IT IS AGREED AS FOLLOWS. The Client will pay the Consultant the amount due and carry out his duties in accordance with the conditions of contract identified in the Contract Data and the Contract Schedules. The Consultant will Provide the Service in accordance with the conditions of contract identified in the Contract Data and the Contract Schedules. This contract incorporates the conditions of contract in the form of the NEC4 Professional Services Short Contract June 2017 Edition incorporating amendments January 2019 and October 2020 and incorporating the additional conditions specified in the Client’s Contract Data, which form this contract together with the documents referred to in it. References in the NEC4 Professional Services Short Contract June 2017 Edition incorporating amendments January 2019 and October 2020 to "the contract" are references to this contract. This contract [and the Framework Agreement] is the entire agreement between the parties in relation to the service and supersedes and extinguishes all prior arrangements, understandings, agreements, statements, representations or warranties (whether written or oral) relating thereto. Neither party has been given, nor entered into this contract in reliance on any arrangements, understandings, agreements, statements, representations or warranties other than those expressly set out in this agreement. Nothing in clauses 4 or 5 shall exclude liability in respect of misrepresentations made fraudulently. [Execution note Appropriate execution provisions will need to be inserted here depending upon whether the Call Off Contract is to be executed as a deed (meaning the contract will have a limitation period of 12 years) or a simple contract under hand (meaning that the contract will have a limitation period of only 6 years) and how each entity intends to effect the execution. Example execution clauses are set out below and customer guidance concerning the options can be obtained from Crown Commercial Service. Contracting Authorities will need to check with the relevant company as to which option is required.] [General note Access to the NEC suite of contracts, including guidance and membership details can be found via the NEC Website: xxxxx://xxx.xxxxxxxxxxx.xxx/ Additionally, Crown Commercial Service has worked together with NEC to provide discounted access to the suite of contracts . Further information can be found on the Project Management and Full Design Team Services Framework Agreement Webpage: xxxx://xxx-xxxxxxxxxx.xxxxxxxxxxxxx.xxx.xx/project-management-and-full-design-team-services-rm [ ] Example execution clauses: (Note: the following signature blocks need to be adapted to reflect the specific requirements of the relevant parties who are executing the Call Off Contract as a Deed. The following is an example only) Executed under hand [Signed by [NAME OF DIRECTOR] for and on behalf of [NAME OF COMPANY] ............................... [SIGNATURE OF DIRECTOR] Director OR Executed as a deed EXECUTED AS A DEED by the parties on the date which first appears in this Deed. EXECUTED (but not delivered until the date hereof) AS A DEED by [ ] acting by: - Director _________________________ Director/Secretary_________________________ OR EXECUTED AS A DEED by the parties on the date which first appears in this Deed. EXECUTED (but not delivered until the date hereof) AS A DEED by [ ] acting by:- Authorised Signatory_________________________ Authorised Signatory_________________________ OR EXECUTED AS A DEED by the parties on the date which first appears in this Deed. Executed as a deed by affixing the common seal of [ ] [COMMON SEAL] in the presence of: ................................................. [SIGNATURE OF DIRECTOR / SIGNATURE OF AUTHORISED SIGNATORY] Director .................................................. [SIGNATURE OF DIRECTOR/SECRETARY] [Director OR Secretary] OR EXECUTED AS A DEED by the parties on the date which first appears in this Deed. Executed as a deed by [ ] acting by [NAME OF DIRECTOR], a director, in the presence of: ………………………… [SIGNATURE OF DIRECTOR] Director ............................. [SIGNATURE OF WITNESS] [NAME OF WITNESS [IN BLOCK CAPITALS]] [ADDRESS OF WITNESS] [OCCUPATION OF WITNESS] nec4 Professional Service Short Contract A contract between and for Contract Forms Contract Data The Consultant’s Offer Price List Scope Notes about the contract are printed in boxes like this one. They are not part of the contract Contract Data The Client’s Contract Data The Client is Name Address for communications Address for electronic communications The service is q The starting date is The completion date is The delay damages are per day The law of the contract is The period for reply is weeks The defects date is weeks after Completion The assessment date is the of each month The United Kingdom Housing Grants, Construction and Regeneration Act (1996) does/does not apply (delete as applicable) The Adjudicator is: Name Address for communications Address for electronic communications Contract Data The Client’s Contract Data The interest rate on late payments is % per complete week of delay Insert a rate only if a rate less than 0.5% per week of delay has been agreed. The Client provides this insurance Only enter details here if the Client is to provide insurance. The Consultant provides the following insurance cover q INSURANCE AGAINST MINIMUM AMOUNT OF COVER PERIOD FOLLOWING COMPLETION OR EARLIER TERMINATION Liability of the Consultant for claims made against it arising out of the Consultant's failure to use the skill and care normally used by professionals providing services similar to the service. in respect of each claim, without limit to the number of claims Loss of or damage to property and liability for bodily injury to or death of a person (not an employee of the Consultant) arising from or in connection with the Consultant Providing the Service in respect of each event, without limit to the number of events Liability for death of or bodily injury to employees of the Consultant arising out of and in the course of their employment in connection with the contract in respect of each event, without limit to the number of events The Consultant’s total liability to the Client which arises under or in connection with the contract is limited to The Adjudicator nominating body is: The tribunal is: If the tribunal is arbitration, the arbitration procedure is Contract Data The Client’s Contract Data The conditions of contract are the NEC4 Professional Service Short Contract June 2017 incorporating amendments January 2019 and October 2020 and the following additional conditions Only enter details here if additional conditions are required Option Z2 Identified and defined terms [applies][does not apply] Option Z4 Admittance to Client’s Premises [applies][does not apply] Option Z5 Prevention of fraud and bribery [applies][does not apply] Option Z6 Equality and Diversity [applies][does not apply] Option Z7 Legislation and Official Secrets [applies][does not apply] Option Z8 Conflict of Interest [applies][does not apply] Option Z9 Publicity and Branding [applies][does not apply] Option Z10 Freedom of information [applies][does not apply] Option Z13 Confidentiality and Information Sharing [applies][does not apply] Option Z14 Security Requirements [applies][does not apply] Option Z16 Tax Compliance [applies][does not apply] Option Z22 Fair payment [applies][does not apply] Option Z26 Building Information Modelling [applies][does not apply] the information execution plan is …………………… Option Z42 The Housing Grants, Construction and Regeneration Xxx 0000 [applies][does not apply] Option Z44 Intellectual Property Rights [applies][does not apply] Option Z45 HMRC Requirements [applies][does not apply] Option Z46 MoD DEFCON Requirements [applies][does not apply] Option Z47 Small and Medium Sized Enterprises (SMEs) [applies][does not apply] The percentage of the Consultant’s subcontractors required to be SMEs is …………. % Option Z48 Apprenticeships [applies][does not apply] Option Z49 Change of Control [applies][does not apply] Option Z50 Financial Standing [applies][does not apply] Option Z51 Financial Distress [applies][does not apply] Option Z52 Records, audit access and open book data [applies][does not apply] Option Z100 Data Protection [applies][does not apply] Option Z101 Cyber Essentials [applies][does not apply] Other additional conditions [insert details/reference of any other additional conditions required by the Client] Contract Data The Consultant’s Contract Data The Consultant is Name Address for communications Address for electronic communications The service is q The starting date is The completion date is The delay damages are per day The fee percentage is % The people rates are category of person unit rate If the work is to be carried out on a time change basis the Consultant includes people rates for its own people as well as people provided by a subcontractor The key persons are Name Job Responsibilities Qualifications Experience Name Job Responsibilities Qualifications Experience The Consultant’s Offer The Consultant offers to Provide the Service in accordance with these conditions of contract for an amount to be determined in accordance with these conditions of contract. The offered total of the prices is Enter the total of the Prices from the Price List. If all work is to be carried out on a time charge basis, enter ‘Not Applicable’ Price List “The contract does not provide for the Consultant to be paid on a mixture of time charge and Prices and one or the other must be selected. If the work is to be paid on a time charge basis, only expenses should be included. No other entries should be made in the Price List. If the Consultant is to be paid on a priced basis the entries in the first four columns are made by either the Client of the tenderer. For each row: If the Consultant is to be paid an amount for the item which is not adjusted if the quantity of work in the item changes, the tenderer enters the amount in the Price column only. If the Consultant is to be paid an amount for the item of work and which is the rate for the work multiplied by the quantity completed, the tenderer enters the rate which is then multiplied by the expected quantity to produce the Price, which is also entered. Costs incurred by the Consultant other than the listed expenses are included in the Rates and Prices and the People Rates. If expenses are paid at cost, then 'at cost' should be entered into the Rate column. Delete or strike through unused rows. ITEM NUMBER DESCRIPTION UNIT EXPECTED QUANTITY RATE PRICE The total of the Prices
Appears in 1 contract
Samples: Template Call Off Agreement
IT IS AGREED AS FOLLOWS. The Client Employer will pay the Consultant the amount due and carry out his duties in accordance with the conditions of contract identified in the Contract Data and the Contract Schedules. The Consultant will Provide the Service Services in accordance with the conditions of contract identified in the Contract Data and the Contract Schedules. This contract incorporates the conditions of contract in the form of the NEC4 NEC3 Professional Services Short Contract June 2017 Edition incorporating amendments January 2019 and October 2020 and incorporating April 2013 together with the additional conditions specified in the Client’s Contract Data, which form this contract together with the documents referred to in it. References in the NEC4 NEC3 Professional Services Short Contract June 2017 April 2013 Edition incorporating amendments January 2019 and October 2020 to "the contract" are references to this contract. This contract [and the Framework Agreement] is the entire agreement between the parties in relation to the service services and supersedes and extinguishes all prior arrangements, understandings, agreements, statements, representations or warranties (whether written or oral) relating thereto. Neither party has been given, nor entered into this contract agreement in reliance on any arrangements, understandings, agreements, statements, representations or warranties other than those expressly set out in this agreement. Nothing in clauses 4 or 5 shall exclude liability in respect of misrepresentations made fraudulently. [Execution note Appropriate execution provisions will need to be inserted here depending upon whether the Call Off Contract is to be executed as a deed (meaning the contract will have a limitation period of 12 years) or a simple contract under hand (meaning that the contract will have a limitation period of only 6 years) and how each entity intends to effect the execution. Example execution clauses are set out below and customer guidance concerning the options can be obtained from Crown Commercial Service. Contracting Authorities will need to check with the relevant company as to which option is required.] [General note Access to the NEC suite of contracts, including guidance and membership details can be found via the NEC Website: xxxxx://xxx.xxxxxxxxxxx.xxx/ Additionally, Crown Commercial Service has worked together with NEC to provide discounted access to the suite of contracts . Further information can be found on the Project Management and Full Design Team Services Framework Agreement Webpage: xxxx://xxx-xxxxxxxxxx.xxxxxxxxxxxxx.xxx.xx/project-management-and-full-design-team-services-rm [ ] Example execution clauses: (Note: the following signature blocks need to be adapted to reflect the specific requirements of the relevant parties who are executing the Call Off Contract as a Deed. The following is an example only) Executed under hand [Signed by [NAME OF DIRECTOR] for and on behalf of [NAME OF COMPANY] ............................... [SIGNATURE OF DIRECTOR] Director OR Executed as a deed EXECUTED AS A DEED by the parties on the date which first appears in this Deed. EXECUTED (but not delivered until the date hereof) AS A DEED by [ ] acting by: - Director _________________________ Director/Secretary_________________________ OR EXECUTED AS A DEED by the parties on the date which first appears in this Deed. EXECUTED (but not delivered until the date hereof) AS A DEED by [ ] acting by:- Authorised Signatory_________________________ Authorised Signatory_________________________ OR EXECUTED AS A DEED by the parties on the date which first appears in this Deed. Executed as a deed by affixing the common seal of [ ] [COMMON SEAL] in the presence of: ................................................. [SIGNATURE OF DIRECTOR / SIGNATURE OF AUTHORISED SIGNATORY] Director .................................................. [SIGNATURE OF DIRECTOR/SECRETARY] [Director OR Secretary] OR EXECUTED AS A DEED by the parties on the date which first appears in this Deed. Executed as a deed by [ ] acting by [NAME OF DIRECTOR], a director, in the presence of: ………………………… [SIGNATURE OF DIRECTOR] Director ............................. [SIGNATURE OF WITNESS] [NAME OF WITNESS [IN BLOCK CAPITALS]] [ADDRESS OF WITNESS] [OCCUPATION OF WITNESS] nec4 nec3 Professional Service Short Contract A contract between and for Contents Contract Forms Contract Data The Consultant’s Offer Price List Scope Notes about the contract are printed in boxes like this one. They are not part of the contract Contract Data The Client’s Contract Data The Client is Name Address for communications Address for electronic communications Telephone E-mail address The service is q services are The starting date is The completion date is The delay damages for late Completion are per day The law of the contract is The period for reply is weeks The defects date is weeks after Completion The assessment date is the of each month Work is to be carried out on a time charge basis Delete if work is not to be carried out on a time charge basis If the period for payment is not four weeks The United Kingdom Housing Grants, Construction and Regeneration Act (1996) does/does not apply (delete as applicable) The Adjudicator is: Name Address period for communications Address for electronic communications Contract Data The Client’s Contract Data payment is weeks The interest rate on late payments payment is % per complete week of delay delay. Insert a rate only if a rate less than 0.5% per week of delay has been agreed. The Client provides this insurance Only enter details here if the Client is to provide insurance. Contract Data The Consultant provides the following insurance cover q INSURANCE AGAINST MINIMUM AMOUNT OF COVER PERIOD FOLLOWING COMPLETION OR EARLIER TERMINATION Liability Insurance against Minimum amount of cover Period following Completion or earlier termination Failure of the Consultant for claims made against it arising out of the Consultant's failure to use the skill and care normally used by professionals providing services similar to the serviceservices. ___________________________ in respect of each claim, without limit to the number of claims Loss ___________________________ Death of or damage to property and liability for bodily injury to or death of a person (not an employee of the Consultant) arising or loss of or damage to property resulting from an action or in connection with failure to take action by the Consultant Providing the Service ___________________________ in respect of each eventclaim, without limit to the number of events Liability for death claims ___________________________ Death of or bodily injury to employees of the Consultant arising out of and in the course of their employment in connection with the this contract ___________________________ in respect of each eventclaim, without limit to the number of events claims The Client provides the following insurance cover Only enter details here if Client is to provide insurance. _________________________________________________________________________ _________________________________________________________________________ _________________________________________________________________________ The Consultant’s total liability to the Client for matters for which arises under or in connection with the contract insurance is provided is limited to The Adjudicator nominating body is: Consultant’s total liability to the Client for other matters is limited to The tribunal is: If the tribunal is arbitration, the arbitration procedure is Contract Data The Client’s Contract Data place where the arbitration is to be held is The person who will choose the arbitrator if the Parties cannot agree is Only include these statements if the tribunal is arbitration. The conditions of contract are the NEC4 NEC Professional Service Services Short Contract June 2017 incorporating amendments January 2019 and October 2020 (April 2013) and the following additional conditions conditions. Only enter details here if additional conditions are required Option Z2 Identified and defined terms [applies][does not apply] Option Z4 Admittance to Client’s Premises [applies][does not apply] Option Z5 Prevention of fraud and bribery [applies][does not apply] Option Z6 Equality and Diversity diversity [applies][does not apply] Option Z7 Legislation and Official Secrets [applies][does not apply] Option Z8 Conflict of Interest interest [applies][does not apply] Option Z9 Publicity and Branding [applies][does not apply] Option Z10 Freedom of information [applies][does not apply] Option Z13 Confidentiality and Information Sharing [applies][does not apply] Option Z14 Security Requirements [applies][does not apply] Option Z16 Tax Compliance [applies][does not apply] Option Z22 Fair payment [applies][does not apply] Option Z26 Building Information Modelling [applies][does not apply] the information execution plan is …………………… Option Z42 The Housing Grants, Construction and Regeneration Xxx 0000 [applies][does not apply] Option Z44 Intellectual Property Rights [applies][does not apply] Option Z45 HMRC Requirements [applies][does not apply] Option Z46 MoD DEFCON Requirements [applies][does not apply] Option Z47 Small and Medium Sized Enterprises (SMEs) [applies][does not apply] The percentage of the Consultant’s subcontractors Subconsultants required to be SMEs is ……………………………. % Option Z48 Apprenticeships [applies][does not apply] Option Z49 Change of Control [applies][does not apply] Option Z50 Financial Standing [applies][does not apply] Option Z51 Financial Distress [applies][does not apply] Option Z52 Records, audit access and open book data [applies][does not apply] Option Z100 Data Protection [applies][does not apply] Option Z101 Cyber Essentials [applies][does not apply] Other additional conditions [insert details/reference of any other additional conditions required by the Client] Contract Data The Consultant’s Contract Data The Consultant is Name Address for communications Address for electronic communications The service is q The starting date is The completion date is The delay damages are per day The fee percentage is % The people rates are category of person unit rate If the work is to be carried out on a time change basis the Consultant includes people rates for its own people as well as people provided by a subcontractor The key persons are Name Job Responsibilities Qualifications Experience Name Job Responsibilities Qualifications Experience __________________________________________________________________________ The Consultant’s Offer The Consultant is Name Address Telephone The Consultant offers to Provide the Service Services in accordance with these the conditions of contract for an amount to be determined in accordance with these the conditions of contractconditions. The name, job, qualifications and experience of the Consultant’s key people are in The staff rates are Person or job Unit of measurement rate People not stated here are at open market rates or competitively tendered rates The offered total of the prices Prices is Enter the total of the Prices from the Price List. If all work is to be carried out on a time charge basis, enter ‘Not Applicable’ Price List “The contract does not provide for the Consultant to be paid on a mixture of time charge and Prices and one or the other must be selected. If the work is to be paid on a time charge basis, only expenses should be included. No other entries should be made in the Price List. If the Consultant is to be paid on a priced basis the entries Entries in the first four columns are made either by either the Client of or the tenderer. For each row: If the Consultant is to be paid an amount for the item which is not adjusted if the quantity of work in the item changes, the tenderer enters the amount in the Price column only. If the Consultant is to be paid an amount for the item of work and which is the rate for the work multiplied by the quantity completed, the tenderer enters the rate which is then multiplied by the expected Expected quantity to produce the Price, which is also entered. If the work is to be paid on a time charge basis, only expenses should be included. Costs incurred by the Consultant other than the listed expenses are included in the Rates and Prices and the People Ratesstaff rates. If expenses are paid at cost, then 'at cost' should be entered into the Rate column. Delete or strike through unused rows. ITEM NUMBER DESCRIPTION UNIT EXPECTED QUANTITY RATE PRICE EXPENSES The total of the PricesPrices is Scope The Scope should be a complete and precise statement of the Client's requirements. If it is incomplete or imprecise, there is a risk that the Consultant will interpret it differently from the Client's intention. Information provided by the Consultant should be listed in the Scope only if the Client is satisfied that it is required, is part of a complete statement of the Client's requirements and is consistent with other parts of the Scope. Purpose of the Service Provide a brief summary of why the service is being commissioned and what it will be used for. Description of the service Give a complete and precise description of what the Consultant is required to do. If items of work have to be provided by a stated date, include a table describing the works and stating the date when it is to be provided. Scope Existing information List existing information which is relevant to the services. This can include documents which the Consultant is to further develop Specifications and standards List the specifications and standards that apply to the contract. Scope Constraints on how the Consultant provides the Service State any constraints on sequence and timing of work and on method and conduct of work including the requirements for any work by the Client. Set out any requirements for a quality management system. Include a dispute resolution procedure if required. Scope Requirements for the programme State whether a programme is required and, if it is, what form it is to be in, what information is to be shown on it, when it is to be submitted and when it is to be updated Scope Information and other things provided by the Client Describe what information and other things the Client is to provide and by when. Information is that which is not currently available, but will become available during the contract. Other things could include access to a person, place (such as office space or a site) or the Client's information technology systems. Item Date by which it will be provided
Appears in 1 contract
Samples: Template Call Off Agreement
IT IS AGREED AS FOLLOWS. The Client Employer will pay the Consultant the amount due and carry out his duties in accordance with the conditions of contract identified in the Contract Data and the Contract Schedules. The Consultant will Provide the Service Services in accordance with the conditions of contract identified in the Contract Data and the Contract Schedules. This contract incorporates the conditions of contract in the form of the NEC4 NEC3 Professional Services Short Contract June 2017 Edition incorporating amendments January 2019 and October 2020 April 2013 and incorporating the following Options: [Insert selected main option to be selected on a project specific basis] [W1] [W2]; Option [insert selected X Options to be selected on a project specific basis] and Option [Y(UK)1] [Y(UK)2] [Y(UK)3] which together with the additional conditions of contract specified in Option Z, and the Client’s Contract Dataamendments specified in Option Z, which form this contract together with the documents referred to in it. References in the NEC4 NEC3 Professional Services Short Contract June 2017 April 2013 Edition incorporating amendments January 2019 and October 2020 to "the contract" are references to this contract. This contract [and the Framework Agreement] is the entire agreement between the parties in relation to the service services and supersedes and extinguishes all prior arrangements, understandings, agreements, statements, representations or warranties (whether written or oral) relating thereto. Neither party has been given, nor entered into this contract agreement in reliance on any arrangements, understandings, agreements, statements, representations or warranties other than those expressly set out in this agreement. Nothing in clauses 4 or 5 shall exclude liability in respect of misrepresentations made fraudulently. [Execution note Appropriate execution provisions will need to be inserted here depending upon whether the Call Off Contract is to be executed as a deed (meaning the contract will have a limitation period of 12 years) or a simple contract under hand (meaning that the contract will have a limitation period of only 6 years) and how each entity intends to effect the execution. Example execution clauses are set out below and customer guidance concerning the options can be obtained from Crown Commercial Service. Contracting Authorities will need to check with the relevant company as to which option is required.] [General note Access to the NEC suite of contracts, including guidance and membership details can be found via the NEC Website: xxxxx://xxx.xxxxxxxxxxx.xxx/ Additionally, Crown Commercial Service has worked together with NEC to provide discounted access to the suite of contracts . Further information can be found on the Project Management and Full Design Team Services Framework Agreement Webpage: xxxx://xxx-xxxxxxxxxx.xxxxxxxxxxxxx.xxx.xx/project-management-and-full-design-team-services-rm [ xxxx://xxx-xxxxxxxxxx.xxxxxxxxxxxxx.xxx.xx/project-management-and-full-design-team-services-rm3741 Contracting Authorities are able to select the most appropriate W, X, Y and Z clauses and include additional Z clauses that meet their requirement.] Example execution clauses: (Note: the following signature blocks need to be adapted to reflect the specific requirements of the relevant parties who are executing the Call Off Contract as a Deed. The following is an example only) Executed under hand [Signed by [NAME OF DIRECTOR] for and on behalf of [NAME OF COMPANY] ............................... [SIGNATURE OF DIRECTOR] Director OR Executed as a deed EXECUTED AS A DEED by the parties on the date which first appears in this Deed. EXECUTED (but not delivered until the date hereof) AS A DEED by [ ] acting by: - Director _________________________ Director/Secretary_________________________ OR EXECUTED AS A DEED by the parties on the date which first appears in this Deed. EXECUTED (but not delivered until the date hereof) AS A DEED by [ ] acting by:- Authorised Signatory_________________________ Authorised Signatory_________________________ OR EXECUTED AS A DEED by the parties on the date which first appears in this Deed. Executed as a deed by affixing the common seal of [ ] [COMMON SEAL] in the presence of: ................................................. [SIGNATURE OF DIRECTOR / SIGNATURE OF AUTHORISED SIGNATORY] Director .................................................. [SIGNATURE OF DIRECTOR/SECRETARY] [Director OR Secretary] OR EXECUTED AS A DEED by the parties on the date which first appears in this Deed. Executed as a deed by [ ] acting by [NAME OF DIRECTOR], a director, in the presence of: ………………………… [SIGNATURE OF DIRECTOR] Director ............................. [SIGNATURE OF WITNESS] [NAME OF WITNESS [IN BLOCK CAPITALS]] [ADDRESS OF WITNESS] [OCCUPATION OF WITNESS] nec4 Professional Service Short Services Contract A contract between and for Contract Forms Contract Data Part one – Data provided by the Employer 1 General The Consultant’s Offer Price List Scope Notes about the conditions of contract are printed in boxes like this one. They are not part the core clauses and the clauses for main Option [A, C, E, G], dispute resolution Option [W1 or W2] and secondary Options [X1, X2, X3, X4, X5, X6, X7, X8, X9, X10, X11, X12, X18, X19, X20, Y(UK)1, Y(UK)2], [Y(UK)3] and Z of the NEC3 Professional Services Contract (April 2013). The Employer is [ insert name and address of contracting authority ] The Adjudicator is the person agreed by the Parties from the list of Adjudicators published by the Institution of Civil Engineers or nominated by the Adjudicator nominating body in the absence of agreement. [Replace with Chartered Institute of Arbitrators for non-engineering services] The services are [….]. The Scope is in [schedule [ ] of the Framework Agreement….]. The language of this contract Contract Data The Client’s Contract Data The Client is Name Address for communications Address for electronic communications The service is q The starting date is The completion date is The delay damages are per day English. The law of the contract is the law of [England and Wales],[Scotland] or [Northern Ireland] [and the Courts of the country selected above, shall have exclusive jurisdiction with regard to any dispute in connection with this Agreement and the Parties irrevocably agree to submit to the jurisdiction of those courts]. [Where legislation is expressly mentioned in this Call Off Contract the legislation of the country selected here, shall have the effect of substituting the equivalent country’s legislation] The period for reply is [two weeks]. [If periods other than 2 weeks are required for certain communications, identify them here and add “all other communications … 2 weeks”] The defects date period for retention is weeks after [6/12] years following Completion The assessment date or earlier termination. (If the Call Off Contract is executed as a deed, then select 12 years. If the of each month The United Kingdom Housing Grants, Construction and Regeneration Act (1996Call Off Contract is signed as a simple contract then select 6 years) does/does not apply (delete as applicable) The Adjudicator is: Name Address for communications Address for electronic communications Contract Data The Client’s Contract Data The interest rate on late payments is % per complete week of delay Insert a rate only if a rate less than 0.5% per week of delay has been agreed. The Client provides this insurance Only enter details here if the Client is to provide insurance. The Consultant provides the following insurance cover q INSURANCE AGAINST MINIMUM AMOUNT OF COVER PERIOD FOLLOWING COMPLETION OR EARLIER TERMINATION Liability of the Consultant for claims made against it arising out of the Consultant's failure to use the skill and care normally used by professionals providing services similar to the service. in respect of each claim, without limit to the number of claims Loss of or damage to property and liability for bodily injury to or death of a person (not an employee of the Consultant) arising from or in connection with the Consultant Providing the Service in respect of each event, without limit to the number of events Liability for death of or bodily injury to employees of the Consultant arising out of and in the course of their employment in connection with the contract in respect of each event, without limit to the number of events The Consultant’s total liability to the Client which arises under or in connection with the contract is limited to The Adjudicator nominating body is: is the [Institution of Civil Engineers] [Chartered Institute of Arbitrators] [other nominating body] The tribunal is: If the tribunal is [litigation] or [arbitration, the arbitration procedure is Contract Data The Client’s Contract Data The conditions of contract are the NEC4 Professional Service Short Contract June 2017 incorporating amendments January 2019 and October 2020 and the following additional conditions Only enter details here if additional conditions are required Option Z2 Identified and defined terms [applies][does not apply] Option Z4 Admittance to Client’s Premises [applies][does not apply] Option Z5 Prevention of fraud and bribery [applies][does not apply] Option Z6 Equality and Diversity [applies][does not apply] Option Z7 Legislation and Official Secrets [applies][does not apply] Option Z8 Conflict of Interest [applies][does not apply] Option Z9 Publicity and Branding [applies][does not apply] Option Z10 Freedom of information [applies][does not apply] Option Z13 Confidentiality and Information Sharing [applies][does not apply] Option Z14 Security Requirements [applies][does not apply] Option Z16 Tax Compliance [applies][does not apply] Option Z22 Fair payment [applies][does not apply] Option Z26 Building Information Modelling [applies][does not apply] the information execution plan is …………………… Option Z42 The Housing Grants, Construction and Regeneration Xxx 0000 [applies][does not apply] Option Z44 Intellectual Property Rights [applies][does not apply] Option Z45 HMRC Requirements [applies][does not apply] Option Z46 MoD DEFCON Requirements [applies][does not apply] Option Z47 Small and Medium Sized Enterprises (SMEs) [applies][does not apply] The percentage of the Consultant’s subcontractors required to following matters will be SMEs is …………. % Option Z48 Apprenticeships [applies][does not apply] Option Z49 Change of Control [applies][does not apply] Option Z50 Financial Standing [applies][does not apply] Option Z51 Financial Distress [applies][does not apply] Option Z52 Records, audit access and open book data [applies][does not apply] Option Z100 Data Protection [applies][does not apply] Option Z101 Cyber Essentials [applies][does not apply] Other additional conditions [insert details/reference of any other additional conditions required by the Client] Contract Data The Consultant’s Contract Data The Consultant is Name Address for communications Address for electronic communications The service is q The starting date is The completion date is The delay damages are per day The fee percentage is % The people rates are category of person unit rate If the work is to be carried out on a time change basis the Consultant includes people rates for its own people as well as people provided by a subcontractor The key persons are Name Job Responsibilities Qualifications Experience Name Job Responsibilities Qualifications Experience The Consultant’s Offer The Consultant offers to Provide the Service in accordance with these conditions of contract for an amount to be determined in accordance with these conditions of contract. The offered total of the prices is Enter the total of the Prices from the Price List. If all work is to be carried out on a time charge basis, enter ‘Not Applicable’ Price List “The contract does not provide for the Consultant to be paid on a mixture of time charge and Prices and one or the other must be selected. If the work is to be paid on a time charge basis, only expenses should be included. No other entries should be made in the Price List. If the Consultant is to be paid on a priced basis the entries in the first four columns are made by either the Client of the tenderer. For each row: If the Consultant is to be paid an amount for the item which is not adjusted if the quantity of work in the item changes, the tenderer enters the amount in the Price column only. If the Consultant is to be paid an amount for the item of work and which is the rate for the work multiplied by the quantity completed, the tenderer enters the rate which is then multiplied by the expected quantity to produce the Price, which is also entered. Costs incurred by the Consultant other than the listed expenses are included in the Rates and Prices and the People Rates. If expenses are paid at cost, then 'at cost' should be entered into the Rate column. Delete or strike through unused rows. ITEM NUMBER DESCRIPTION UNIT EXPECTED QUANTITY RATE PRICE The total of the PricesRisk Register [….].
Appears in 1 contract
Samples: Form of Agreement
IT IS AGREED AS FOLLOWS. The Client will pay the Consultant the amount due and carry out his duties in accordance with the conditions of contract identified in the Contract Data and the Contract Schedules. The Consultant will Provide the Service in accordance with the conditions of contract identified in the Contract Data and the Contract Schedules. This contract incorporates the conditions of contract in the form of the NEC4 Professional Services Short Contract June 2017 Edition incorporating amendments January 2019 and October 2020 and incorporating the additional conditions specified in the Client’s Contract Data, which form this contract together with the documents referred to in it. References in the NEC4 Professional Services Short Contract June 2017 Edition incorporating amendments January 2019 and October 2020 to "the contract" are references to this contract. This contract [and the Framework Agreement] is the entire agreement between the parties in relation to the service and supersedes and extinguishes all prior arrangements, understandings, agreements, statements, representations or warranties (whether written or oral) relating thereto. Neither party has been given, nor entered into this contract in reliance on any arrangements, understandings, agreements, statements, representations or warranties other than those expressly set out in this agreement. Nothing in clauses 4 or 5 shall exclude liability in respect of misrepresentations made fraudulently. [Execution note Appropriate execution provisions will need to be inserted here depending upon whether the Call Off Contract is to be executed as a deed (meaning the contract will have a limitation period of 12 years) or a simple contract under hand (meaning that the contract will have a limitation period of only 6 years) and how each entity intends to effect the execution. Example execution clauses are set out below and customer guidance concerning the options can be obtained from Crown Commercial Service. Contracting Authorities will need to check with the relevant company as to which option is required.] [General note Access to the NEC suite of contracts, including guidance and membership details can be found via the NEC Website: xxxxx://xxx.xxxxxxxxxxx.xxx/ Additionally, Crown Commercial Service has worked together with NEC to provide discounted access to the suite of contracts . Further information can be found on the Project Management and Full Design Team Services Framework Agreement Webpage: xxxx://xxx-xxxxxxxxxx.xxxxxxxxxxxxx.xxx.xx/project-management-and-full-design-team-services-rm [ ] Example execution clauses: (Note: the following signature blocks need to be adapted to reflect the specific requirements of the relevant parties who are executing the Call Off Contract as a Deed. The following is an example only) Executed under hand [Signed by [NAME OF DIRECTOR] for and on behalf of [NAME OF COMPANY] ............................... [SIGNATURE OF DIRECTOR] Director OR Executed as a deed EXECUTED AS A DEED by the parties on the date which first appears in this Deed. EXECUTED (but not delivered until the date hereof) AS A DEED by [ ] acting by: - Director _________________________ Director/Secretary_________________________ OR EXECUTED AS A DEED by the parties on the date which first appears in this Deed. EXECUTED (but not delivered until the date hereof) AS A DEED by [ ] acting by:- Authorised Signatory_________________________ Authorised Signatory_________________________ OR EXECUTED AS A DEED by the parties on the date which first appears in this Deed. Executed as a deed by affixing the common seal of [ ] [COMMON SEAL] in the presence of: ................................................. [SIGNATURE OF DIRECTOR / SIGNATURE OF AUTHORISED SIGNATORY] Director .................................................. [SIGNATURE OF DIRECTOR/SECRETARY] [Director OR Secretary] OR EXECUTED AS A DEED by the parties on the date which first appears in this Deed. Executed as a deed by [ ] acting by [NAME OF DIRECTOR], a director, in the presence of: ………………………… [SIGNATURE OF DIRECTOR] Director ............................. [SIGNATURE OF WITNESS] [NAME OF WITNESS [IN BLOCK CAPITALS]] [ADDRESS OF WITNESS] [OCCUPATION OF WITNESS] nec4 Professional Service Short Contract A contract between and for Contract Forms Contract Data The Consultant’s Offer Price List Scope Notes about the contract are printed in boxes like this one. They are not part of the contract Contract Data The Client’s Contract Data The Client is Name Address for communications Address for electronic communications The service is q The starting date is The completion date is The delay damages are per day The law of the contract is The period for reply is weeks The defects date is weeks after Completion The assessment date is the of each month The United Kingdom Housing Grants, Construction and Regeneration Act (1996) does/does not apply (delete as applicable) The Adjudicator is: Name Address for communications Address for electronic communications Contract Data The Client’s Contract Data The interest rate on late payments is % per complete week of delay Insert a rate only if a rate less than 0.5% per week of delay has been agreed. The Client provides this insurance Only enter details here if the Client is to provide insurance. The Consultant provides the following insurance cover q INSURANCE AGAINST MINIMUM AMOUNT OF COVER PERIOD FOLLOWING COMPLETION OR EARLIER TERMINATION Liability of the Consultant for claims made against it arising out of the Consultant's failure to use the skill and care normally used by professionals providing services similar to the service. in respect of each claim, without limit to the number of claims Loss of or damage to property and liability for bodily injury to or death of a person (not an employee of the Consultant) arising from or in connection with the Consultant Providing the Service in respect of each eventclaim, without limit to the number of events claims Liability for death of or bodily injury to employees of the Consultant arising out of and in the course of their employment in connection with the contract in respect of each eventclaim, without limit to the number of events claims The Consultant’s total liability to the Client which arises under or in connection with the contract is limited to The Adjudicator nominating body is: The tribunal is: If the tribunal is arbitration, the arbitration procedure is Contract Data The Client’s Contract Data The conditions of contract are the NEC4 Professional Service Short Contract June 2017 incorporating amendments January 2019 and October 2020 and the following additional conditions Only enter details here if additional conditions are required Option Z2 Identified and defined terms [applies][does not apply] Option Z4 Admittance to Client’s Premises [applies][does not apply] Option Z5 Prevention of fraud and bribery [applies][does not apply] Option Z6 Equality and Diversity [applies][does not apply] Option Z7 Legislation and Official Secrets [applies][does not apply] Option Z8 Conflict of Interest [applies][does not apply] Option Z9 Publicity and Branding [applies][does not apply] Option Z10 Freedom of information [applies][does not apply] Option Z13 Confidentiality and Information Sharing [applies][does not apply] Option Z14 Security Requirements [applies][does not apply] Option Z16 Tax Compliance [applies][does not apply] Option Z22 Fair payment [applies][does not apply] Option Z26 Building Information Modelling [applies][does not apply] the information execution plan is …………………… Option Z42 The Housing Grants, Construction and Regeneration Xxx 0000 Act 1996 [applies][does not apply] Option Z44 Intellectual Property Rights [applies][does not apply] Option Z45 HMRC Requirements [applies][does not apply] Option Z46 MoD DEFCON Requirements [applies][does not apply] Option Z47 Small and Medium Sized Enterprises (SMEs) [applies][does not apply] The percentage of the Consultant’s subcontractors required to be SMEs is …………. % Option Z48 Apprenticeships [applies][does not apply] Option Z49 Change of Control [applies][does not apply] Option Z50 Financial Standing [applies][does not apply] Option Z51 Financial Distress [applies][does not apply] Option Z52 Records, audit access and open book data [applies][does not apply] Option Z100 Data Protection [applies][does not apply] Option Z101 Cyber Essentials [applies][does not apply] Other additional conditions [insert details/reference of any other additional conditions required by the Client] Contract Data The Consultant’s Contract Data The Consultant is Name Address for communications Address for electronic communications The service is q The starting date is The completion date is The delay damages are per day The fee percentage is % The people rates are category of person unit rate If the work is to be carried out on a time change basis the Consultant includes people rates for its own people as well as people provided by a subcontractor The key persons are Name Job Responsibilities Qualifications Experience Name Job Responsibilities Qualifications Experience The Consultant’s Offer The Consultant offers to Provide the Service in accordance with these conditions of contract for an amount to be determined in accordance with these conditions of contract. The offered total of the prices is Enter the total of the Prices from the Price List. If all work is to be carried out on a time charge basis, enter ‘Not Applicable’ Price List “The contract does not provide for the Consultant to be paid on a mixture of time charge and Prices and one or the other must be selected. If the work is to be paid on a time charge basis, only expenses should be included. No other entries should be made in the Price List. If the Consultant is to be paid on a priced basis the entries in the first four columns are made by either the Client of the tenderer. For each row: If the Consultant is to be paid an amount for the item which is not adjusted if the quantity of work in the item changes, the tenderer enters the amount in the Price column only. If the Consultant is to be paid an amount for the item of work and which is the rate for the work multiplied by the quantity completed, the tenderer enters the rate which is then multiplied by the expected quantity to produce the Price, which is also entered. Costs incurred by the Consultant other than the listed expenses are included in the Rates and Prices and the People Rates. If expenses are paid at cost, then 'at cost' should be entered into the Rate column. Delete or strike through unused rows. ITEM NUMBER DESCRIPTION UNIT EXPECTED QUANTITY RATE PRICE The total of the Prices.
Appears in 1 contract
Samples: Template Call Off Agreement
IT IS AGREED AS FOLLOWS. The Client Employer will pay the Consultant the amount due and carry out his duties in accordance with the conditions of contract identified in the Contract Data and the Contract Schedules. The Consultant will Provide the Service Services in accordance with the conditions of contract identified in the Contract Data and the Contract Schedules. This contract incorporates the conditions of contract in the form of the NEC4 Professional Services Short Call Off Contract June 2017 Edition incorporating amendments January 2019 and October 2020 and incorporating the additional conditions specified in the Client’s Contract Data, which form this contract together with the documents referred to in it. References in the NEC4 Professional Services Short Contract June 2017 Edition incorporating amendments January 2019 and October 2020 to "the contract" are references to this contract. This contract [and the Framework Agreement] is the entire agreement between the parties in relation to the service services and supersedes and extinguishes all prior arrangements, understandings, agreements, statements, representations or warranties (whether written or oral) relating thereto. Neither party has been given, nor entered into this contract agreement in reliance on any arrangements, understandings, agreements, statements, representations or warranties other than those expressly set out in this agreement. Nothing in clauses 3 or 4 or 5 shall exclude liability in respect of misrepresentations made fraudulently. The Contract Schedules are: [TUPE Schedules] [Template collateral warranty in favour of a beneficiary] [Template Deed of Guarantee] [Security Policy] [Employer’s Code of Conduct] [Other details to be inserted here] [Execution note Appropriate execution provisions will need to be inserted here depending upon whether the Call Off Contract is to be executed as a deed (meaning the contract will have a limitation period of 12 years) or a simple contract under hand (meaning that the contract will have a limitation period of only 6 years) and how each entity intends to effect the execution. Example execution clauses are set out below and customer guidance concerning the options can be obtained from Crown Commercial Service. Contracting Authorities will need to check with the relevant company as to which option is required.] [General note Access to the NEC suite of contracts, including guidance and membership details can be found via the NEC Website: xxxxx://xxx.xxxxxxxxxxx.xxx/ Additionally, Crown Commercial Service has worked together with NEC to provide discounted access to the suite of contracts . Further information can be found on the Project Management and Full Design Team Services Framework Agreement Webpage: xxxx://xxx-xxxxxxxxxx.xxxxxxxxxxxxx.xxx.xx/project-management-and-full-design-team-services-rm [ xxxx://xxx-xxxxxxxxxx.xxxxxxxxxxxxx.xxx.xx/project-management-and-full-design-team-services-rm3741 Contracting Authorities are able to select the most appropriate W, X, Y and Z clauses and include additional Z clauses that meet their requirement.] Example execution clauses: (Note: the following signature blocks need to be adapted to reflect the specific requirements of the relevant parties who are executing the Call Off Contract as a Deed. The following is an example only) Executed under hand [Signed by [NAME OF DIRECTOR] for and on behalf of [NAME OF COMPANY] ............................... [SIGNATURE OF DIRECTOR] Director OR Executed as a deed EXECUTED AS A DEED by the parties on the date which first appears in this Deed. EXECUTED (but not delivered until the date hereof) AS A DEED by [ ] acting by: - Director _________________________ Director/Secretary_________________________ OR EXECUTED AS A DEED by the parties on the date which first appears in this Deed. EXECUTED (but not delivered until the date hereof) AS A DEED by [ ] acting by:- Authorised Signatory_________________________ Authorised Signatory_________________________ OR EXECUTED AS A DEED by the parties on the date which first appears in this Deed. Executed as a deed by affixing the common seal of [ ] [COMMON SEAL] in the presence of: ................................................. [SIGNATURE OF DIRECTOR / SIGNATURE OF AUTHORISED SIGNATORY] Director .................................................. [SIGNATURE OF DIRECTOR/SECRETARY] [Director OR Secretary] OR EXECUTED AS A DEED by the parties on the date which first appears in this Deed. Executed as a deed by [ ] acting by [NAME OF DIRECTOR], a director, in the presence of: ………………………… [SIGNATURE OF DIRECTOR] Director ............................. [SIGNATURE OF WITNESS] [NAME OF WITNESS [IN BLOCK CAPITALS]] [ADDRESS OF WITNESS] [OCCUPATION OF WITNESS] nec4 Professional Service Short Services Contract A contract between and for Contract Forms Contract Data Part one – Data provided by the Employer 1 General The Consultant’s Offer Price List Scope Notes about the conditions of contract are printed in boxes like this one. They are not part the core clauses and the clauses for main Option [A, C, E], dispute resolution Option [W1 or W2] and secondary Options [X1, X2, X3, X4, X5, X6, X7, X8, X9, X10, X11, X12, X18, X19, X20, Y(UK)1, Y(UK)2], Y(UK)3 and Z of the NEC3 Professional Services Contract (April 2013). The Employer is [ insert name and address of contracting authority ] The Adjudicator is the person agreed by the Parties from the list of Adjudicators published by the Institution of Civil Engineers or nominated by the Adjudicator nominating body in the absence of agreement. [Replace with Chartered Institute of Arbitrators for non-engineering services] The services are [….]. The Scope is in [schedule [ ] of the Framework Agreement….]. The language of this contract Contract Data The Client’s Contract Data The Client is Name Address for communications Address for electronic communications The service is q The starting date is The completion date is The delay damages are per day English. The law of the contract is the law of [England and Wales],[Scotland] or [Northern Ireland] [and the Courts of the country selected above, shall have exclusive jurisdiction with regard to any dispute in connection with this Agreement and the Parties irrevocably agree to submit to the jurisdiction of those courts]. [Where legislation is expressly mentioned in this Call Off Contract the legislation of the country selected here, shall have the effect of substituting the equivalent country’s legislation] The period for reply is [two weeks]. [If periods other than 2 weeks are required for certain communications, identify them here and add “all other communications … 2 weeks”] The defects date period for retention is weeks after [6/12] years following Completion The assessment date or earlier termination. (If the Call Off Contract is executed as a deed, then select 12 years. If the of each month The United Kingdom Housing Grants, Construction and Regeneration Act (1996Call Off Contract is signed as a simple contract then select 6 years) does/does not apply (delete as applicable) The Adjudicator is: Name Address for communications Address for electronic communications Contract Data The Client’s Contract Data The interest rate on late payments is % per complete week of delay Insert a rate only if a rate less than 0.5% per week of delay has been agreed. The Client provides this insurance Only enter details here if the Client is to provide insurance. The Consultant provides the following insurance cover q INSURANCE AGAINST MINIMUM AMOUNT OF COVER PERIOD FOLLOWING COMPLETION OR EARLIER TERMINATION Liability of the Consultant for claims made against it arising out of the Consultant's failure to use the skill and care normally used by professionals providing services similar to the service. in respect of each claim, without limit to the number of claims Loss of or damage to property and liability for bodily injury to or death of a person (not an employee of the Consultant) arising from or in connection with the Consultant Providing the Service in respect of each event, without limit to the number of events Liability for death of or bodily injury to employees of the Consultant arising out of and in the course of their employment in connection with the contract in respect of each event, without limit to the number of events The Consultant’s total liability to the Client which arises under or in connection with the contract is limited to The Adjudicator nominating body is: is the [Institution of Civil Engineers] [Chartered Institute of Arbitrators] [other nominating body] The tribunal is: If the tribunal is [litigation] or [arbitration, the arbitration procedure is Contract Data The Client’s Contract Data The conditions of contract are the NEC4 Professional Service Short Contract June 2017 incorporating amendments January 2019 and October 2020 and the following additional conditions Only enter details here if additional conditions are required Option Z2 Identified and defined terms [applies][does not apply] Option Z4 Admittance to Client’s Premises [applies][does not apply] Option Z5 Prevention of fraud and bribery [applies][does not apply] Option Z6 Equality and Diversity [applies][does not apply] Option Z7 Legislation and Official Secrets [applies][does not apply] Option Z8 Conflict of Interest [applies][does not apply] Option Z9 Publicity and Branding [applies][does not apply] Option Z10 Freedom of information [applies][does not apply] Option Z13 Confidentiality and Information Sharing [applies][does not apply] Option Z14 Security Requirements [applies][does not apply] Option Z16 Tax Compliance [applies][does not apply] Option Z22 Fair payment [applies][does not apply] Option Z26 Building Information Modelling [applies][does not apply] the information execution plan is …………………… Option Z42 The Housing Grants, Construction and Regeneration Xxx 0000 [applies][does not apply] Option Z44 Intellectual Property Rights [applies][does not apply] Option Z45 HMRC Requirements [applies][does not apply] Option Z46 MoD DEFCON Requirements [applies][does not apply] Option Z47 Small and Medium Sized Enterprises (SMEs) [applies][does not apply] The percentage of the Consultant’s subcontractors required to following matters will be SMEs is …………. % Option Z48 Apprenticeships [applies][does not apply] Option Z49 Change of Control [applies][does not apply] Option Z50 Financial Standing [applies][does not apply] Option Z51 Financial Distress [applies][does not apply] Option Z52 Records, audit access and open book data [applies][does not apply] Option Z100 Data Protection [applies][does not apply] Option Z101 Cyber Essentials [applies][does not apply] Other additional conditions [insert details/reference of any other additional conditions required by the Client] Contract Data The Consultant’s Contract Data The Consultant is Name Address for communications Address for electronic communications The service is q The starting date is The completion date is The delay damages are per day The fee percentage is % The people rates are category of person unit rate If the work is to be carried out on a time change basis the Consultant includes people rates for its own people as well as people provided by a subcontractor The key persons are Name Job Responsibilities Qualifications Experience Name Job Responsibilities Qualifications Experience The Consultant’s Offer The Consultant offers to Provide the Service in accordance with these conditions of contract for an amount to be determined in accordance with these conditions of contract. The offered total of the prices is Enter the total of the Prices from the Price List. If all work is to be carried out on a time charge basis, enter ‘Not Applicable’ Price List “The contract does not provide for the Consultant to be paid on a mixture of time charge and Prices and one or the other must be selected. If the work is to be paid on a time charge basis, only expenses should be included. No other entries should be made in the Price List. If the Consultant is to be paid on a priced basis the entries in the first four columns are made by either the Client of the tenderer. For each row: If the Consultant is to be paid an amount for the item which is not adjusted if the quantity of work in the item changes, the tenderer enters the amount in the Price column only. If the Consultant is to be paid an amount for the item of work and which is the rate for the work multiplied by the quantity completed, the tenderer enters the rate which is then multiplied by the expected quantity to produce the Price, which is also entered. Costs incurred by the Consultant other than the listed expenses are included in the Rates and Prices and the People Rates. If expenses are paid at cost, then 'at cost' should be entered into the Rate column. Delete or strike through unused rows. ITEM NUMBER DESCRIPTION UNIT EXPECTED QUANTITY RATE PRICE The total of the PricesRisk Register [….].
Appears in 1 contract
Samples: Project Management And