Intellectual Property Rights and Indemnification Any intellectual property which originates from or is developed by a Party shall remain in the exclusive ownership of that Party. No license in patent, copyright, trademark or trade secret, or other proprietary or intellectual property right now or hereafter owned, controlled or licensable to a Party, is granted to the other Party or shall be implied or arise by estoppel. It is the responsibility of each Party to ensure at its own cost that it has obtained any necessary licenses in relation to intellectual property of third Parties used by it to receive any service or to perform its respective obligations under this Agreement.
Intellectual Property Indemnification by Vendor Procedures Related to Indemnification. In the event that an indemnity obligation arises, Vendor shall pay all amounts set forth in Section 14 and 15 above (including any settlements) and – if it has accepted its indemnity obligation without qualification – control the legal defense to such claim or cause of action, including without limitation attorney selection, strategy, discovery, trial, appeal, and settlement, and TIPS shall, at Vendor’s cost and expense (with respect to reasonable out of pocket costs and expenses incurred by TIPS which shall be reimbursed to TIPS by Vendor), provide all commercially reasonable assistance requested by Vendor. In controlling any defense, Vendor shall ensure that all assertions of governmental immunity and all applicable pleas and defenses shall be promptly asserted.
Intellectual Property Warranty and Indemnification Contractor represents and warrants that any materials or deliverables, including all Deliverable Materials, provided under this Contract are either original, or not encumbered, and do not infringe upon the copyright, trademark, patent or other intellectual property rights of any third party, or are in the public domain. If Deliverable Materials provided hereunder become the subject of a claim, suit or allegation of copyright, trademark or patent infringement, City shall have the right, in its sole discretion, to require Contractor to produce, at Contractor’s own expense, new non-infringing materials, deliverables or works as a means of remedying any claim of infringement in addition to any other remedy available to the City under law or equity. Contractor further agrees to indemnify, defend, and hold harmless the City, its officers, employees and agents from and against any and all claims, actions, costs, judgments or damages, of any type, alleging or threatening that any Deliverable Materials, supplies, equipment, services or works provided under this contract infringe the copyright, trademark, patent or other intellectual property or proprietary rights of any third party (Third Party Claim of Infringement). If a Third Party Claim
Intellectual Property Indemnification Supplier agrees to defend, indemnify, and hold harmless DXC and its affiliates, subsidiaries, assigns, agents, subcontractors, distributors and customers (collectively “Indemnitees”) from and against all claims, losses, demands, fees, damages, liabilities, costs, expenses, obligations, causes of action, suits, or injuries, of any kind or nature, arising from: (i) any claim that Supplier’s Products or Services, or the use, sale or importation of them, infringes any intellectual property right. Without limiting the foregoing, Supplier will pay all costs, damages and expenses (including reasonable attorneys’ fees) incurred by DXC and/or its Indemnitees and will pay any award with respect to any such claim or agreed to in settlement of that claim.
Intellectual Property Infringement Indemnification 1.1 We will defend you against any third party claim(s) that the Tyler Software or Documentation infringes that third party’s patent, copyright, or trademark, or misappropriates its trade secrets, and will pay the amount of any resulting adverse final judgment (or settlement to which we consent). You must notify us promptly in writing of the claim and give us sole control over its defense or settlement. You agree to provide us with reasonable assistance, cooperation, and information in defending the claim at our expense.
1.2 Our obligations under this Section G(1) will not apply to the extent the claim or adverse final judgment is based on your use of the Tyler Software in contradiction of this Agreement, including with non-licensed third parties, or your willful infringement.
1.3 If we receive information concerning an infringement or misappropriation claim related to the Tyler Software, we may, at our expense and without obligation to do so, either: (a) procure for you the right to continue its use; (b) modify it to make it non-infringing; or (c) replace it with a functional equivalent, in which case you will stop running the allegedly infringing Tyler Software immediately. Alternatively, we may decide to litigate the claim to judgment, in which case you may continue to use the Tyler Software consistent with the terms of this Agreement.
1.4 If an infringement or misappropriation claim is fully litigated and your use of the Tyler Software is enjoined by a court of competent jurisdiction, in addition to paying any adverse final judgment (or settlement to which we consent), we will, at our option, either: (a) procure the right to continue its use; (b) modify it to make it non-infringing; or (c) replace it with a functional equivalent. This section provides your exclusive remedy for third party copyright, patent, or trademark infringement and trade secret misappropriation claims.
INTELLECTUAL PROPERTY RIGHTS AND INDEMNITY 42.1 Save as granted under this Framework Agreement, neither the Authority nor the Supplier shall acquire any right, title or interest in the other's Pre-Existing Intellectual Property Rights.
42.2 The Supplier shall ensure and procure that the availability, provision and use of the Services and the performance of the Supplier's responsibilities and obligations hereunder shall not infringe any Intellectual Property Rights of any Third party.
42.3 With respect to the Supplier's obligations under this Framework Agreement, the Supplier warrants and represents that:
42.3.1 it owns, has obtained or shall obtain valid licences for all Intellectual Property Rights that are necessary to perform its obligations under this Framework Agreement and/or any Call-Off Contract which may be entered with the Authority or Other Contracting Bodies and shall maintain the same in full force and effect;
42.3.2 it has and shall continue to take all steps, in accordance with Good Industry Practice, to prevent the introduction, creation or propagation of any disruptive elements (including any virus, worms and/or Trojans, spyware or other malware) into systems, data, software or Authority Confidential Information (held in electronic form (owned by or under the control of, or used by the Authority and/or Other Contracting Bodies;
42.4 The Supplier shall during and after the Term of this Framework Agreement indemnify and keep indemnified the Authority on demand from and against all claims, proceedings, suits, demands, actions, costs, expenses (including legal costs and disbursements on a solicitor and client basis), losses and damages and any other liabilities whatsoever arising from, out of, in respect of or incurred by reason of any infringement or alleged infringement (including the defence of such alleged infringement) of any Intellectual Property Right by the:
42.4.1 availability, provision or use of the Services (or any parts thereof); and
42.4.2 performance of the Supplier's responsibilities and obligations hereunder.
42.5 The Supplier shall promptly notify the Authority if any claim or demand is made or action brought against the Supplier for infringement or alleged infringement of any Intellectual Property Right that may affect the availability, provision or use of the Services (or any deliverables or parts thereof) and/or the performance of the Supplier's responsibilities and obligations hereunder.
42.6 If a claim or demand is made or action brought to which Clauses 42.3 and/or 42.4 may apply, or in the reasonable opinion of the Supplier is likely to be made or brought, the Supplier may (subject to Approval) at its own expense and within a reasonable time either:
42.6.1 modify any or all of the affected Services without reducing the performance and functionality of the same, or substitute alternative services of equivalent performance and functionality for any or all of the affected Services, so as to avoid the infringement or the alleged infringement, provided that the terms herein shall apply mutatis mutandis to such modified or substituted services and such substitution shall not increase the burden on Contracting Bodies to a Call-Off Contract; or
42.6.2 procure a licence to use the Services on terms that are reasonably acceptable to the Authority and in relation to the performance of the Supplier’s responsibilities and obligations hereunder, promptly re-perform those responsibilities and obligations; and
42.7 Subject to full compliance with the Branding Guidance, the Supplier shall be entitled to use the Authority’s logo exclusively in connection with the provision of the Services during the Term and for no other purpose.
Protection of Proprietary Rights 4.1 Right to Use Licensed Products Licensee acknowledges that no right, title, or interest, other than the right to use the Licensed Products, is transferred or granted by this Agreement. Licensee is prohibited from selling, renting, leasing, making available to third parties, and sublicensing the Licensed Products.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable. TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree (Yes) TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes Does Vendor agree? Yes, Vendor agrees (Yes) Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees (Yes)
INDEMNIFICATION RELATING TO THIRD PARTY RIGHTS The Contractor will also indemnify and hold the Authorized Users harmless from and against any and all damages, expenses (including reasonable attorneys' fees), claims, judgments, liabilities and costs that may be finally assessed against the Authorized Users in any action for infringement of a United States Letter Patent, or of any copyright, trademark, trade secret or other third party proprietary right except to the extent such claims arise from the Authorized Users gross negligence or willful misconduct, provided that the State shall give Contractor: (i) prompt written notice of any action, claim or threat of infringement suit, or other suit, (ii) the opportunity to take over, settle or defend such action, claim or suit at Contractor's sole expense, and (iii) assistance in the defense of any such action at the expense of Contractor. If usage shall be enjoined for any reason or if Contractor believes that it may be enjoined, Contractor shall have the right, at its own expense and sole discretion to take action in the following order of precedence: (i) to procure for the Authorized User the right to continue Usage (ii) to modify the service or Product so that Usage becomes non-infringing, and is of at least equal quality and performance; or (iii) to replace said service or Product or part(s) thereof, as applicable, with non-infringing service or Product of at least equal quality and performance. If the above remedies are not available, the parties shall terminate the Contract, in whole or in part as necessary and applicable, provided the Authorized User is given a refund for any amounts paid for the period during which Usage was not feasible. The foregoing provisions as to protection from third party rights shall not apply to any infringement occasioned by modification by the Authorized User of any Product without Contractor’s approval. In the event that an action at law or in equity is commenced against the Authorized User arising out of a claim that the Authorized User's use of the service or Product under the Contract infringes any patent, copyright or proprietary right, and Contractor is of the opinion that the allegations in such action in whole or in part are not covered by the indemnification and defense provisions set forth in the Contract, Contractor shall immediately notify the Authorized User and the Office of the Attorney General in writing and shall specify to what extent Contractor believes it is obligated to defend and indemnify under the terms and conditions of the Contract. Contractor shall in such event protect the interests of the Authorized User and secure a continuance to permit the Authorized User to appear and defend its interests in cooperation with Contractor, as is appropriate, including any jurisdictional defenses the Authorized User may have. This constitutes the Authorized User’s sole and exclusive remedy for patent infringement, or for infringement of any other third party proprietary right.
Intellectual Property Rights and Confidentiality Clauses 3.1 Party A shall have exclusive and proprietary ownership, rights and interests in any and all intellectual properties arising out of or created during the performance of this Agreement, including but not limited to copyrights, patents, patent applications, software, technical secrets, trade secrets and others. Party B shall execute all appropriate documents, take all appropriate actions, submit all filings and/or applications, render all appropriate assistance and otherwise conduct whatever is necessary as deemed by Party A at its sole discretion for the purposes of vesting any ownership, right or interest of any such intellectual property rights in Party A, and/or perfecting the protections for any such intellectual property rights in Party A.
3.2 The Parties acknowledge that the existence and the terms of this Agreement and any oral or written information exchanged between the Parties in connection with the preparation and performance of this Agreement are regarded as confidential information. Each Party shall maintain confidentiality of all such confidential information, and without obtaining the written consent of the other Party, it shall not disclose any relevant confidential information to any third party, except for the information that: (a) is or will be in the public domain (other than through the receiving Party’s unauthorized disclosure); (b) is under the obligation to be disclosed pursuant to the applicable laws or regulations, rules of any stock exchange, or orders of the court or other government authorities; or (c) is required to be disclosed by any Party to its shareholders, directors, employees, legal counsels or financial advisors regarding the transaction contemplated hereunder, provided that such shareholders, directors, employees, legal counsels or financial advisors shall be bound by the confidentiality obligations similar to those set forth in this Section. Disclosure of any confidential information by the shareholders, director, employees of or agencies engaged by any Party shall be deemed disclosure of such confidential information by such Party and such Party shall be held liable for breach of this Agreement.
