Indemnification and Defense 16.1 To the fullest extent permitted by California law, Developer shall indemnify, keep and hold harmless the District, the Architect(s) and Construction Manager(s), their respective consultants, separate contractors, board members, officers, representatives, agents, and employees, in both individual and official capacities (“Indemnitees”), against all suits, claims, injury, damages, losses, and expenses (“Claims”), including but not limited to attorney’s fees and costs, caused by, arising out of, resulting from, or incidental to, in whole or in part, the performance of the Work under this Contract by Developer or its Subcontractors, vendors and/or suppliers. However, Developer’s indemnification and hold harmless obligation shall be reduced by the proportion of the Indemnitees’ and/or Architect’s liability to the extent the Claim(s) is/are caused wholly by the active negligence or willful misconduct of the Indemnitees, and/or defects in design furnished by the Architect, as found by a court or arbitrator of competent jurisdiction. This indemnification and hold harmless obligation of Developer shall not be construed to negate, abridge, or otherwise reduce any right or obligation of indemnity that would otherwise exist or arise as to any Indemnitee or other person described herein. This indemnification and hold harmless obligation includes, but is not limited to, any failure or alleged failure by Developer to comply with any law and/or provision of the Contract Documents in strict accordance with their terms, and without limitation, any failure or alleged failure of Developers obligations regarding any stop payment notice actions or liens, including Civil Wage and Penalty Assessments and/or Orders by the DIR.
16.2 To the furthest extent permitted by California law, Developer shall also defend Indemnitees, at its own expense, including but not limited to attorneys’ fees and costs, against all Claims caused by, arising out of, resulting from, or incidental to, in whole or in part, the performance of the Work under this Facilities Lease by Developer, its Subcontractors, vendors, or suppliers. However, without impacting Developer’s obligation to provide an immediate and ongoing defense of Indemnitees, Developer’s defense obligation shall be reduced by the proportion of the Indemnitees’ and/or Architect’s liability to the extent caused by the sole negligence, active negligence, or willful misconduct of the Indemnitees, and/or defects in design furnished by the Architect, as found by a court or arbitrator of competent jurisdiction. The District shall have the right to accept or reject any legal representation that Xxxxxxxxx proposes to defend the Indemnitees. If any Indemnitee provides its own defense due to failure to timely respond to tender of defense, rejection of tender of defense, or conflict of interest of proposed counsel, Developer shall reimburse such Indemnitee for any expenditures. Developer’s defense obligation shall not be construed to negate, abridge, or otherwise reduce any right or obligation of defense that would otherwise exist as to any Indemnitee or other person described herein. Developer’s defense obligation includes, but is not limited to, any failure or alleged failure by Developer to comply with any provision of law, any failure or alleged failure to timely and properly fulfill all of its obligations under the Contract Documents in strict accordance with their terms, and without limitation, any failure or alleged failure of Developer’s obligations regarding any stop payment notice actions or liens, including Civil Wage and Penalty Assessments and/or Orders by the DIR. Developer shall give prompt notice to the District in the event of any Claim(s).
16.3 Without limitation of the provisions herein, if Xxxxxxxxx’s obligation to indemnify and hold harmless the Indemnitees or its obligation to defend Indemnitees as provided herein shall be determined to be void or unenforceable, in whole or in part, it is the intention of the Parties that these circumstances shall not otherwise affect the validity or enforceability of Developer’s agreement to indemnify, defend, and hold harmless the rest of the Indemnitees, as provided herein. Further, Developer shall be and remain fully liable on its agreements and obligations herein to the fullest extent permitted by law.
Indemnification of Third Party Claims The obligations and liabilities of any party to indemnify any other under this Article 6 with respect to Claims relating to third parties shall be subject to the following terms and conditions:
Indemnification and Contribution (a) The Company agrees to indemnify and hold harmless each Underwriter, the directors, officers, employees, affiliates and agents of each Underwriter, each person who controls any Underwriter within the meaning of either the Act or the Exchange Act and each affiliate of each Underwriter against any and all losses, claims, damages or liabilities, joint or several, to which they or any of them may become subject under the Act, the Exchange Act or other U.S. federal or state statutory law or regulation, at common law or otherwise, insofar as such losses, claims, damages or liabilities (or actions in respect thereof) arise out of or are based upon any untrue statement or alleged untrue statement of a material fact contained in the Registration Statement for the registration of the Securities as originally filed or in any amendment thereof, or in any Preliminary Prospectus, the Prospectus, any “road show” as defined in Section 433(h) of the Act or any Written Testing-the-Waters Communication, or in any amendment thereof or supplement thereto, or arise out of or are based upon the omission or alleged omission to state therein a material fact required to be stated therein or necessary to make the statements therein not misleading, and agrees to reimburse each such indemnified party, as incurred, for any legal or other expenses reasonably incurred by them in connection with investigating or defending any such loss, claim, damage, liability or action; provided, however, that the Company will not be liable in any such case to the extent that any such loss, claim, damage or liability arises out of or is based upon any such untrue statement or alleged untrue statement or omission or alleged omission made therein in reliance upon and in conformity with written information furnished to the Company by or on behalf of any Underwriter through the Representative specifically for inclusion therein, it being understood and agreed that only such information furnished by any Underwriter consists of the information described in the last sentence of Section 8(b) hereof. This indemnity agreement will be in addition to any liability which the Company may otherwise have.
(b) Each Underwriter severally and not jointly agrees to indemnify and hold harmless the Company, each of its directors, each of its executive officers who signs the Registration Statement, and each person who controls the Company within the meaning of either the Act or the Exchange Act, to the same extent as the foregoing indemnity from the Company to each Underwriter, but only with reference to written information relating to such Underwriter furnished to the Company by or on behalf of such Underwriter through the Representative specifically for inclusion in the documents referred to in the foregoing indemnity. This indemnity agreement will be in addition to any liability which any Underwriter may otherwise have. The Company acknowledges that the statements set forth (i) in the last paragraph of the cover page regarding delivery of Securities and (ii) in the section entitled “Underwriting” of the Statutory Prospectus and Prospectus, the last sentence of the third paragraph concerning sales to discretionary accounts and the 11th and 12th paragraphs concerning the purchase and sale of Units in the open market and other stabilizing transactions by the underwriters and penalty bids, constitute the only information furnished in writing by or on behalf of the several Underwriters for inclusion in any Preliminary Prospectus and the Prospectus.
(c) Promptly after receipt by an indemnified party under this Section 8 of notice of the commencement of any action, such indemnified party will, if a claim in respect thereof is to be made against the indemnifying party under this Section 8, notify the indemnifying party in writing of the commencement thereof; but the failure so to notify the indemnifying party (i) will not relieve it from liability under paragraph (a) or (b) above unless and to the extent it did not otherwise learn of such action and such failure results in the forfeiture by the indemnifying party of substantial rights and defenses and (ii) will not, in any event, relieve the indemnifying party from any obligations to any indemnified party other than the indemnification obligation provided in paragraph (a) or (b) above. The indemnifying party shall be entitled to appoint counsel of the indemnifying party’s choice at the indemnifying party’s expense to represent the indemnified party in any action for which indemnification is sought (in which case the indemnifying party shall not thereafter be responsible for the fees and expenses of any separate counsel retained by the indemnified party or parties except as set forth below); provided, however, that such counsel shall be satisfactory to the indemnified party. Notwithstanding the indemnifying party’s election to appoint counsel to represent the indemnified party in an action, the indemnified party shall have the right to employ separate counsel (including local counsel), and the indemnifying party shall bear the reasonable fees, costs and expenses of such separate counsel if (i) the use of counsel chosen by the indemnifying party to represent the indemnified party would present such counsel with a conflict of interest, (ii) the actual or potential defendants in, or targets of, any such action include both the indemnified party and the indemnifying party and the indemnified party shall have reasonably concluded that there may be legal defenses available to it and/or other indemnified parties which are different from or additional to those available to the indemnifying party, (iii) the indemnifying party shall not have employed counsel satisfactory to the indemnified party to represent the indemnified party within a reasonable time after notice of the institution of such action or (iv) the indemnifying party shall authorize the indemnified party to employ separate counsel at the expense of the indemnifying party. An indemnifying party will not, without the prior written consent of the indemnified parties, settle or compromise or consent to the entry of any judgment with respect to any pending or threatened claim, action, suit or proceeding in respect of which indemnification or contribution may be sought hereunder (whether or not the indemnified parties are actual or potential parties to such claim or action) unless such settlement, compromise or consent (i) includes an unconditional release of each indemnified party from all liability arising out of such claim, action, suit or proceeding and (ii) does not include a statement as to or an admission of fault, culpability or a failure to act, by or on behalf of any indemnified party.
(d) In the event that the indemnity provided in paragraph (a) or (b) of this Section 8 is unavailable to or insufficient to hold harmless an indemnified party for any reason, the Company and the Underwriters severally agree to contribute to the aggregate losses, claims, damages and liabilities (including legal or other expenses reasonably incurred in connection with investigating or defending the same) (collectively, “Losses”) to which the Company and one or more of the Underwriters may be subject in such proportion as is appropriate to reflect the relative benefits received by the Company on the one hand and by the Underwriters on the other from the Offering. If the allocation provided by the immediately preceding sentence is unavailable for any reason, the Company and the Underwriters severally shall contribute in such proportion as is appropriate to reflect not only such relative benefits but also the relative fault of the Company on the one hand and of the Underwriters on the other in connection with the statements or omissions which resulted in such Losses as well as any other relevant equitable considerations. Benefits received by the Company shall be deemed to be equal to the total net proceeds from the Offering (before deducting expenses) received by it, and benefits received by the Underwriters shall be deemed to be equal to the total underwriting discounts and commissions actually received by the Underwriters, in each case as set forth on the cover page of the Prospectus. Relative fault shall be determined by reference to, among other things, whether any untrue or any alleged untrue statement of a material fact or the omission or alleged omission to state a material fact relates to information provided by the Company on the one hand or the Underwriters on the other, the intent of the parties and their relative knowledge, access to information and opportunity to correct or prevent such untrue statement or omission. The Company and the Underwriters agree that it would not be just and equitable if contribution were determined by pro rata allocation or any other method of allocation which does not take account of the equitable considerations referred to above. Notwithstanding the provisions of this paragraph (d), in no event shall an Underwriter be required to contribute any amount in excess of the amount by which the total underwriting discounts and commissions received by such Underwriter with respect to the Offering exceeds the amount of any damages that such Underwriter has otherwise been required to pay by reason of such untrue or alleged untrue statement or omission or alleged omission. Notwithstanding the provisions of this paragraph (d), no person guilty of fraudulent misrepresentation (within the meaning of Section 11(f) of the Securities Act) shall be entitled to contribution from any person who was not guilty of such fraudulent misrepresentation. For purposes of this Section 8, each person who controls an Underwriter within the meaning of either the Securities Act or the Exchange Act and each director, officer, employee, affiliate and agent of an Underwriter shall have the same rights to contribution as such Underwriter, and each person who controls the Company within the meaning of either the Securities Act or the Exchange Act, each officer of the Company who shall have signed the Registration Statement and each director of the Company shall have the same rights to contribution as the Company, subject in each case to the applicable terms and conditions of this paragraph (d). The Underwriters’ obligations to contribute pursuant to this Section 8 are several in proportion to their respective purchase obligations hereunder and are not joint.
Indemnification of NCPS From and at all times after the date of this Escrow Agreement, Issuer shall, to the fullest extent permitted by law, defend, indemnify and hold harmless NCPS and each director, officer, employee, attorney, agent and affiliate of NCPS (collectively, the “Indemnified Parties”) against any and all actions, claims (whether or not valid), losses, damages, liabilities, costs and expenses of any kind or nature whatsoever (including without limitation reasonable attorneys’ fees, costs and expenses) incurred by or asserted against any of the Indemnified Parties from and after the date hereof, whether direct, indirect or consequential, as a result of or arising from or in any way relating to any claim, demand, suit, action or proceeding (including any inquiry or investigation) by any person, including without limitation Issuer and Broker whether threatened or initiated, asserting a claim for any legal or equitable remedy against any person under any statute or regulation, including, but not limited to, any federal or state securities laws, or under any common law or equitable cause or otherwise, arising from or in connection with the negotiation, preparation, execution, performance or failure of performance of this Escrow Agreement or any transactions contemplated herein, whether or not any such Indemnified Party is a party to any such action, proceeding, suit or the target of any such inquiry or investigation; provided, however, that no Indemnified Party shall have the right to be indemnified hereunder for any liability finally determined by a court of competent jurisdiction, subject to no further appeal, to have resulted from the gross negligence or willful misconduct of such Indemnified Party. Each Indemnified Party shall, in its sole discretion, have the right to select and employ separate counsel with respect to any action or claim brought or asserted against it, and the reasonable fees of such counsel shall be paid upon demand by the Issuer. The obligations of Issuer under this Section 9 shall survive any termination of this Escrow Agreement and the resignation or removal of NCPS.
Indemnification; Third Party Claims The Master Servicer agrees to indemnify the Depositor, the Sponsor and the Trustee, and their respective officers, directors, agents and affiliates, and hold each of them harmless against any and all claims, losses, penalties, fines, forfeitures, reasonable legal fees and related costs, judgments, and any other costs, liability, fees and expenses that the Depositor, the Sponsor or the Trustee may sustain as a result of (a) any material breach by the Master Servicer of any if its obligations hereunder, including particularly its obligations to provide any reports under Section 9.25(a), Section 9.25(b), Section 9.26 or any information, data or materials required to be included in any Exchange Act report, (b) any material misstatement or omission in any information, data or materials provided by the Master Servicer, or (c) the negligence, bad faith or willful misconduct of the Master Servicer in connection with its performance hereunder, provided, however, that in no event shall the Master Servicer be liable for any special, consequential, indirect or punitive damages pursuant to this Section 9.31, even if advised of the possibility of such damages. The Depositor, the Sponsor and the Trustee shall immediately notify the Master Servicer if a claim is made by a third party with respect to this Agreement or the Mortgage Loans entitling the Depositor, the Sponsor or the Trustee to indemnification hereunder, whereupon the Master Servicer shall assume the defense of any such claim and pay all expenses in connection therewith, including counsel fees, and promptly pay, discharge and satisfy any judgment or decree which may be entered against it or them in respect of such claim. Notwithstanding anything to the contrary contained herein, the Master Servicer shall not settle any claim involving any of the other parties hereto without such party’s prior written consent unless such settlement involves a complete and absolute release of such party from any and all liability in connection with such claim. This indemnification shall survive the termination of this Agreement or the termination of the Master Servicer as a party to this Agreement.
Indemnification Procedures for Non-Third Party Claims In the event any Indemnified Party should have an indemnification claim against the Shareholder under this Agreement that does not involve a claim by a third party, the Indemnified Party shall promptly deliver notice of such claim to the Shareholder in writing and in reasonable detail. The failure by any Indemnified Party to so notify the Shareholder shall not relieve the Shareholder from any liability that it may have to such Indemnified Party, except to the extent that the Shareholder has been actually prejudiced by such failure. If the Shareholder does not notify the Indemnified Party within fifteen (15) Business Days following its receipt of such notice that the Shareholder disputes such claim, such claim specified by the Shareholder in such notice shall be conclusively deemed a liability of the Shareholder under this Article VII and the Shareholder shall pay the amount of such liability to the Indemnified Party on demand, or in the case of any notice in which the amount of the claim is estimated, on such later date when the amount of such claim is finally determined. If the Shareholder disputes its liability with respect to such claim in a timely manner, Shareholder and the Indemnified Party shall proceed in good faith to negotiate a resolution of such dispute and, if not resolved through negotiations, such dispute shall be submitted to arbitration pursuant to Section 9.9.
Indemnification in Third Party Proceedings Subject to Section 10 below, the Company shall indemnify Indemnitee to the fullest extent permitted by the Code, as the same may be amended from time to time (but, only to the extent that such amendment permits Indemnitee to broader indemnification rights than the Code permitted prior to adoption of such amendment), if Indemnitee is a party to or threatened to be made a party to or otherwise involved in any proceeding, for any and all expenses, actually and reasonably incurred by Indemnitee in connection with the investigation, defense, settlement or appeal of such proceeding.
Indemnification of the QIU Without limitation and in addition to its obligation under the other subsections of this Section 5, the Company agrees to indemnify and hold harmless Odeon, in its capacity as the QIU, its directors, officers, agents, partners, members and employees and each Controlling Person from and against any and all loss, liability, claim, damage and expense, as incurred, arising out of or based upon the QIU’s acting as a “qualified independent underwriter” (within the meaning of Rule 5121 of the Rules of FINRA) in connection with the Offering contemplated by this Agreement, and agrees to reimburse each such indemnified person for any legal or other expense reasonably incurred by them in connection with investigating, defending, settling, compromising or paying any such loss, claim, damage, liability, expense or action; provided, however, that the Company shall not be liable in any such case to the extent that any such loss, claim, damage, liability or expense results from the gross negligence or willful misconduct of the QIU. Notwithstanding the indemnification set forth in this Section 5.1.5, Odeon will undertake liability under Section 11 of the Exchange Act for acting as a qualified independent underwriter in connection with this Offering in compliance with FINRA Rule 5121(f)(12)(C).
Indemnification of TIPS XXXXXX AGREES TO INDEMNIFY, HOLD HARMLESS, AND DEFEND TIPS, TIPS MEMBERS, TIPS officers, TIPS Employees, TIPS Directors, and TIPS Trustees (the “TIPS Indemnitees”) from and against all claims and suits by third-parties for damages, injuries to persons (including death), property damages, losses, expenses, fees, including court costs, attorney’s fees, and expert fees, arising out of or relating to Vendor’s performance under this Agreement (including the performance of Vendor’s officers, employees, agents, Authorized Resellers, subcontractors, licensees, or invitees), regardless of the nature of the cause of action, including without limitation causes of action based upon common, constitutional, or statutory law or based in whole or in part upon allegations of negligent or intentional acts or omissions on the part of Vendor, its officers, employees, agents, Authorized Resellers, subcontractors, licensees, or invitees. NO LIMITATION OF LIABILITY FOR DAMAGES FOR PERSONAL INJURY OR PROPERTY DAMAGE ARE PERMITTED OR AGREED TO BY TIPS. Apart from this indemnification provision requiring indemnification of the TIPS Indemnitees’ attorney’s fees as set forth above, recovery of attorneys’ fees by the prevailing party is authorized only if authorized by Xxx. Educ. Code § 44.032(f).
Indemnification Procedures for Third Party Claims If a claim by a third party (including claims for breaches of fiduciary duties) is made against an Indemnified Party and such Indemnified Party intends to seek indemnity with respect thereto from the Company (in the case of a Purchaser Indemnified Party seeking such indemnity) or the Purchaser (in the case of a Company Indemnified Party seeking indemnity) (each of the Company or the Purchaser, as the case may be, in such capacity, an “Indemnifying Party”), such Indemnified Party shall give notice in writing as promptly as reasonably practicable to such Indemnifying Party of any Proceeding commenced against or by it in respect of which indemnity may be sought hereunder, but failure to so notify such Indemnifying Party shall not relieve such Indemnifying Party from any liability that it may have on account of this Article VI, so long as such failure shall not have materially prejudiced the position of such Indemnifying Party. Upon such notification, the Indemnifying Party shall assume the defense of such Proceeding brought by a third party, and, after such assumption, the Indemnified Party shall not be entitled to reimbursement of any expenses thereafter incurred by it in connection with such Proceeding, except as described below. In any such Proceeding, any Indemnified Party shall have the right to retain its own counsel (including local counsel), but the fees and expenses of such counsel shall be at the expense of such Indemnified Party unless (i) the Indemnifying Party shall have failed to promptly assume and thereafter conduct such defense, (ii) the Indemnifying Party and the Indemnified Party shall have mutually agreed to the contrary, (iii) in the reasonable determination of counsel for the Indemnified Party, representation of such Indemnified Party by counsel obtained by the Indemnifying Party would be inappropriate due to actual or potential conflicting interests between such Indemnified Party and any other party represented by such counsel in such proceeding. No Indemnifying Party, in the defense of a third-party claim, shall, except with the consent of the Indemnified Party, consent to entry of any judgment or enter into any settlement that does not include as an unconditional term thereof the giving by the claimant or plaintiff to such Indemnified Party of a release from all liability in respect of such claim. The Indemnifying Party shall not be liable for any settlement of any Proceeding effected without its written consent (which shall not be unreasonably withheld, delayed or conditioned by such Indemnifying Party), but if settled with such consent or if there be final judgment for the plaintiff, the Indemnifying Party shall indemnify the Indemnified Party from and against any Loss by reason of such settlement or judgment. The Indemnifying Party will advance expenses to an Indemnified Party as reasonably incurred so long as such indemnified party shall have provided the indemnifying party with a written undertaking to reimburse the indemnifying party for all amounts so advanced if it is ultimately determined that the indemnified party is not entitled to indemnification hereunder (which shall include breaches of fiduciary duty if permitted above).
