Common use of INDIVIDUAL AND COLLABORATIVE APPROACH Clause in Contracts

INDIVIDUAL AND COLLABORATIVE APPROACH. Each Party has -well-defined tasks called out in the Gemini Project Plan. The Parties will work closely together on system design, integration and testing, particularly of software. The Parties also will work together as necessary to solve a problem or correct for a missed milestone or a delay in an element on the critical path. Because the various components of the Gemini MS will need to work together, a Party may offer suggestions respecting a component even if that Party is not responsible for developing that component. The Party responsible for developing the component will consider each suggestion and will adopt the suggestion unless in its judgment the suggestion is not feasible or reasonable.