Late Delivery. Supplier shall give DXC prompt notice of any prospective failure to ship Products or provide Services on the delivery date specified by DXC (the “Delivery Date”).
Late Delivery. Without limiting any other rights or obligations of the parties hereunder, if the Supplier will be unable to deliver the goods by the delivery date(s) stipulated in this Purchase Order, the Supplier shall (i) immediately consult with UNDP to determine the most expeditious means for delivering the goods and (ii) use an expedited means of delivery, at the Supplier's cost (unless the delay is due to Force Majeure), if reasonably so requested by UNDP.
Late Delivery. Supplier shall give HP prompt notice of any prospective failure to ship Goods on the delivery date specified by HP (“the Delivery Date”).
Late Delivery. (a) No adjustment shall be made and the Contract Price shall remain unchanged for the first thirty (30) days of delay in delivery of the VESSEL beyond the Delivery Date (ending as of twelve o’clock midnight of the thirtieth (30th) day of delay).
(b) If the delivery of the VESSEL is delayed more than thirty (30) days after the Delivery Date, then, in such event, beginning at twelve o’clock midnight of the thirtieth (30th) day after the Delivery Date, the Contract Price shall be reduced by deducting there from as follows: 31st - 60th day NOK 40.000,- per day 61st - 180th day NOK 50.000,- per day However, the total reduction in the Contract Price shall not be more than as would be the case for a delay of one hundred and fifty (150) days, counting from midnight of the thirtieth (30th) day after the Delivery Date at the above specified rate of reduction, i.e. the maximum reduction shall be NOK 7.200.000,-. If the delay in delivery of the VESSEL should continue for a period of hundred and fifty (150) days from the thirty-first (31st) day after the Delivery Date (adjusted for Permissible Delays), then in such event, and after such period has expired, the BUYER may at its option cancel this Contract in accordance with the provisions of Article VIII hereof. If one hundred and eighty (180) days of delay have elapsed after the Delivery Date (adjusted for Permissible Delays), and provided that the BUYER has not sent notice of cancellation as provided for in Article VIII hereof, the BUILDER may in writing propose a new date for delivery of the VESSEL and demand that the BUYER shall make an election whether to cancel the Contract or accept the proposed new date for delivery, in which case the BUYER shall, within fifteen (15) days after such demand is received by the BUYER, notify the BUILDER of its choice; it being understood that, if the VESSEL is not delivered by such agreed future date, the BUYER shall have the same right to cancel as hereinabove provided. Should the BUYER fail to give such notification within the said fifteen (15) days, the BUYER shall be deemed to have accepted the new date for delivery as proposed by the BUILDER.
Late Delivery. (10/19) In the event that any specified delivery date is not met, Contractor shall be liable for any loss, expense, or damage resulting from delay in delivery or failure to deliver Deliverables or provide Services which is due to any cause except as set forth in Force Majeure. In the event of delay due to any such cause, the City may obtain substitute Services from another source and xxxx all additional costs directly to Contractor who shall remain financially liable for all additional acquisition costs.
Late Delivery. If prior to 5:00 p.m., New York City time, on the Expiration Date you receive (i) payment in full of the Subscription Price for the Units being subscribed for and (ii) a guarantee notice substantially in the form of the Notice of Guaranteed Delivery delivered with the Subscription Certificate, from a financial institution having an office or correspondent in the United States, or a member firm of any registered United States national securities exchange or of the National Association of Securities Dealers, Inc. stating the certificate number of the Subscription Certificate relating to the Rights, the name and address of the exercising subscriber, the number of Rights represented by the Subscription Certificate held by such exercising subscriber, the number of Units being subscribed for pursuant to the Rights and guaranteeing the delivery to you of the Subscription Certificate evidencing such Rights within three business days following the date of the Notice of Guaranteed Delivery, then the Rights may be exercised even though the Subscription Certificate was not delivered to you prior to 5:00 p.m., New York City time, on the Expiration Date, provided that within three business days following the date of the Notice of Guaranteed Delivery you receive the properly completed Subscription Certificate evidencing the Rights being exercised, with signatures guaranteed if required.
Late Delivery. Seller shall provide Purchaser prompt written notice of any events that will or could cause a delay in delivery under the Purchase Order; and
Late Delivery. If the Equipment or licensed program materials are not delivered to the Equipment Location on or before the 15th day after the Estimated Shipment Date, Lessor may, upon written notice to Lessee, increase the Lease Rate. Lessee may terminate the Lease for the affected item by giving Lessor written notice prior to delivery. Otherwise, the Rent shall be adjusted to reflect such increase.
Late Delivery. If Seller fails to perform the services or deliver the Deliverables in accordance with the delivery or performance schedules, or any extension thereof, specified in the Order or otherwise established between the Parties, the Parties mutually agree that, because time is of the essence, the services or Deliverables have a diminished value for Buyer and the price payable therefor shall accordingly be reduced by two-thirds of one percent (0.6667%) of the original price per calendar day of delay. Such price adjustment is without prejudice to any other rights or remedies provided by law or under this Order to Buyer.
Late Delivery. Any PO not completed by Supplier within three (3) months of the agreed delivery date shall be automatically null and void. Snap-on reserves the right to claim indemnification for any damages caused as a result of Supplier’s delivery delays. The foregoing is in addition to any other rights or recourse which Snap-on may have against the Supplier.
