Interference with Tests on Completion. If the Contractor suffers delay or is prevented, for more than 14 days, from carrying out the Tests on Completion by a cause for which the Employer is responsible and/or incurs Cost as a result of this delay in carrying out the Tests on Completion, the Contractor shall give notice to the Engineer and shall be entitled subject to clause 20 [Claims and Disputes] to:
Appears in 10 contracts
Samples: Contract Agreement, STS Crane, Contract Agreement
Interference with Tests on Completion. If the Contractor suffers delay or is prevented, for more than 14 days, from carrying out the Tests on Completion by a cause for which the Employer Contract Awarder is responsible responsible, the Contractor shall carry out the Tests on Completion as soon as practicable. If the Contractor suffers delay and/or incurs Cost as a result of this delay in carrying out the Tests on Completion, the Contractor shall give notice to the Engineer Contract Awarder and shall be entitled subject to clause 20 Sub-Clause 20.1 [Claims and DisputesContractor's Claims] to:
Appears in 2 contracts
Samples: Contract Agreement (Renewable Fuel Corp), Contract Agreement (Renewable Fuel Corp)
Interference with Tests on Completion. If the Contractor suffers delay or is prevented, for more than 14 days, from carrying out the Tests on Completion by a cause for which the Employer is responsible and/or incurs Cost as a result of this delay in carrying out the Tests on Completion, the Contractor shall give notice to the Engineer and shall be entitled subject to clause 20 [Claims Claims, Disputes and DisputesArbitration] to:
Appears in 2 contracts
Samples: STS Crane, www.dctgdansk.pl
Interference with Tests on Completion. If the Contractor suffers delay or is prevented, for more than 14 days, from carrying out the Tests on Completion by a cause for which the Employer is responsible responsible, the Contractor shall carry out the Tests on Completion as soon as practicable. If the Contractor suffers delay and/or incurs Cost as a result of this delay in carrying out the Tests on Completion, the Contractor shall give notice to the Engineer Employer and shall be entitled subject to clause 20 Sub-Clause 20.1 [Claims and DisputesContractor's Claims] to:
Appears in 1 contract
