Interim payments Interim payments are intended to reimburse the beneficiary for expenditure on the basis of a detailed statement of the costs incurred, once the action has reached a certain level of completion. It may clear all or part of any pre-financing. By the appropriate deadline indicated in Article I.5, the beneficiary shall submit a request for interim payment accompanied by the following documents: - an interim report on implementation of the action; - an interim financial statement of the eligible costs actually incurred, following the structure of the estimated budget; - where required by the provisions of Article I.4 on interim payment, a certificate on the action's financial statements and underlying accounts, produced by an approved auditor or, in case of public bodies, by a competent and independent public officer. The certificate shall certify, in accordance with a methodology approved by the Commission, that the costs declared by the beneficiary in the financial statements on which the request of payment is based are real, accurately recorded and eligible and that all receipts have been declared, in accordance with the agreement. The documents accompanying the request for payment shall be drawn up in accordance with the relevant provisions in Article I.5 and the annexes. The beneficiary shall certify that the information provided in his request for payment is full, reliable and true. He shall also certify that the costs incurred can be considered eligible in accordance with the agreement, that all receipts have been declared, and that his request for payment is substantiated by adequate supporting documents that can be checked. On receipt of these documents, the Commission shall have the period specified in Article I.4 in order to: - approve the interim report on implementation of the action; - ask the beneficiary for supporting documents or any additional information it deems necessary to allow the approval of the report; - reject the report and ask for the submission of a new report. Failing a written reply from the Commission within the time limit for scrutiny indicated above, the report shall be deemed to have been approved. Approval of the report accompanying the request for payment shall not imply recognition of the regularity or of the authenticity, completeness and correctness of the declarations and information it contains. Requests for additional information or a new report shall be notified to the beneficiary in writing. If additional information or a new report is requested, the time limit for scrutiny shall be extended by the time it takes to obtain this information. The beneficiary shall be informed of that request and the extension of the delay for scrutiny by means of a formal document. The beneficiary shall have the period laid down in Article I.4 to submit the information or new documents requested. Extension of the delay for approval of the report may delay the payment by the equivalent time. Where a report is rejected and a new report requested, the approval procedure described in this article shall apply. In the event of renewed rejection, the Commission reserves the right to terminate the agreement by invoking Article II.11.2 (b).
Interim payment At the end of each of the periods indicated in Annex I the Contractor shall submit to the Agency a formal request for payment accompanied by those of the following documents which are provided for in the Special Conditions: ➢ an interim technical report in accordance with the instructions laid down in Xxxxx X; ➢ the relevant invoices indicating the reference number of the Contract and of the order or specific contract to which they refer;
Final Payment All items or Automated Clearing House (ACH) transfers credited to your account are provisional until we receive final payment. If final payment is not received, we may charge your account for the amount of such items or ACH transfers and impose a return item charge on your account. Any collection fees we incur may be charged to your account. We reserve the right to refuse or return any item or funds transfer.
FINAL COMPLETION AND FINAL PAYMENT 9.9.1 Upon receipt of written notice that the Work is ready for final inspection and acceptance and upon receipt of a final Application for Payment, the Architect will promptly make such inspection and, when he or she finds the Work acceptable under the Contract Documents and the Contract fully performed, he or she will promptly issue a final Certificate for Payment stating that to the best of his / her knowledge, information and belief, and on the basis of his or her observations and inspections, the Work has been completed in accordance with the terms and conditions of the Contract Documents and that the entire balance found to be due the Contractor, and noted in said final Certificate, is due and payable. The Architect's final Certificate for Payment will constitute a further representation that the Contractor has fulfilled the conditions entitling him or her to final payment as set forth in Subparagraph 9.9.2 of these General Conditions.
Treatment of Passthru Payments and Gross Proceeds The Parties are committed to work together, along with Partner Jurisdictions, to develop a practical and effective alternative approach to achieve the policy objectives of foreign passthru payment and gross proceeds withholding that minimizes burden.
ACCEPTANCE AND FINAL PAYMENT Final payment may be requested by the Contractor upon completion and acceptance, by the Town, of all work as set forth in the Contract Documents. The total amount of final payment shall consist of the Contract Price, as adjusted in accordance with approved change orders, if applicable, less all previous payments to the Contractor.
ADDITIONAL PAYMENT In addition to any Spousal Support, in the event of Divorce: (check one) ☐ - There shall be No Additional Payment made by either Spouse to the other than those listed in this Agreement. ☐ - There shall be an Additional One (1) Time payment in the amount of $ made by the ☐ Husband ☐ Wife to the ☐ Husband ☐ Wife (“Additional Payment”). The Additional Payment shall be made within thirty (30) days after a divorce judgment, decree, or similar document that certifies the Divorce. ☐ - Other. .
Additional Payments Any sums expended by Agent or any Lender due to any Borrower’s failure to perform or comply with its obligations under this Agreement or any Other Document including any Borrower’s obligations under Sections 4.2, 4.4, 4.12, 4.13, 4.14 and 6.1 hereof, may be charged to Borrowers’ Account as a Revolving Advance and added to the Obligations.
Billing, Payment, Milestones, and Financial Security 6.1 Billing and Payment Procedures and Final Accounting
Initial Payment Interconnection Customer shall elect (and provide its election to the Transmission Provider within five days of the commencement of negotiation of the GIA pursuant to Section 11.2 of the GIP) to make either 1) an initial payment equal to twenty (20) percent of the total cost of Network Upgrades, Transmission Owner Interconnection Facilities, Transmission Owner’s System Protection Facilities, Distribution Upgrades and/or Generator Upgrades (if the In-Service Date is less than or equal to five (5) years of the initial payment date); or 2) an initial payment equal to ten (10) percent of the total cost of Network Upgrades, Transmission Owner Interconnection Facilities, Transmission Owner’s System Protection Facilities, Distribution Upgrades and/or Generator Upgrades (if the In-Service Date exceeds the initial payment date by more than five (5) years); or 3) the total cost of Network Upgrades, Transmission Owner Interconnection Facilities, Transmission Owner’s System Protection Facilities, Distribution Upgrades and/or Generator Upgrades in the form of security pursuant to Article 11.6. The initial payment shall be provided to Transmission Owner by Interconnection Customer pursuant to this Article 11.5 within the later of a) forty-five (45) Calendar Days of the execution of the GIA by all Parties, or b) forty-five (45) Calendar Days of acceptance by FERC if the GIA is filed unexecuted and the payment is being protested by Interconnection Customer, or c) forty-five (45) Calendar Days of the filing if the GIA is filed unexecuted and the initial payment is not being protested by Interconnection Customer. If the Interconnection Customer made its milestone payments in the form of cash and the Interconnection Customer elects a cash initial payment, then the Transmission Provider shall transfer those funds to the Transmission Owner on the Interconnection Customer’s behalf.
