Jurisdictional Disputes 17.01 A xxxx-up meeting will be held with each Contractor not later than the commencement of the Contractor's work on all projects and no assignments shall be made before this xxxx- up. Xxxx-up assignments shall also apply to all sub-contractors. If a jurisdictional dispute arises once the work has commenced, assignments will be made in accordance with procedures, rules and regulations of the National Joint Board Building Trades Department, A.F.L. & C.I.O. The work assignment shall not be completed until a meeting on site has been convened with all Parties involved and until a subsequent meeting (not later than twenty-four (24) hours) has taken place, at which the Contractor shall present the work assignment on paper to all Parties.
17.02 In the event such jurisdictional dispute cannot be settled on a Local basis by the Unions involved, such dispute shall be submitted to the International Unions involved for settlement without permitting it to interfere in any way with the progress of the work at any time. In the event the dispute is not settled by the International Unions involved, it shall then be submitted to the National Joint Board for resolution. It is understood and agreed, however, that if the dispute causes any delay in the progress of the work or gives rise to an apprehended delay, any of the Parties hereto may apply to the Labour Relations Board (Nova Scotia) Construction Panel for an Interim Order under Section 50 of the Trade Union Act, Chapter 311, R.S.N.S. 1967, amended.
Non-Jurisdictional Entities LIPA and NYPA do not waive their exemptions, pursuant to Section 201(f) of the FPA, from Commission jurisdiction with respect to the Commission’s exercise of the FPA’s general ratemaking authority.
Jurisdiction; Governing Law For all matters relating to the interpretation and fulfillment of this Agreement, the parties hereto expressly and irrevocably submit to the applicable laws of Mexico, and to the jurisdiction of the competent courts sitting in Mexico, Federal District, Mexico, with respect to any action or proceeding arising out of or relating hereto, and the parties hereby expressly and irrevocably waive all rights to any other jurisdiction to which they may be entitled to by reason of their present or future domiciles, or by any other reason.
Jurisdiction of Organization During the term of the Receivables, CNHICA will maintain its “location” (as defined in Section 9-307 of the UCC) in one of the States.
Jurisdiction and Service of Process Any Proceeding arising out of or relating to this procurement process or any contract issued by TIPS resulting from or any contemplated transaction shall be brought in a court of competent jurisdiction in Camp County, Texas and each of th e parties irrevocably submits to the exclusive jurisdiction of said court in any such proceeding, waives any objection it may no w or hereafter have to venue or to convenience of forum, agrees that all claims in respect of the Proceeding shall be heard and de termined only in any such court, and agrees not to bring any proceeding arising out of or relating to this procurement process or an y contract resulting from or any contemplated transaction in any other court. The parties agree that either or both of them may file a co py of this paragraph with any court as written evidence of the knowing, voluntary and freely bargained for agreement between the partie s irrevocably to waive any objections to venue or to convenience of forum. Process in any Proceeding referred to in the first senten ce of this Section may be served on any party anywhere in the world. Venue clauses in contracts with TIPS members may be determin ed by the parties. Not a negotiable term. Failure to agree will render your proposal non-responsive and it will not be considered. Do y ou agree to these terms? Yes The successful vendor will be expected to indemnify and hold harmless the TIPS and its employees, officers, agents , representatives, contractors, assignees and designees from any and all third party claims and judgments involving infringement of patent, copyright, trade secrets, trade or service marks, and any other intellectual or intangible prop erty rights attributed to or claims based on the Vendor's proposal or Vendor’s performance of contracts awarded an d approved. Do you agree to these terms? Yes, I Agree
Governing Laws and Jurisdiction This Agreement shall be deemed to have been executed and to be performed within the State of California and shall be construed and governed by the internal laws of the State of California. Any legal proceedings arising out of or relating to this Agreement shall be brought in Sacramento County, California.
Jurisdiction of Courts Québec hereby appoints the person from time to time who holds the position of Delegate General of Québec in New York, Xxx Xxxxxxxxxxx Xxxxx, 00xx xxxxx, Xxx Xxxx, Xxx Xxxx 00000-0000, as its authorized agent (the “Authorized Agent”) upon whom process may be served in any action by any Underwriter, or by any person controlling such Underwriter, and based upon this Agreement which may be instituted in any State or Federal court in The City of New York, and expressly accepts the non-exclusive jurisdiction of any such court in respect of such action. Québec hereby irrevocably waives any immunity to service of process in respect of any such action to which the Authorized Agent might otherwise be entitled. Such appointment shall be irrevocable as long as any of the Securities remain outstanding, except that, if for any reason the Authorized Agent ceases to be able to act as agent or no longer has an address in The City of New York, Québec will appoint another person or persons in The City of New York, selected in its discretion, as Authorized Agent(s). Québec will take any and all action, including the filing of any and all documents and instruments that may be necessary to continue such appointment or appointments in full force and effect as aforesaid. Service of process upon the Authorized Agent together with written notice of such service mailed or delivered to Québec at its address set forth in Section 11, shall be deemed in every respect effective service of process upon Québec. Notwithstanding the foregoing, any action by an Underwriter, or by any person controlling such Underwriter, and based upon this Agreement may be instituted in any competent court in Québec. Québec hereby waives, to the fullest extent permitted by applicable law, any immunity to jurisdiction to which it might otherwise be entitled in any action based on this Agreement which may be instituted as provided in this Section in any State or Federal court in The City of New York or in any competent court in Québec.
Jurisdiction, Etc (a) Each party hereto hereby irrevocably and unconditionally agrees that it will not commence any action, litigation or proceeding of any kind or description, whether in law or equity, whether in contract or in tort or otherwise, against the Administrative Agent, any Lender, any LC Issuing Bank, or any Related Party of the foregoing in any way relating to this Agreement or any other Loan Document or the transactions relating hereto or thereto, in any forum other than the courts of the State of New York sitting in the Borough of Manhattan in New York City, and of the United States District Court of the Southern District of New York sitting in the Borough of Manhattan in New York City, and any appellate court from any thereof, and each of the parties hereto irrevocably and unconditionally submits to the jurisdiction of such courts and agrees that all claims in respect of any such action, litigation or proceeding may be heard and determined in such New York State court or, to the fullest extent permitted by applicable law, in such federal court. Each party hereto agrees that a final judgment in any such action, litigation or proceeding shall be conclusive and may be enforced in other jurisdictions by suit on the judgment or in any other manner provided by law.
(b) The Borrower irrevocably and unconditionally waives, to the fullest extent permitted by Applicable Law, any objection that it may now or hereafter have to the laying of venue of any action or proceeding arising out of or relating to this Agreement or any other Loan Document in any court referred to in paragraph (a) of this Section. Each of the parties hereto hereby irrevocably waives, to the fullest extent permitted by applicable law, the defense of an inconvenient forum to the maintenance of such action or proceeding in any such court.
(c) Each party hereto irrevocably consents to service of process in the manner provided for notices in Section 8.02. Nothing in this Agreement will affect the right of any party hereto to serve process in any other manner permitted by Applicable Law.
Exclusive English jurisdiction Subject to Clause 30.3, the courts of England shall have exclusive jurisdiction to settle any disputes which may arise out of or in connection with this Agreement.
Jurisdictions The Managing Dealer shall cause Shares to be offered and sold only in those jurisdictions specified in writing by the Company for whose account Shares are then offered for sale, and such list of jurisdictions shall be updated by the Company as additional states are added. The Company shall specify only such jurisdictions in which the offering and sale of its Shares has been authorized by appropriate State Regulatory Authorities. No Shares shall be offered or sold for the account of the Company in any other states.
