Additional Indemnification; Limitation of Liability A. Subject to Section 2(A), USBFS CANNOT AND DOES NOT GUARANTEE AVAILABILITY OF THE ELECTRONIC SERVICES. Accordingly, USBFS’s sole liability to the Trust or any third party (including End Users) for any claims, notwithstanding the form of such claims (e.g., contract, negligence, or otherwise), arising out of the delay of or interruption in the Electronic Services to be provided by USBFS hereunder shall be to use its best reasonable efforts to commence or resume the Electronic Services as promptly as is reasonably possible.
B. USBFS shall, at its sole cost and expense, defend, indemnify, and hold harmless the Trust and its trustees, officers and employees from and against any and all claims, demands, losses, expenses and liabilities of any and every nature (including reasonable attorneys’ fees) arising out of or relating to (a) any infringement, or claim of infringement, of any United States patent, trademark, copyright, trade secret, or other proprietary rights based on the use or potential use of the Electronic Services and (b) the provision of the Trust Files (as defined below) or Confidential Information (as defined below) to a person other than a person to whom such information may be properly disclosed hereunder.
C. If an injunction is issued against the Trust’s use of the Electronic Services by reason of infringement of a patent, copyright, trademark, or other proprietary rights of a third party, USBFS shall, at its own option and expense, either (i) procure for the Trust the right to continue to use the Electronic Services on substantially the same terms and conditions as specified hereunder, or (ii) after notification to the Trust, replace or modify the Electronic Services so that they become non-infringing, provided that, in the Trust’s judgment, such replacement or modification does not materially and adversely affect the performance of the Electronic Services or significantly lessen their utility to the Trust. If in the Trust’s judgment, such replacement or modification does materially adversely affect the performance of the Electronic Services or significantly lessen their utility to the Trust, the Trust may terminate all rights and responsibilities under this Exhibit C immediately on written notice to USBFS.
D. Because the ability of USBFS to deliver Electronic Services is dependent upon the Internet and equipment, software, systems, data and services provided by various telecommunications carriers, equipment manufacturers, firewall providers and encryption system developers and other vendors and third parties, USBFS shall not be liable for delays or failures to perform its obligations hereunder to the extent that such delays or failures are attributable to circumstances beyond its reasonable control which interfere with the delivery of the Electronic Services by means of the Internet or any of the equipment, software and services which support the Internet provided by such third parties. USBFS shall also not be liable for the actions or omissions of any third party wrongdoers (i.e., hackers not employed by USBFS or its affiliates) or of any third parties involved in the Electronic Services and shall not be liable for the selection of any such third party, unless USBFS selected the third party in bad faith or in a grossly negligent manner.
E. USBFS shall not be responsible for the accuracy of input material from End Users nor the resultant output derived from inaccurate input. The accuracy of input and output shall be judged as received at USBFS’s data center as determined by the records maintained by USBFS.
F. Notwithstanding anything to the contrary contained herein, USBFS shall not be obligated to ensure or verify the accuracy or actual receipt, or the transmission, of any data or information contained in any transaction via the Electronic Services or the consummation of any inquiry or transaction request not actually reviewed by USBFS.
Mandatory Indemnification; Indemnification as a Witness (i) To the extent that Indemnitee shall have been successful on the merits or otherwise in defense of any Claim relating to an Indemnifiable Event or any portion thereof or in defense of any issue or matter therein, including without limitation dismissal without prejudice, Indemnitee shall be indemnified against all Losses relating to such Claim in accordance with Section 2 to the fullest extent allowable by law, and no Standard of Conduct Determination (as defined in Section 8(b)) shall be required.
(ii) To the extent that Xxxxxxxxxx’s involvement in a Claim relating to an Indemnifiable Event is to prepare to serve and serve as a witness, and not as a party, the Indemnitee shall be indemnified against all Losses incurred in connection therewith to the fullest extent allowable by law and no Standard of Conduct Determination (as defined in Section 8(b)) shall be required.
Indemnification of NCPS From and at all times after the date of this Escrow Agreement, Issuer shall, to the fullest extent permitted by law, defend, indemnify and hold harmless NCPS and each director, officer, employee, attorney, agent and affiliate of NCPS (collectively, the “Indemnified Parties”) against any and all actions, claims (whether or not valid), losses, damages, liabilities, costs and expenses of any kind or nature whatsoever (including without limitation reasonable attorneys’ fees, costs and expenses) incurred by or asserted against any of the Indemnified Parties from and after the date hereof, whether direct, indirect or consequential, as a result of or arising from or in any way relating to any claim, demand, suit, action or proceeding (including any inquiry or investigation) by any person, including without limitation Issuer and Broker whether threatened or initiated, asserting a claim for any legal or equitable remedy against any person under any statute or regulation, including, but not limited to, any federal or state securities laws, or under any common law or equitable cause or otherwise, arising from or in connection with the negotiation, preparation, execution, performance or failure of performance of this Escrow Agreement or any transactions contemplated herein, whether or not any such Indemnified Party is a party to any such action, proceeding, suit or the target of any such inquiry or investigation; provided, however, that no Indemnified Party shall have the right to be indemnified hereunder for any liability finally determined by a court of competent jurisdiction, subject to no further appeal, to have resulted from the gross negligence or willful misconduct of such Indemnified Party. Each Indemnified Party shall, in its sole discretion, have the right to select and employ separate counsel with respect to any action or claim brought or asserted against it, and the reasonable fees of such counsel shall be paid upon demand by the Issuer. The obligations of Issuer under this Section 9 shall survive any termination of this Escrow Agreement and the resignation or removal of NCPS.
Additional Indemnification Provisions (a) With respect to each indemnification obligation under this Agreement (i) each such obligation shall be calculated on an After-Tax Basis and (ii) all Losses shall be net of any third-party insurance proceeds that have been recovered or are recoverable by the Indemnified Party in connection with the facts giving rise to the right of indemnification.
(b) If an Indemnifying Party makes any payment for any Losses suffered or incurred by an Indemnified Party pursuant to the provisions of this Article VII, such Indemnifying Party shall be subrogated, to the extent of such payment, to all rights and remedies of the Indemnified Party to any insurance benefits or other claims of the Indemnified Party with respect to such Losses and with respect to the claim giving rise to such Losses.
(c) The right to indemnification or other remedy based on any representations, warranties, obligations, covenants and agreements set forth in this Agreement or in any of the Ancillary Agreements, will not be affected by any investigation conducted with respect to, or any notice or knowledge acquired (or capable of being acquired), with respect to the accuracy or inaccuracy of or compliance with, any such representation, warranty, covenant or agreement; provided, however, that notwithstanding anything to the contrary contained herein, except as set forth on Section 7.7(c) of the ABI Disclosure Letter, ABI shall not have any liability relating to any breach of, or inaccuracy in, any representation or warranty made herein that, as of the date hereof, any Buyer Party had Knowledge of the breach or inaccuracy of the representation or warranty or of the facts relating to such breach or inaccuracy.
Indemnification Matters The Company hereby acknowledges that one (1) or more of the directors nominated to serve on the Board of Directors by the Investors (each a “Fund Director”) may have certain rights to indemnification, advancement of expenses and/or insurance provided by one or more of the Investors and certain of their affiliates (collectively, the “Fund Indemnitors”). The Company hereby agrees (a) that it is the indemnitor of first resort (i.e., its obligations to any such Fund Director are primary and any obligation of the Fund Indemnitors to advance expenses or to provide indemnification for the same expenses or liabilities incurred by such Fund Director are secondary), (b) that it shall be required to advance the full amount of expenses incurred by such Fund Director and shall be liable for the full amount of all expenses, judgments, penalties, fines and amounts paid in settlement by or on behalf of any such Fund Director to the extent legally permitted and as required by the Company’s Certificate of Incorporation or Bylaws of the Company (or any agreement between the Company and such Fund Director), without regard to any rights such Fund Director may have against the Fund Indemnitors, and, (c) that it irrevocably waives, relinquishes and releases the Fund Indemnitors from any and all claims against the Fund Indemnitors for contribution, subrogation or any other recovery of any kind in respect thereof. The Company further agrees that no advancement or payment by the Fund Indemnitors on behalf of any such Fund Director with respect to any claim for which such Fund Director has sought indemnification from the Company shall affect the foregoing and the Fund Indemnitors shall have a right of contribution and/or be subrogated to the extent of such advancement or payment to all of the rights of recovery of such Fund Director against the Company.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable. TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree (Yes) TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes Does Vendor agree? Yes, Vendor agrees (Yes) Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees (Yes)
Basic Indemnification Arrangement (a) In the event Indemnitee was, is or becomes a party to or witness or other participant in, or is threatened to be made a party to or witness or other participant in, a Claim by reason of (or arising in part out of) an Indemnifiable Event, the Company shall indemnify Indemnitee to the fullest extent permitted by law as soon as practicable but in any event no later than thirty days after written demand is presented to the Company, against any and all Expenses, judgments, fines, penalties and amounts paid in settlement (including all interest, assessments and other charges paid or payable in connection with or in respect of such Expenses, judgments, fines, penalties or amounts paid in settlement) of such Claim. If so requested by Indemnitee, the Company shall advance (within five business days of such request) any and all Expenses to Indemnitee (an “Expense Advance”).
(b) Notwithstanding the foregoing, (i) the obligations of the Company under Section 2(a) shall be subject to the condition that the Reviewing Party shall not have determined (in a written opinion, in any case in which the Independent Legal Counsel referred to in Section 3 hereof is involved) that Indemnitee would not be permitted to be indemnified under applicable law, and (ii) the obligation of the Company to make an Expense Advance pursuant to Section 2(a) shall be subject to the condition that, if, when and to the extent that the Reviewing Party determines that Indemnitee would not be permitted to be so indemnified under applicable law, the Company shall be entitled to be reimbursed by Indemnitee (who hereby agrees to reimburse the Company) for all such amounts theretofore paid; provided, however, that if Indemnitee has commenced or thereafter commences legal proceedings in a court of competent jurisdiction to secure a determination that Indemnitee should be indemnified under applicable law, any determination made by the Reviewing Party that Indemnitee would not be permitted to be indemnified under applicable law shall not be binding and Indemnitee shall not be required to reimburse the Company for any Expense Advance until a final judicial determination is made with respect thereto (as to which all rights of appeal therefrom have been exhausted or lapsed). If there has not been a Change in Control, the Reviewing Party shall be selected by the Board of Directors, and if there has been such a Change in Control (other than a Change in Control which has been approved by a majority of the Company’s Board of Directors who were directors immediately prior to such Change in Control), the Reviewing Party shall be the Independent Legal Counsel referred to in Section 3 hereof. If there has been no determination by the Reviewing Party or if the Reviewing Party determines that Indemnitee substantively would not be permitted to be indemnified in whole or in part under applicable law, Indemnitee shall have the right to commence litigation in any court in the State of Colorado or Delaware having subject matter jurisdiction thereof and in which venue is proper seeking an initial determination by the court or challenging any such determination by the Reviewing Party or any aspect thereof, including the legal or factual bases therefor, and the Company hereby consents to service of process and agrees to appear in any such proceeding. Any determination by the Reviewing Party otherwise shall be conclusive and binding on the Company and Indemnitee.
Indemnification Provisions Contractor agrees to indemnify, defend with counsel approved in writing by County, and hold County, its elected and appointed officials, officers, employees, agents and those special districts and agencies which County’s Board of Supervisors acts as the governing Board (“County Indemnitees”) harmless from any claims, demands or liability of any kind or nature, including but not limited to personal injury or property damage, arising from or related to the services, products or other performance provided by Contractor pursuant to this Contract. If judgment is entered against Contractor and County by a court of competent jurisdiction because of the concurrent active negligence of County or County Indemnitees, Contractor and County agree that liability will be apportioned as determined by the court. Neither party shall request a jury apportionment.
Limitation of Liability of the Adviser; Indemnification The Adviser (and its officers, managers, partners, agents, employees, controlling persons, members and any other person or entity affiliated with the Adviser, including without limitation its general partner and the Administrator) shall not be liable to the Corporation for any action taken or omitted to be taken by the Adviser in connection with the performance of any of its duties or obligations under this Agreement or otherwise as an investment adviser of the Corporation, except to the extent specified in Section 36(b) of the Investment Company Act concerning loss resulting from a breach of fiduciary duty (as the same is finally determined by judicial proceedings) with respect to the receipt of compensation for services, and the Corporation shall indemnify, defend and protect the Adviser (and its officers, managers, partners, agents, employees, controlling persons, members and any other person or entity affiliated with the Adviser, including without limitation its general partner and the Administrator, each of whom shall be deemed a third party beneficiary hereof) (collectively, the “Indemnified Parties”) and hold them harmless from and against all damages, liabilities, costs and expenses (including reasonable attorneys’ fees and amounts reasonably paid in settlement) incurred by the Indemnified Parties in or by reason of any pending, threatened or completed action, suit, investigation or other proceeding (including an action or suit by or in the right of the Corporation or its security holders) arising out of or otherwise based upon the performance of any of the Adviser’s duties or obligations under this Agreement or otherwise as an investment adviser of the Corporation. Notwithstanding the preceding sentence of this Paragraph 9 to the contrary, nothing contained herein shall protect or be deemed to protect the Indemnified Parties against or entitle or be deemed to entitle the Indemnified Parties to indemnification in respect of, any liability to the Corporation or its security holders to which the Indemnified Parties would otherwise be subject by reason of willful misfeasance, bad faith or gross negligence in the performance of the Adviser’s duties or by reason of the reckless disregard of the Adviser’s duties and obligations under this Agreement (as the same shall be determined in accordance with the Investment Company Act and any interpretations or guidance by the Securities and Exchange Commission or its staff thereunder).
Limitation of Liability; Indemnification (a) Funds Management shall not be liable for any error of judgment or mistake of law or for any loss suffered by the Trust in connection with the performance of its obligations and duties under this Agreement, except a loss resulting from Funds Management’s willful misfeasance, bad faith, or negligence in the performance of its obligations and duties or that of its agents or sub-administrators, or by reason of its or their reckless disregard thereof. Any person, even though also an officer, director, employee or agent of Funds Management, shall be deemed, when rendering services to the Trust or acting on any business of the Trust (other than services or business in connection with Funds Management’s duties as Administrator hereunder), to be acting solely for the Trust and not as an officer, director, employee, or agent or one under the control or discretion of Funds Management even though paid by it.
(b) The Trust, on behalf of each Fund, will indemnify Funds Management against and hold it harmless from any and all losses, claims, damages, liabilities, or expenses (including reasonable counsel fees and expenses) resulting from any claim, demand, action, or suit relating to the particular Fund and not resulting from willful misfeasance, bad faith, or negligence of Funds Management or its agents or sub-administrators in the performance of their obligations and duties hereunder, or by reason of its or their reckless disregard thereof. Funds Management will not confess any claim or settle or make any compromise in any instance in which the Trust will be asked to provide indemnification, except with the Trust’s prior written consent. Any amounts payable by the Trust under this Subparagraph shall be satisfied only against the assets of the Fund involved in the claim, demand, action, or suit and not against the assets of any other Fund.
(c) Funds Management will indemnify the Trust against and hold it harmless from any and all losses, claims, damages, liabilities, or expenses (including reasonable counsel fees and expenses) resulting from any claim, demand, action, or suit against the Trust or any Fund that resulted from a failure of Funds Management or its agents to act in accordance with the standard of care set forth in Subparagraph (a) above; provided that such loss, claim, damage, liability or expense did not result primarily from willful misfeasance, bad faith, or negligence of the Trust or its agents (other than Funds Management or agents of Funds Management) in the performance of their obligations and duties, or by reason of its or their reckless disregard thereof. The Trust will not confess any claim or settle or make any compromise in any instance in which Funds Management will be asked to provide indemnification, except with Funds Management’s prior written consent.
