Common use of INDEMINIFICATION & LIMITATION OF LIABILITY Clause in Contracts

INDEMINIFICATION & LIMITATION OF LIABILITY. Neither party shall be liable for any delay or failure in performance beyond its control resulting from acts of God or force majeure. The parties shall use reasonable efforts to eliminate or minimize the effect of such events upon performance of their respective duties under Contract. Contractor shall be fully liable for the actions of its agents, employees, partners or subcontractors and shall fully indemnify and save harmless the State and Authorized User from suits, actions, damages and costs of every name and description relating to personal injury and damage to real or personal tangible property caused by Contractor, its agents, employees, partners or subcontractors, without limitation; provided, however, that the Contractor shall not indemnify for that portion of any claim, loss or damage arising hereunder due to the negligent act or failure to act of the State. Contractor will indemnify, defend and hold the State and its Authorized Users harmless, without limitation, from and against any and all damages, expenses (including reasonable attorneys' fees), claims, judgments, liabilities and costs which may be finally assessed against the State in any action for infringement of a United States Letter Patent with respect to the Products furnished, or of any copyright, trademark, trade secret or intellectual property right, provided that the State shall give the Contractor: (i) prompt written notice of any action, claim or threat of infringement suit, or other suit, (ii) the opportunity to take over, settle or defend such action, claim or suit at Contractor's sole expense, and (iii) assistance in the defense of any such action at the expense of Contractor. Where a dispute or claim arises relative to a real or anticipated infringement, the State or Authorized User may require Contractor, at its sole expense, to submit such information and documentation, including formal patent attorney opinions, as the Commissioner shall require. The Contractor shall not be obligated to indemnify that portion of a claim or dispute based upon: i) Authorized User’s unauthorized modification or alteration of a Product; ii) Authorized User’s use of the Product in combination with other products not furnished by Contractor; iii) Authorized User’s use in other than the specified operating conditions and environment. In addition to the foregoing, if the use of any item(s) or part(s) thereof shall be enjoined for any reason or if Contractor believes that it may be enjoined, Contractor shall have the right, at its own expense and sole discretion as the Authorized User’s exclusive remedy to take action in the following order of precedence: (i) to procure for the State the right to continue using such item(s) or part (s) thereof, as applicable; (ii) to modify the component so that it becomes non-infringing equipment of at least equal quality and performance; or

INDEMINIFICATION & LIMITATION OF LIABILITY. Neither party shall be liable for any delay or failure in performance beyond its control resulting from acts of God or force majeure. The parties shall use reasonable efforts to eliminate or minimize the effect of such events upon performance of their respective duties under Contract. Contractor shall be fully liable for the actions of its agents, employees, partners or subcontractors and shall fully indemnify and save harmless the State and Authorized User from suits, actions, damages and costs of every name and description relating to personal injury and damage to real or personal tangible property caused by Contractor, its agents, employees, partners or subcontractors, without limitation; provided, however, that the Contractor shall not indemnify for that portion of any claim, loss or damage arising hereunder due to the negligent act or failure to act of the State. Contractor will indemnify, defend and hold the State and its Authorized Users harmless, without limitation, from and against any and all damages, expenses (including reasonable attorneys' fees), claims, judgments, liabilities and costs which may be finally assessed against the State in any action for infringement of a United States Letter Patent with respect to the Products furnished, or of any copyright, trademark, trade secret or intellectual property right, provided that the State shall give the Contractor: : (i) prompt written notice of any action, claim or threat of infringement suit, or other suit, (ii) the opportunity to take over, settle or defend such action, claim or suit at Contractor's sole expense, and (iii) assistance in the defense of any such action at the expense of Contractor. Where a dispute or claim arises relative to a real or anticipated infringement, the State or Authorized User may require Contractor, at its sole expense, to submit such information and documentation, including formal patent attorney opinions, as the Commissioner shall require. The Contractor shall not be obligated to indemnify that portion of a claim or dispute based upon: i) Authorized User’s unauthorized modification or alteration of a Product; ii) Authorized User’s use of the Product in combination with other products not furnished by Contractor; iii) Authorized User’s use in other than the specified operating conditions and environment. In addition to the foregoing, if the use of any item(s) or part(s) thereof shall be enjoined for any reason or if Contractor believes that it may be enjoined, Contractor shall have the right, at its own expense and sole discretion as the Authorized User’s exclusive remedy to take action in the following order of precedence: (i) to procure for the State the right to continue using such item(s) or part (s) thereof, as applicable; (ii) to modify the component so that it becomes non-infringing equipment of at least equal quality and performance; or;

INDEMINIFICATION & LIMITATION OF LIABILITY. Neither party shall be liable for any delay or failure in performance beyond its control resulting from acts of God or force majeure. The parties shall use reasonable efforts to eliminate or minimize the effect of such events upon performance of their respective duties under Contract. Contractor shall be fully liable for the actions of its agents, employees, partners or subcontractors and shall fully indemnify and save harmless the State and Authorized User from suits, actions, damages and costs of every name and description relating to personal injury and damage to real or personal tangible property caused by Contractor, its agents, employees, partners or subcontractors, without limitation; provided, however, that the Contractor shall not indemnify for that portion of any claim, loss or damage arising hereunder due to the negligent act or failure to act of the State. Contractor will indemnify, defend and hold the State and its Authorized Users harmless, without limitation, from and against any and all damages, expenses (including reasonable attorneys' fees), claims, judgments, liabilities and costs which may be finally assessed against the State in any action for infringement of a United States Letter Patent with respect to the Products furnished, or of any copyright, trademark, trade secret or intellectual property right, provided that the State shall give the Contractor: : (i) prompt written notice of any action, claim or threat of infringement suit, or other suit, (ii) the opportunity to take over, settle or defend such action, claim or suit at Contractor's sole expense, and (iii) assistance in the defense of any such action at the expense of Contractor. Where a dispute or claim arises relative to a real or anticipated infringement, the State or Authorized User may require Contractor, at its sole expense, to submit such information and documentation, including formal patent attorney opinions, as the Commissioner shall require. The Contractor shall not be obligated to indemnify that portion of a claim or dispute based upon: i) Authorized User’s unauthorized modification or alteration of a Product; ii) Authorized User’s use of the Product in combination with other products not furnished by Contractor; iii) Authorized User’s use in other than the specified operating conditions and environment. In addition to the foregoing, if the use of any item(s) or part(s) thereof shall be enjoined for any reason or if Contractor believes that it may be enjoined, Contractor shall have the right, at its own expense and sole discretion as the Authorized User’s exclusive remedy to take action in the following order of precedence: (i) to procure for the State the right to continue using such item(s) or part (s) thereof, as applicable; (ii) to modify the component so that it becomes non-infringing equipment of at least equal quality and performance; oror (iii) to replace said item(s) or part(s) thereof, as applicable, with non-infringing components of at least equal quality and performance, or (iv) if none of the foregoing is commercially reasonable, then provide monetary compensation to the State up to the dollar amount of the Project Award. For all other claims against the Contractor under any individual Purchase Order where liability is not otherwise set forth in the Contract as being “without limitation”, and regardless of the basis on which the claim is made, Contractor’s liability under a Purchase Order for direct damages shall the greater of $100,000, the dollar amount of the Contract, or two (2) times the charges rendered by the Contractor under the Contract. Unless otherwise specifically enumerated herein or in the work order mutually agreed between the parties, neither party shall be liable to the other for special, indirect or consequential damages, including lost data or records (unless the Contractor is required to back-up the data or records as part of the work plan), even if the party has been advised of the possibility of such damages. Neither party shall be liable for lost profits, lost revenue or lost institutional operating savings. The State and Authorized User may, in addition to other remedies available to them at law or equity and upon notice to the Contractor, retain such monies from amounts due Contractor, or may proceed against the performance and payment bond, if any, as may be necessary to satisfy any claim for damages, penalties, costs and the like asserted by or against them.