Common use of Indemnification; Release Clause in Contracts

Indemnification; Release. (a) Contractor agrees to take all necessary precautions to prevent injury to any persons (including employees of Company) or damage to property (including Company's property) during the term of this Agreement, and shall indemnify, defend and hold harmless Company, its officers, directors, shareholders, employees, representatives and/or agents from any claim, liability, loss, cost, damage, judgment, settlement or expense (including attorney's fees) resulting from or arising in any way out of injury (including death) to any person or damage to property arising in any way out of any act, error, omission or negligence on the part of Contractor or any Contractor Employee in the performance or failure to fulfill any Services or obligations under this Agreement. Contractor further agrees to indemnify, defend and hold harmless Company, its officers, directors, shareholders, employees, representatives and/or agents from the costs to Company of remedying any violation or breach of this Agreement by Contractor and/or from the costs to the Company resulting from a breach by Contractor to a third party during the performance of the Services under this Agreement. (b) Contractor agrees to indemnify and hold the Company harmless from and against any and all claims, losses, demands, liabilities, damages, costs, or expenses (including, without limitation, attorney's fees, back wages, liquidated damages, penalties or interest) resulting from any violation of any federal, state or local law, regulation, or ordinance by Contractor, including, without limitation, Contractor's failure to collect, withhold, or pay any and all federal or state taxes required to be withheld or paid by employers or employees, including, without limitation, any and all income tax, social security, and FUTA taxes. (c) In remedying any violation of this Agreement by Contractor, the Company shall first notify Contractor of the existence of such violation and provide Contractor thirty (30) days in which to remedy the violation at Contractor's expense.

Appears in 2 contracts

Samples: Employment Agreement (Sontra Medical Corp), Independent Contractor Agreement (Sontra Medical Corp)

AutoNDA by SimpleDocs

Indemnification; Release. (a) Contractor Consultant agrees to take all necessary precautions to prevent injury to any persons (including employees of Company) or damage to property (including Company's ’s property) during the term of this Agreement, and shall indemnify, defend and hold harmless Company, its officers, directors, shareholders, employees, representatives and/or agents from any claim, liability, loss, cost, damage, judgment, settlement or expense (including attorney's ’s fees) resulting from or arising in any way out of injury (including death) to any person or damage to property arising in any way out of any act, error, omission or negligence on the part of Contractor Consultant or any Contractor Employee Consultant employee in the performance or failure to fulfill any Services or obligations under this Agreement. Contractor Consultant further agrees to indemnify, defend and hold harmless Company, its officers, directors, shareholders, employees, representatives and/or agents from the costs to Company of remedying any violation or breach of this Agreement by Contractor Consultant and/or from the costs to the Company resulting from a breach by Contractor Consultant to a third party during the performance of the Services under this Agreement. (b) Contractor Consultant agrees to indemnify and hold the Company harmless from and against any and all claims, losses, demands, liabilities, damages, costs, or expenses (including, without limitation, attorney's ’s fees, back wages, liquidated damages, penalties or interest) resulting from any violation of any federal, state or local law, regulation, or ordinance by ContractorConsultant, including, without limitation, Contractor's Consultant’s failure to collect, withhold, or pay any and all federal or state taxes required to be withheld or paid by employers or employees, including, without limitation, any and all income tax, social security, and FUTA taxes. (c) In remedying the event of any violation breach of this Agreement or the Company CDA by ContractorConsultant, the Company shall first notify Contractor Consultant of the existence of such violation breach and provide Contractor Consultant thirty (30) days in which to remedy the breach at Consultant’s expense. Notwithstanding the foregoing, Consultant agrees that any breach of this Agreement or the Company CDA will cause irreparable harm to the Company and that in the event of such breach or threatened breach, Company shall have, in addition to any and all remedies at law and those remedies stated in this Agreement and the Company CDA, the right to an injunction, specific performance, or other equitable relief to prevent violation at Contractor's expenseof Consultant’s obligations hereunder or under the Company CDA.

Appears in 1 contract

Samples: Consulting Agreement (BeyondSpring Inc.)

Indemnification; Release. (a) Contractor Consultant agrees to take all necessary precautions to prevent injury to any persons (including employees of the Company) or damage to property (including the Company's ’s property) during the term of this Agreement, and shall indemnify, defend and hold harmless the Company, its officers, directors, shareholders, employees, representatives and/or agents from any claim, liability, loss, cost, damage, judgment, settlement or expense (including attorney's ’s fees) resulting from or arising in any way out of injury (including death) to any person or damage to property arising in any way out of any act, error, omission or negligence on the part of Contractor Consultant or any Contractor Employee Consultant employee in the performance or failure to fulfill any Services or obligations under this Agreement. Contractor Consultant further agrees to indemnify, defend and hold harmless the Company, its officers, directors, shareholders, employees, representatives and/or agents from the costs to the Company of remedying any violation or breach of this Agreement by Contractor Consultant and/or from the costs to the Company resulting from a breach by Contractor Consultant to a third party during the performance of the Services under this Agreement. (b) Contractor Consultant agrees to indemnify and hold the Company harmless from and against any and all claims, losses, demands, liabilities, damages, costs, or expenses (including, without limitation, attorney's ’s fees, back wages, liquidated damages, penalties or interest) resulting from any violation of any federal, state or local law, regulation, or ordinance by ContractorConsultant, including, without limitation, Contractor's Consultant’s failure to collect, withhold, or pay any and all federal or state taxes required to be withheld or paid by employers or employees, including, without limitation, any and all income tax, social security, and FUTA taxes. (c) In remedying the event of any violation breach of this Agreement or the Company CDA by ContractorConsultant, the Company shall first notify Contractor Consultant of the existence of such violation breach and provide Contractor Consultant thirty (30) days in which to remedy the breach at Consultant’s expense. Notwithstanding the foregoing, Consultant agrees that any breach of this Agreement or the Company CDA will cause irreparable harm to the Company and that in the event of such breach or threatened breach, the Company shall have, in addition to any and all remedies at law and those remedies stated in this Agreement and the Company CDA, the right to an injunction, specific performance, or other equitable relief to prevent violation at Contractor's expenseof Consultant’s obligations hereunder or under the Company CDA.

Appears in 1 contract

Samples: Consulting Agreement (BeyondSpring Inc.)

AutoNDA by SimpleDocs

Indemnification; Release. (a) Contractor Consultant agrees to take all necessary precautions to prevent injury to any persons (including employees of the Company) or damage to property (including the Company's ’s property) as a result of Consultant’s performance of the Services during the term of this Agreement, and shall indemnify, defend and hold harmless the Company, its officers, directors, shareholders, employees, representatives and/or agents from any claim, liability, loss, cost, damage, judgment, settlement or expense (including attorney's ’s fees) resulting from or arising in any way out of injury (including death) to any person or damage to property arising in any way out of any act, error, omission or negligence on the part of Contractor Consultant or any Contractor Employee Consultant employee in the performance or failure to fulfill of any Services or obligations under this Agreement. Contractor Consultant further agrees to indemnify, defend and hold harmless the Company, its officers, directors, shareholders, employees, representatives and/or agents from the costs to the Company of remedying any violation or breach of this Agreement by Contractor Consultant and/or from the costs to the Company resulting from a breach by Contractor Consultant to a third party during the performance of the Services under this Agreement. (b) Contractor Consultant agrees to indemnify and hold the Company harmless from and against any and all claims, losses, demands, liabilities, damages, costs, or expenses (including, without limitation, attorney's ’s fees, back wages, liquidated damages, penalties or interest) resulting from any violation of any federal, state or local law, regulation, or ordinance by ContractorConsultant, including, without limitation, Contractor's Consultant’s failure to collect, withhold, or pay any and all federal or state taxes required to be withheld or paid by employers or employees, including, without limitation, any and all income tax, social security, and FUTA taxes. (c) In remedying the event of any violation breach of this Agreement or the Company CDA by ContractorConsultant, the Company shall first notify Contractor Consultant of the existence of such violation breach and provide Contractor Consultant thirty (30) days in which to remedy the violation at Contractor's expensebreach.

Appears in 1 contract

Samples: Consulting Agreement (BeyondSpring Inc.)

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!