Issuer to Pursue Remedies Against Contractors Sample Clauses

Issuer to Pursue Remedies Against Contractors. Subcontractors and Sureties. In the event of default of any contractor or subcontractor under any contract made by it in connection with the Project, the Issuer at the request of the Company will promptly proceed (at the Company's sole cost and expense), either separately or in conjunction with others, to exhaust the remedies of the Issuer against the contractor or subcontractor so in default and against his surety, if any, for the performance of such contract. The Issuer will advise the Company of the steps it intends to take in connection with any such default. If the Company shall so notify the Issuer, the Company may, in its own name or in the name of the Issuer, prosecute or defend any action or proceeding or take any other action involving any such contractor, subcontractor or surety which the Company deems reasonably necessary, and in such event the Issuer will cooperate fully with the Company and will take all action necessary to effect the substitution of the Company for the Issuer in any such action or proceeding. Any amounts recovered by way of damages, refunds, adjustments or otherwise in connection with the foregoing prior to the completion of the Project shall, after payment of all costs and expenses including reasonable attorney's fees incurred in connection with the foregoing, be paid into the Construction Fund. Upon completion of the Project or at any time prior thereto upon the request of the Company, so long as it is not in default hereunder, the Issuer will assign to the Company all warranties and guaranties of all contractors, subcontractors, suppliers, architects and engineers for the furnishing of labor, materials or equipment or for supervision or design in connection with the Project and any rights or causes of action against any of the foregoing.
Sample 1
AutoNDA by SimpleDocs
Issuer to Pursue Remedies Against Contractors. AND SUBCONTRACTORS AND THEIR SURETIES. In the event of any default of any supplier, contractor or subcontractor under any Construction Contract entered into in connection with the Project Construction or in the event of breach of warranty with respect to any material, workmanship or performance guaranty, the Issuer, at the request and sole cost of the Lessee, will promptly proceed either separately or in conjunction with others, to exhaust the remedies of the Issuer against any defaulting supplier, contractor or subcontractor and against any surety thereof or for the performance of any contract made in connection with the Project. Unless the Lessee shall request the Issuer to proceed in another manner, the Issuer shall proceed, in connection with any such default, only through the Lessee as agent for the Issuer; and the Lessee, as such agent and in the name of the Issuer, shall prosecute, defend or settle any action or proceeding or take any other action involving any such supplier, contractor, subcontractor or surety which the Lessee deems reasonably necessary. Any amounts recovered by way of damages, refunds, adjustments or otherwise in connection with the foregoing prior to the Completion Date shall be paid into the Construction Fund and after the Completion Date shall be applied in the manner specified in Section 4.3 hereof.
Sample 1

Related to Issuer to Pursue Remedies Against Contractors

  • Rights and Remedies are Cumulative Except with respect to rights and remedies expressly declared to be exclusive in this Agreement, the rights and remedies of the parties are cumulative and the exercise by either party of one or more of such rights or remedies shall not preclude the exercise by it, at the same or different times, of any other rights or remedies for the same default or any other default by the other party.

  • Limitation of Remedies and Damages 8.1 Liability Cap. EXCEPT WITH RESPECT TO: (A) EITHER PARTY'S OBLIGATIONS UNDER SECTION 9 8.2 EXCEPT FOR CUSTOMER’S INFRINGEMENT OF SYSDIG’S INTELLECTUAL PROPERTY RIGHTS, IN NO EVENT SHALL EITHER PARTY, OR SYSDIG’S AFFILIATES OR ITS LICENSORS BE LIABLE FOR ANY CONSEQUENTIAL, INCIDENTAL, SPECIAL, INDIRECT, PUNITIVE OR EXEMPLARY DAMAGES, INCLUDING WITHOUT LIMITATION LOST PROFITS, LOSS OF USE, BUSINESS INTERRUPTIONS, LOSS OF DATA, REVENUE, GOODWILL, PRODUCTION, ANTICIPATED SAVINGS, COSTS OF PROCUREMENT OF SUBSTITUTE GOODS OR SERVICES, IN CONNECTION WITH OR ARISING OUT OF THE PERFORMANCE OF OR FAILURE TO PERFORM THIS AGREEMENT, WHETHER ALLEGED AS A BREACH OF CONTRACT OR TORTIOUS CONDUCT, INCLUDING NEGLIGENCE, EVEN OF A PARTY HAS BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES. 8.3 Limitations Fair and Reasonable. EACH PARTY ACKNOWLEDGES THAT THE LIMITATIONS OF LIABILITY SET FORTH IN THIS SECTION 8 REFLECT THE ALLOCATION OF RISK BETWEEN THE PARTIES UNDER THIS AGREEMENT, AND THAT IN THE ABSENCE OF SUCH LIMITATIONS OF LIABILITY, THE ECONOMIC TERMS OF THIS AGREEMENT WOULD BE SIGNIFICANTLY DIFFERENT.

  • No Waiver; Cumulative Remedies; Enforcement No failure by any Lender, the L/C Issuer or the Administrative Agent to exercise, and no delay by any such Person in exercising, any right, remedy, power or privilege hereunder or under any other Loan Document shall operate as a waiver thereof; nor shall any single or partial exercise of any right, remedy, power or privilege hereunder preclude any other or further exercise thereof or the exercise of any other right, remedy, power or privilege. The rights, remedies, powers and privileges herein provided, and provided under each other Loan Document, are cumulative and not exclusive of any rights, remedies, powers and privileges provided by law. Notwithstanding anything to the contrary contained herein or in any other Loan Document, the authority to enforce rights and remedies hereunder and under the other Loan Documents against the Loan Parties or any of them shall be vested exclusively in, and all actions and proceedings at law in connection with such enforcement shall be instituted and maintained exclusively by, the Administrative Agent in accordance with Section 8.02 for the benefit of all the Lenders and the L/C Issuer; provided, however, that the foregoing shall not prohibit (a) the Administrative Agent from exercising on its own behalf the rights and remedies that inure to its benefit (solely in its capacity as Administrative Agent) hereunder and under the other Loan Documents, (b) the L/C Issuer or the Swing Line Lender from exercising the rights and remedies that inure to its benefit (solely in its capacity as L/C Issuer or Swing Line Lender, as the case may be) hereunder and under the other Loan Documents, (c) any Lender from exercising setoff rights in accordance with Section 10.08 (subject to the terms of Section 2.13), or (d) any Lender from filing proofs of claim or appearing and filing pleadings on its own behalf during the pendency of a proceeding relative to any Loan Party under any Debtor Relief Law; and provided, further, that if at any time there is no Person acting as Administrative Agent hereunder and under the other Loan Documents, then (i) the Required Lenders shall have the rights otherwise ascribed to the Administrative Agent pursuant to Section 8.02 and (ii) in addition to the matters set forth in clauses (b), (c) and (d) of the preceding proviso and subject to Section 2.13, any Lender may, with the consent of the Required Lenders, enforce any rights and remedies available to it and as authorized by the Required Lenders.

  • No Waiver of Provisional Remedies, Self-Help and Foreclosure The arbitration requirement does not limit the right of any party to (i) foreclose against real or personal property collateral; (ii) exercise self-help remedies relating to collateral or proceeds of collateral such as setoff or repossession; or (iii) obtain provisional or ancillary remedies such as replevin, injunctive relief, attachment or the appointment of a receiver, before during or after the pendency of any arbitration proceeding. This exclusion does not constitute a waiver of the right or obligation of any party to submit any dispute to arbitration or reference hereunder, including those arising from the exercise of the actions detailed in sections (i), (ii) and (iii) of this paragraph.

  • Limitations on Remedies 7.1 IN NO EVENT WHATSOEVER SHALL SELLER OR ANY OF THE TEKNI-PLEX COMPANIES OR ANY OF ITS OR THEIR EMPLOYEES, AGENTS OR SUPPLIERS HAVE ANY LIABILITY, WHETHER BASED ON BREACH OF CONTRACT, WARRANTY, BREACH OF STATUTORY DUTY, NEGLIGENCE, TORT, STRICT LIABILITY OR OTHERWISE, IN AN AMOUNT IN EXCESS OF THE AMOUNT ACTUALLY RECEIVED BY SELLER FROM BUYER AS PURCHASE PRICE FOR THE PRODUCTS OR SERVICES WHICH ARE THE SUBJECT OF A CLAIM OR SERIES OF RELATED CLAIMS. IN NO EVENT WHATSOEVER SHALL SELLER OR ANY OF ITS EMPLOYEES, AGENTS OR SUPPLIERS HAVE ANY LIABILITY FOR ANY: LOSS OF INCOME; LOSS OF ACTUAL OR ANTICIPATED PROFITS; LOSS OF BUSINESS; LOSS OF CONTRACTS; LOSS OF GOODWILL OR REPUTATION; LOSS OF ANTICIPATED SAVINGS; LOSS OF, DAMAGE TO OR CORRUPTION OF DATA; BUYER’S ATTORNEY FEES OR ANY OTHER TYPE OF LUCRUM CESSANS; ANY INDIRECT, INCIDENTAL, CONSEQUENTIAL, SPECIAL, STATUTORY, PUNITIVE OR EXEMPLARY DAMAGES, EVEN IF SELLER HAS BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES, INCLUDING BUT NOT LIMITED TO ANY DAMAGES ARISING FROM OR RELATING TO ANY INJURY TO PERSONS; LOSS OF VALUE OR USE (INCLUDING WITHOUT LIMITATION, DIMINUTION IN VALUE OR STIGMA DAMAGES); LOSS OF ANTICIPATED REVENUE OR PROFIT; COST OF CAPITAL; DAMAGE TO OR LOSS OF OTHER PROPERTY OR EQUIPMENT; CLAIMS MADE BY END-USERS; OR COST OF SUBSTITUTE SUPPLIES, FACILITIES OR SERVICES, WHETHER BASED IN TORT, CONTRACT, BREACH OF STATUTORY DUTY, NEGLIGENCE, STRICT LIABILITY OR ANY OTHER LEGAL THEORY. 7.2 Without prejudice to any other provisions of this Agreement (including, but not limited to Section

  • Rights and Remedies Generally Upon the occurrence and during the continuance of any Event of Default, the Lender shall have, in addition to any other rights and remedies contained in this Agreement and in any of the other Financing Agreements, all of the rights and remedies of a secured party under the Code or other applicable laws, all of which rights and remedies shall be cumulative, and non-exclusive, to the extent permitted by law, including, without limitation, the right of Lender to sell, assign, or lease any or all of the Collateral or the Real Property. Upon notice to the Borrowers after an Event of Default and during the continuance thereof, Borrowers at their own expense shall assemble all or any part of the Collateral as determined by Lender and make it available to Lender at any location designated by Lender. In such event, the Borrowers shall, at their sole cost and expense, store and keep any Collateral so assembled at such location pending further action by Lender and provide such security guards and maintenance services as shall be necessary to protect and preserve such Collateral. In addition to all such rights and remedies, the sale, lease or other disposition of the Collateral, or any part thereof, by the Lender after an Event of Default and during the continuance thereof may be for cash, credit or any combination thereof, and the Lender may purchase all or any part of the Collateral at public or, if permitted by law, private sale, and in lieu of actual payment of such purchase price, may set-off the amount of such purchase price against the Liabilities of the Borrowers then owing. Any sales of such Collateral may be adjourned from time to time with or without notice. The Lender may, in its sole discretion, cause the Collateral to remain on any Borrower’s premises, at the Borrowers’ expense, pending sale or other disposition of such Collateral. The Lender shall have the right after an Event of Default and during the continuance thereof to conduct such sales on any Borrower’s premises, at the Borrowers’ expense, or elsewhere, on such occasion or occasions as the Lender may see fit.

  • Lessor's Remedies on Default If Lessee defaults in the payment of rent or defaults in the performance of any of the other covenants or conditions hereof, Lessor may give Lessee notice of such default and if Lessee does not cure any such default within thirty (30) days after the giving of such notice (or if the default is of a nature that it cannot be completely cured within such period, if Lessee does not commence such cure within such thirty (30) days and thereafter proceed with reasonable diligence and in good faith to cure such default), then Lessor may terminate this Lease on not less than thirty (30) days' notice to Lessee. On the date specified in such notice, the term of this Lease shall terminate and Lessee shall then quit and surrender the Premises to Lessor, without extinguishing Lessee’s liability. If this Lease shall have been so terminated by Lessor, Lessor may at any time thereafter resume possession of the Premises by any lawful means and remove Lessee or other occupants and their effects.

  • Waivers and remedies cumulative The rights of each Finance Party under the Finance Documents: (a) may be exercised as often as necessary; (b) are cumulative and not exclusive of its rights under the general law; and (c) may be waived only in writing and specifically. Delay in exercising or non-exercise of any right is not a waiver of that right.

  • Remedies are Cumulative Except as expressly provided in this Agreement, the rights and remedies contained in this Agreement are cumulative and not exclusive of any rights or remedies provided by law.

  • Waivers and Amendments; Non-Contractual Remedies; Preservation of Remedies This Guaranty may be amended, superseded, canceled, renewed or extended, and the terms hereof may be waived, only by a written instrument signed by the parties or, in the case of a waiver, by the party waiving compliance. No delay on the part of any party on exercising any right, power or privilege hereunder shall operate as a waiver thereof, nor shall any waiver on the part of any party of any right, power or privilege, nor any single or partial exercise of any such right, power or privilege, preclude any further exercise thereof or the exercise of any other such right, power or privilege. The rights and remedies herein provided are cumulative and are not exclusive of any rights or remedies that any party may otherwise have at law or in equity.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!