requested by the Indemnifying Party in defense or prosecution thereof and shall furnish such records, information and testimony and attend all such conferences, discovery proceedings, hearings, trials and appeals as may be reasonably requested by the Indemnifying Party in connection therewith. If the Indemnifying Party shall elect to assume the defense of such claim, the Indemnified Party shall have the right to employ its own counsel in any such case, but the fees and expenses of such counsel shall be at the expense of the Indemnified Party. If the Indemnifying Party has assumed the defense of any claim against the Indemnified Party, the Indemnifying Party shall have the right to settle any claim for which indemnification has been sought and is available hereunder; provided that, to the extent that such settlement requires the Indemnified Party to take, or prohibits the Indemnified Party from taking, any action or purports to obligate the Indemnified Party, then the Indemnifying Party shall not settle such claim without the prior written consent of the Indemnified Party, such consent not to be unreasonably withheld, conditioned or delayed. If the Indemnifying Party does not assume the defense of a third party claim and disputes the Indemnified Party’s right to indemnification, the Indemnified Party shall have the right to assume control of the defense of such claim through counsel of its choice, the reasonable costs of which shall be at the Indemnifying Party’s expense in the event that the Indemnified Party’s right of indemnification is ultimately established through settlement, compromise or other legal proceeding. In no circumstance may the Indemnified Party compromise or settle a claim with a third party for which it seeks indemnification from the Indemnifying Party without first obtaining the prior written consent of the Indemnifying Party, such consent not to be unreasonably withheld, conditioned or delayed.
Breach of Contract Claims To the extent that Chapter 2260, Texas Government Code, is applicable to this Agreement and is not preempted by other applicable law, the dispute resolution process provided for in Chapter 2260 and the related rules adopted by the Texas Attorney General pursuant to Chapter 2260, will be used by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor that cannot be resolved in the ordinary course of business. The chief business officer of University will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims. The parties specifically agree (i) neither execution of this Agreement by University nor any other conduct, action or inaction of any representative of University relating to this Agreement constitutes or is intended to constitute a waiver of University’s or the state's sovereign immunity to suit; and (ii) University has not waived its right to seek redress in the courts.
Submission of a Claim 1. A disputing investor may submit a claim referred to in Article 32 (Claim by an Investor of a Member State) at the choice of the disputing investor:
Third Party Claim A Claim where there is (a) a claim, demand, suit or action by a person who is not a Party, (b) a settlement with, judgment by, or liability to, a person who is not a Party, or (c) a fine or penalty imposed by a person who is not a Party.
