INDEMNIFICATION RELATING TO INFRINGEMENT The Contractor will also defend, indemnify and hold the Authorized Users harmless from and against any and all damages, expenses (including reasonable attorneys' fees), claims, judgments, liabilities and costs in any action for infringement of a patent, copyright, trademark, trade secret or other proprietary right provided: a) such claim arises solely out of the Products as supplied by the Contractor, and not out of any modification to the Products made by Authorized User or by someone other than Contractor at the direction of the Authorized User without Contractor’s approval, or by reason of an off-the-shelf component; and b) Authorized User gives Contractor prompt written notice of any such action, claim suit or threat of suit alleging infringement. The Authorized User shall give Contractor the opportunity to take over, settle or defend such action, claim or suit at Contractor's sole expense, and to provide assistance in the defense of any such action, claim or suit at the expense of Contractor. Such indemnity shall only be applicable in the event of claims, judgments, liabilities and/or costs that may be finally assessed against Authorized User in any action for infringement of a patent, or of any copyright, trademark, trade secret or other third party proprietary right except to the extent such claims, judgments, liabilities and/or costs arise solely from the Authorized Users negligent act, failure to act, gross negligence or willful misconduct. If usage of a Product shall be enjoined for any reason or if Contractor believes that it may be enjoined, Contractor shall have the right, at its own expense and sole discretion to take action in the following order of precedence: (i) to procure for the Authorized User the right to continue usage (ii) to modify the service or Product so that usage becomes non-infringing, and is of at least equal quality and performance; or (iii) to replace such Product or parts thereof, as applicable, with non-infringing Product of at least equal quality and performance. If the above remedies are not available, the parties shall terminate the Contract, in whole or in part as necessary and applicable, provided that the Authorized User is given a refund for any amounts paid for the period during which usage was not feasible. In the event that an action at law or in equity is commenced against the Authorized User arising out of a claim that the Authorized User's use of the Product under the Contract infringes any patent, copyright, trademark, trade secret or proprietary right, and Contractor is of the opinion that the allegations in such action in whole or in part are not covered by the indemnification and defense provisions set forth in the Contract, Contractor shall immediately notify the Authorized User and the Office of the Attorney General in writing and shall specify to what extent Contractor believes it is obligated to defend and indemnify under the terms and conditions of the Contract and to what extent it is not so obligated to defend and indemnify. Contractor shall in such event protect the interests of the Authorized User and seek to secure a continuance to permit the Authorized User to appear and defend their interests in cooperation with Contractor, as is appropriate, including any jurisdictional defenses the Authorized User may have. This constitutes the Authorized User’s sole and exclusive remedy for patent infringement, or for infringement of any other third party proprietary right.
Procedures Relating to Indemnification (a) If a claim or demand is made against an Indemnitee, or an Indemnitee shall otherwise learn of an assertion, by any Person who is not a party to this Agreement (or an Affiliate thereof) as to which an Indemnifying Party may be obligated to provide indemnification pursuant to this Agreement (a "Third Party Claim"), such Indemnitee will notify the Indemnifying Party in writing, and in reasonable detail, of the Third Party Claim reasonably promptly after becoming aware of such Third Party Claim; provided, however, that failure to give such notification will not affect the indemnification provided hereunder except to the extent the Indemnifying Party shall have been actually prejudiced as a result of such failure. Thereafter, the Indemnitee will deliver to the Indemnifying Party, promptly after the Indemnitee's receipt thereof, copies of all material notices and documents (including court papers) received or transmitted by the Indemnitee relating to the Third Party Claim.
(b) If a Third Party Claim is made against an Indemnitee, the Indemnifying Party will be entitled to participate in or to assume the defense thereof (in either case, at the expense of the Indemnifying Party) with counsel selected by the Indemnifying Party and reasonably satisfactory to the Indemnitee. Should the Indemnifying Party so elect to assume the defense of a Third Party Claim, the Indemnifying Party will not be liable to the Indemnitee for any legal or other expenses subsequently incurred by the Indemnitee in connection with the defense thereof; provided, that if in the Indemnitee's reasonable judgment a conflict of interest exists in respect of such claim or if the Indemnifying Party shall have assumed responsibility for such claim with any reservations or exceptions, such Indemnitee will have the right to employ separate counsel reasonably satisfactory to the Indemnifying Party to represent such Indemnitee and in that event the reasonable fees and expenses of such separate counsel (but not more than one separate counsel for all Indemnitees similarly situated) shall be paid by such Indemnifying Party. If the Indemnifying Party assumes the defense of any Third Party Claim, the Indemnitee will have the right to participate in the defense thereof and to employ counsel, at its own expense, separate from the counsel employed by the Indemnifying Party, it being understood that the Indemnifying Party will control such defense. The Indemnifying Party will be liable for the fees and expenses of counsel employed by the Indemnitee for any period during which the Indemnifying Party has failed to assume the defense thereof. If the Indemnifying Party assumes the defense of any Third Party Claim, the Indemnifying Party will promptly supply to the Indemnitee copies of all material correspondence and documents relating to or in connection with such Third Party Claim and keep the Indemnitee fully informed of all material developments relating to or in connection with such Third Party Claim (including providing to the Indemnitee on request updates and summaries as to the status thereof). If the Indemnifying Party chooses to defend a Third Party Claim, the parties hereto will cooperate in the defense thereof (such cooperation to be at the expense, including reasonable legal fees and expenses, of the Indemnifying Party), which cooperation shall include the retention in accordance with this Agreement and (upon the Indemnifying Party's request) the provision to the Indemnifying Party of records and information which are reasonably relevant to such Third Party Claim, and making employees available on a mutually convenient basis to provide additional information and explanation of any material provided hereunder.
(c) No Indemnifying Party will consent to any settlement, compromise or discharge (including the consent to entry of any judgment) of any Third Party Claim without the Indemnitee's prior written consent (which consent will not be unreasonably withheld); provided, that if the Indemnifying Party assumes the defense of any Third Party Claim, the Indemnitee will agree to any settlement, compromise or discharge of such Third Party Claim which the Indemnifying Party may recommend and which by its terms obligates the Indemnifying Party to pay the full amount of Indemnifiable Losses in connection with such Third Party Claim and unconditionally and irrevocably releases the Indemnitee and its Affiliates completely from all Liability in connection with such Third Party Claim; provided, however, that the Indemnitee may refuse to agree to any such settlement, compromise or discharge (x) that provides for injunctive or other nonmonetary relief affecting the Indemnitee or any of its Affiliates or (y) that, in the reasonable opinion of the Indemnitee, would otherwise materially adversely affect the Indemnitee or any of its Affiliates. Whether or not the Indemnifying Party shall have assumed the defense of a Third Party Claim, the Indemnitee will not (unless required by law) admit any liability with respect to, or settle, compromise or discharge, such Third Party Claim without the Indemnifying Party's prior written consent (which consent will not be unreasonably withheld).
(d) Any claim on account of Indemnifiable Losses which does not involve a Third Party Claim will be asserted by reasonably prompt written notice given by the Indemnitee to the Indemnifying Party from whom such indemnification is sought. The failure by any Indemnitee so to notify the Indemnifying Party will not relieve the Indemnifying Party from any liability which it may have to such Indemnitee under this Agreement, except to the extent that the Indemnifying Party shall have been actually prejudiced by such failure.
(e) In the event of payment in full by an Indemnifying Party to any Indemnitee in connection with any Third Party Claim, such Indemnifying Party will be subrogated to and shall stand in the place of such Indemnitee as to any events or circumstances in respect of which such Indemnitee may have any right or claim relating to such Third Party Claim against any claimant or plaintiff asserting such Third Party Claim or against any other Person. Such Indemnitee will cooperate with such Indemnifying Party in a reasonable manner, and at the cost and expense of such Indemnifying Party, in prosecuting any subrogated right or claim.
INDEMNIFICATION RELATING TO THIRD PARTY RIGHTS The Contractor will also indemnify and hold the Authorized Users harmless from and against any and all damages, expenses (including reasonable attorneys' fees), claims, judgments, liabilities and costs that may be finally assessed against the Authorized Users in any action for infringement of a United States Letter Patent, or of any copyright, trademark, trade secret or other third party proprietary right except to the extent such claims arise from the Authorized Users gross negligence or willful misconduct, provided that the State shall give Contractor: (i) prompt written notice of any action, claim or threat of infringement suit, or other suit, (ii) the opportunity to take over, settle or defend such action, claim or suit at Contractor's sole expense, and (iii) assistance in the defense of any such action at the expense of Contractor. If usage shall be enjoined for any reason or if Contractor believes that it may be enjoined, Contractor shall have the right, at its own expense and sole discretion to take action in the following order of precedence: (i) to procure for the Authorized User the right to continue Usage (ii) to modify the service or Product so that Usage becomes non-infringing, and is of at least equal quality and performance; or (iii) to replace said service or Product or part(s) thereof, as applicable, with non-infringing service or Product of at least equal quality and performance. If the above remedies are not available, the parties shall terminate the Contract, in whole or in part as necessary and applicable, provided the Authorized User is given a refund for any amounts paid for the period during which Usage was not feasible. The foregoing provisions as to protection from third party rights shall not apply to any infringement occasioned by modification by the Authorized User of any Product without Contractor’s approval. In the event that an action at law or in equity is commenced against the Authorized User arising out of a claim that the Authorized User's use of the service or Product under the Contract infringes any patent, copyright or proprietary right, and Contractor is of the opinion that the allegations in such action in whole or in part are not covered by the indemnification and defense provisions set forth in the Contract, Contractor shall immediately notify the Authorized User and the Office of the Attorney General in writing and shall specify to what extent Contractor believes it is obligated to defend and indemnify under the terms and conditions of the Contract. Contractor shall in such event protect the interests of the Authorized User and secure a continuance to permit the Authorized User to appear and defend its interests in cooperation with Contractor, as is appropriate, including any jurisdictional defenses the Authorized User may have. This constitutes the Authorized User’s sole and exclusive remedy for patent infringement, or for infringement of any other third party proprietary right.
Indemnification of NCPS From and at all times after the date of this Escrow Agreement, Issuer shall, to the fullest extent permitted by law, defend, indemnify and hold harmless NCPS and each director, officer, employee, attorney, agent and affiliate of NCPS (collectively, the “Indemnified Parties”) against any and all actions, claims (whether or not valid), losses, damages, liabilities, costs and expenses of any kind or nature whatsoever (including without limitation reasonable attorneys’ fees, costs and expenses) incurred by or asserted against any of the Indemnified Parties from and after the date hereof, whether direct, indirect or consequential, as a result of or arising from or in any way relating to any claim, demand, suit, action or proceeding (including any inquiry or investigation) by any person, including without limitation Issuer and Broker whether threatened or initiated, asserting a claim for any legal or equitable remedy against any person under any statute or regulation, including, but not limited to, any federal or state securities laws, or under any common law or equitable cause or otherwise, arising from or in connection with the negotiation, preparation, execution, performance or failure of performance of this Escrow Agreement or any transactions contemplated herein, whether or not any such Indemnified Party is a party to any such action, proceeding, suit or the target of any such inquiry or investigation; provided, however, that no Indemnified Party shall have the right to be indemnified hereunder for any liability finally determined by a court of competent jurisdiction, subject to no further appeal, to have resulted from the gross negligence or willful misconduct of such Indemnified Party. Each Indemnified Party shall, in its sole discretion, have the right to select and employ separate counsel with respect to any action or claim brought or asserted against it, and the reasonable fees of such counsel shall be paid upon demand by the Issuer. The obligations of Issuer under this Section 9 shall survive any termination of this Escrow Agreement and the resignation or removal of NCPS.
Indemnification; Remedies The Company shall indemnify the Purchaser, each affiliate of the Purchaser, and each of the following parties participating in a Securitization Transaction: each Sponsor; each issuing entity; each Person (including, but not limited to, any Master Servicer if applicable) responsible for the preparation, execution or filing of any report required to be filed with the Commission with respect to such Securitization Transaction, or for execution of a certification pursuant to Rule 13a-14(d) or Rule 15d-14(d) under the Exchange Act with respect to such Securitization Transaction; each broker dealer acting as underwriter, placement agent or initial purchaser, each Person who controls any of such parties or the Depositor (within the meaning of Section 15 of the Securities Act and Section 20 of the Exchange Act); and the respective present and former directors, officers, employees, agents and affiliates of each of the foregoing and of the Depositor (each, an “Indemnified Party”), and shall hold each of them harmless from and against any claims, losses, damages, penalties, fines, forfeitures, legal fees and expenses and related costs, judgments, and any other costs, fees and expenses that any of them may sustain arising out of or based upon:
(a) (A) any untrue statement of a material fact contained or alleged to be contained in any information, report, certification, accountants’ letter or other material provided in written or electronic format under this Article II by or on behalf of the Company, or provided under this Article II by or on behalf of any Third-Party Originator (collectively, the “Company Information”), or (B) the omission or alleged omission to state in the Company Information a material fact required to be stated in the Company Information or necessary in order to make the statements therein, in the light of the circumstances under which they were made, not misleading; provided, by way of clarification, that clause (B) of this paragraph shall be construed solely by reference to the Company Information and not to any other information communicated in connection with a sale or purchase of securities, without regard to whether the Company Information or any portion thereof is presented together with or separately from such other information;
(b) any breach by the Company of its obligations under this Article II, including particularly any failure by the Company or any Third-Party Originator to deliver any information, report, certification, accountants’ letter or other material when and as required under this Article II;
(c) any breach by the Company of a representation or warranty set forth in Section 2.02(a) or in a writing furnished pursuant to Section 2.02(b) and made as of a date prior to the closing date of the related Securitization Transaction, to the extent that such breach is not cured by such closing date, or any breach by the Company of a representation or warranty in a writing furnished pursuant to Section 2.02(b) to the extent made as of a date subsequent to such closing date, or
(d) the negligence, bad faith or willful misconduct of the Company in connection with its performance under this Article II. If the indemnification provided for herein is unavailable or insufficient to hold harmless an Indemnified Party, then the Company agrees that it shall contribute to the amount paid or payable by such Indemnified Party as a result of any claims, losses, damages or liabilities incurred by such Indemnified Party in such proportion as is appropriate to reflect the relative fault of such Indemnified Party on the one hand and the Company on the other. In the case of any failure of performance described in clause (a)(ii) of this Section, the Company shall promptly reimburse the Purchaser, any Depositor, as applicable, and each Person responsible for the preparation, execution or filing of any report required to be filed with the Commission with respect to such Securitization Transaction, or for execution of a certification pursuant to Rule 13a-14(d) or Rule 15d-14(d) under the Exchange Act with respect to such Securitization Transaction, for all costs reasonably incurred by each such party in order to obtain the information, report, certification, accountants’ letter or other material not delivered as required by the Company or any Third-Party Originator.
(e) This indemnification shall survive the termination of the Agreement or the termination of any party to the Agreement.
Limitation of Liability; Indemnification (a) Funds Management shall not be liable for any error of judgment or mistake of law or for any loss suffered by the Trust in connection with the performance of its obligations and duties under this Agreement, except a loss resulting from Funds Management’s willful misfeasance, bad faith, or negligence in the performance of its obligations and duties or that of its agents or sub-administrators, or by reason of its or their reckless disregard thereof. Any person, even though also an officer, director, employee or agent of Funds Management, shall be deemed, when rendering services to the Trust or acting on any business of the Trust (other than services or business in connection with Funds Management’s duties as Administrator hereunder), to be acting solely for the Trust and not as an officer, director, employee, or agent or one under the control or discretion of Funds Management even though paid by it.
(b) The Trust, on behalf of each Fund, will indemnify Funds Management against and hold it harmless from any and all losses, claims, damages, liabilities, or expenses (including reasonable counsel fees and expenses) resulting from any claim, demand, action, or suit relating to the particular Fund and not resulting from willful misfeasance, bad faith, or negligence of Funds Management or its agents or sub-administrators in the performance of their obligations and duties hereunder, or by reason of its or their reckless disregard thereof. Funds Management will not confess any claim or settle or make any compromise in any instance in which the Trust will be asked to provide indemnification, except with the Trust’s prior written consent. Any amounts payable by the Trust under this Subparagraph shall be satisfied only against the assets of the Fund involved in the claim, demand, action, or suit and not against the assets of any other Fund.
(c) Funds Management will indemnify the Trust against and hold it harmless from any and all losses, claims, damages, liabilities, or expenses (including reasonable counsel fees and expenses) resulting from any claim, demand, action, or suit against the Trust or any Fund that resulted from a failure of Funds Management or its agents to act in accordance with the standard of care set forth in Subparagraph (a) above; provided that such loss, claim, damage, liability or expense did not result primarily from willful misfeasance, bad faith, or negligence of the Trust or its agents (other than Funds Management or agents of Funds Management) in the performance of their obligations and duties, or by reason of its or their reckless disregard thereof. The Trust will not confess any claim or settle or make any compromise in any instance in which Funds Management will be asked to provide indemnification, except with Funds Management’s prior written consent.
Indemnification - General The Company shall indemnify, and advance Expenses (as hereinafter defined) to, Indemnitee (a) as provided in this Agreement and (b) to the fullest extent permitted by applicable law in effect on the date hereof and as amended from time to time. The rights of Indemnitee provided under the preceding sentence shall include, but shall not be limited to, the rights set forth in the other Sections of this Agreement.
Indemnification of TIPS XXXXXX AGREES TO INDEMNIFY, HOLD HARMLESS, AND DEFEND TIPS, TIPS MEMBERS, TIPS officers, TIPS Employees, TIPS Directors, and TIPS Trustees (the “TIPS Indemnitees”) from and against all claims and suits by third-parties for damages, injuries to persons (including death), property damages, losses, expenses, fees, including court costs, attorney’s fees, and expert fees, arising out of or relating to Vendor’s performance under this Agreement (including the performance of Vendor’s officers, employees, agents, Authorized Resellers, subcontractors, licensees, or invitees), regardless of the nature of the cause of action, including without limitation causes of action based upon common, constitutional, or statutory law or based in whole or in part upon allegations of negligent or intentional acts or omissions on the part of Vendor, its officers, employees, agents, Authorized Resellers, subcontractors, licensees, or invitees. NO LIMITATION OF LIABILITY FOR DAMAGES FOR PERSONAL INJURY OR PROPERTY DAMAGE ARE PERMITTED OR AGREED TO BY TIPS. Apart from this indemnification provision requiring indemnification of the TIPS Indemnitees’ attorney’s fees as set forth above, recovery of attorneys’ fees by the prevailing party is authorized only if authorized by Xxx. Educ. Code § 44.032(f).
Indemnification Provisions Contractor agrees to indemnify, defend with counsel approved in writing by County, and hold County, its elected and appointed officials, officers, employees, agents and those special districts and agencies which County’s Board of Supervisors acts as the governing Board (“County Indemnitees”) harmless from any claims, demands or liability of any kind or nature, including but not limited to personal injury or property damage, arising from or related to the services, products or other performance provided by Contractor pursuant to this Contract. If judgment is entered against Contractor and County by a court of competent jurisdiction because of the concurrent active negligence of County or County Indemnitees, Contractor and County agree that liability will be apportioned as determined by the court. Neither party shall request a jury apportionment.
Indemnification Procedure Any party entitled to indemnification under this Article VI (an “indemnified party”) will give written notice to the indemnifying party of any matters giving rise to a claim for indemnification; provided, that the failure of any party entitled to indemnification hereunder to give notice as provided herein shall not relieve the indemnifying party of its obligations under this Article VI except to the extent that the indemnifying party is actually prejudiced by such failure to give notice. In case any action, proceeding or claim is brought against an indemnified party in respect of which indemnification is sought hereunder, the indemnifying party shall be entitled to participate in and, unless in the reasonable judgment of the indemnified party a conflict of interest between it and the indemnifying party may exist with respect of such action, proceeding or claim, to assume the defense thereof with counsel reasonably satisfactory to the indemnified party. In the event that the indemnifying party advises an indemnified party that it will contest such a claim for indemnification hereunder, or fails, within thirty (30) days of receipt of any indemnification notice to notify, in writing, such person of its election to defend, settle or compromise, at its sole cost and expense, any action, proceeding or claim (or discontinues its defense at any time after it commences such defense), then the indemnified party may, at its option, defend, settle or otherwise compromise or pay such action or claim. In any event, unless and until the indemnifying party elects in writing to assume and does so assume the defense of any such claim, proceeding or action, the indemnified party’s costs and expenses arising out of the defense, settlement or compromise of any such action, claim or proceeding shall be losses subject to indemnification hereunder. The indemnified party shall cooperate fully with the indemnifying party in connection with any negotiation or defense of any such action or claim by the indemnifying party and shall furnish to the indemnifying party all information reasonably available to the indemnified party which relates to such action or claim. The indemnifying party shall keep the indemnified party fully apprised at all times as to the status of the defense or any settlement negotiations with respect thereto. If the indemnifying party elects to defend any such action or claim, then the indemnified party shall be entitled to participate in such defense with counsel of its choice at its sole cost and expense. The indemnifying party shall not be liable for any settlement of any action, claim or proceeding effected without its prior written consent. Notwithstanding anything in this Article VI to the contrary, the indemnifying party shall not, without the indemnified party’s prior written consent, settle or compromise any claim or consent to entry of any judgment in respect thereof which imposes any future obligation on the indemnified party or which does not include, as an unconditional term thereof, the giving by the claimant or the plaintiff to the indemnified party of a release from all liability in respect of such claim. The indemnification required by this Article VI shall be made by periodic payments of the amount thereof during the course of investigation or defense, as and when bills are received or expense, loss, damage or liability is incurred, so long as the indemnified party irrevocably agrees to refund such moneys if it is ultimately determined by a court of competent jurisdiction that such party was not entitled to indemnification. The indemnity agreements contained herein shall be in addition to (a) any cause of action or similar rights of the indemnified party against the indemnifying party or others, and (b) any liabilities the indemnifying party may be subject to pursuant to the law.
