Launch Schedule Adjustments Sample Clauses

Launch Schedule Adjustments. 7.1 Customer Launch Schedule Adjustments Customer may request either a postponement or advancement of the Launch Period, Launch Slot or Launch Date by giving written notice to the Contractor representative set forth in Paragraph 9.2 requesting a new Launch Period, Launch Slot or Launch Date. **** Until a new Launch Period, Launch Slot or Launch Date is selected in accordance with this Paragraph 7.1, the then-current launch schedule shall remain in effect. 7.1.1 If the launch schedule adjustment results in a later Launch Period, Launch Slot or Launch Date, then only the total number of calendar days of delay originally requested by Customer shall be attributed to Customer. Any delay in the Launch Period, Launch Slot or Launch Date resulting from the determination of a Launch Period, Launch Slot or Launch Date, as applicable, by Contractor in excess of the delay requested by Customer shall not be deemed to be attributed to Contractor or Customer; **** 7.1.2 Postponements by Customer under this Article 7 for each Launch Service shall not extend beyond **** except that such date shall be extended by the number of days of Contractor delay or delay not attributable to either party under 7.1.1 or 7.3
Sample 1Sample 2
AutoNDA by SimpleDocs
Launch Schedule Adjustments. Either Party may, at any time prior to Launch, request to accelerate or postpone any Launch Period specified in Table 1, or the relevant Launch Slot or Launch Date, as applicable, as provided below: 3.3.1 Any request or proposal to accelerate or postpone any Launch Service by either Party under this Paragraph 3.3.1 shall be submitted and negotiated in accordance with ARTICLE 22.3, and a subject to the relevant rights and obligations specified in this Contract and EXHIBITS B through E, as applicable, and the scheduling constraints specified in ARTICLE 3.3.3
Sample 1
Launch Schedule Adjustments. 10.1 Changes to the Launch Schedule will be provided to Customer in writing and shall be governed by the following terms and conditions. 10.2 SpaceDev will promptly provide written notice to Customer of any action which will result in the postponement of a Launch. 10.3 In the event of a launch postponement due to an excusable delay under Article 13, "Excusable Delay", herein, the Launch Schedule for the postponed Launch shall be extended for a period of time equal to such period of Excusable Delay.
Sample 1
Launch Schedule Adjustments. 8 ARTICLE 8:
Sample 1
Launch Schedule Adjustments. 7.1 Customer Launch Schedule Adjustments Customer may request either a postponement or advancement of the Launch Period, Launch Slot or Launch Date by giving written notice to the Contractor representative set forth in Paragraph 9.2 requesting a new Launch Period, Launch Slot or Launch Date. The Parties will cooperate in good faith to select a new Launch Period, Launch Slot or Launch Date. However, in the event that the Parties cannot mutually agree within [***] days of Customer’s notice (or such shorter time period as Contractor may determine, in light of the proximity to the Launch), Contractor shall make such determination taking into account the manifest policy set forth in Paragraph 6.4, the available Launch Opportunities as close as possible to Customer’s requested Launch Period, Launch Slot or Launch Date and the other requirements and interests of Customer, and Contractor shall use commercially reasonable efforts to mitigate any postponements in the Launch of the Satellite. Until a new Launch Period, Launch Slot or Launch Date is selected in accordance with this Paragraph 7.1, the then-current launch schedule shall remain in effect. 7.1.1 If the launch schedule adjustment results in a later Launch Period, Launch Slot or Launch Date, then only the total number of calendar days of delay originally requested by Customer shall be attributed to Customer. Any delay in the Launch Period, Launch Slot or Launch Date resulting from the determination of a Launch Period, Launch Slot or Launch Date, as applicable, by Contractor in excess of the delay requested by Customer shall not be deemed to be attributed to Contractor or Customer. 7.1.2 Postponements by Customer under this Article 7 for each Launch Service shall not exceed a total of [***] months. In the event that a single postponement, or cumulative postponements, attributed to Customer exceed such maximum permissible postponement for the Launch Service, the Launch Service shall, at the election of Contractor, be subject to renegotiation. Contractor shall provide Customer a commercially reasonable proposal for equitable adjustment to extend the period of performance of this Contract in order to accommodate Customer’s postponement within [***] of receipt by Contractor of Customer’s postponement notice which exceeds the maximum permissible postponement. [***] The Parties agree to renegotiate the Contract in good faith and in a commercially reasonable manner, within [***] of the date Customer receives Contra...
Sample 1
Launch Schedule Adjustments. 7.1 CUSTOMER LAUNCH SCHEDULE ADJUSTMENTS Without limiting the Customer's rights under Article 8 of this Contract entitled "Excusable Delays", Customer may request either a postponement for the reasons set forth in 7.1(a), 7.1(b) or 7.1(c) or advancement of the Launch Slot or Launch Date previously determined under Article 6 of this Contract entitled "Launch Schedule," by giving notice to Contractor proposing a new Launch Period, Launch Slot or Launch Date. The Parties will cooperate in good faith to select a new Launch Period, Launch Slot or Launch Date. However, in the event that the Parties cannot mutually agree within sixty (60) days of Customer's notice (or such shorter time period as Contractor may determine, in light of the proximity to the Launch), Contractor shall make such determination in good faith taking into account the available Launch Opportunities and the requirements and interests of Customer. Until the new Launch Period, Launch Slot or Launch Date is selected in accordance with this Paragraph 7.1, the then-current launch schedule shall remain in effect. 7.1 (a) The Customer may request a delay (equal to the schedule impact) to the Launch Period, or Launch Slot or Launch Date if established in the event the Satellite manufacturer experiences delays in the delivery schedules of the Satellite.
Sample 1
Launch Schedule Adjustments 
Sample 1Sample 2Sample 3See All (8)
AutoNDA by SimpleDocs

Related to Launch Schedule Adjustments

  • Price Adjustments 17.1 Prices for Goods/Services supplied in terms of this Agreement shall be subject to review as indicated in the Schedule of Requirements/Works Order annexed hereto. 17.2 No less than 2 [two] months prior to any proposed Price adjustment, the Parties shall commence negotiations for Prices for the next period or as otherwise indicated in Schedule 1 hereto. The Parties shall have regard for market-related pricing of equivalent goods, continuous improvement initiatives, costs [including labour, raw materials and transport/delivery], order size and frequency and changes to the specification of the Goods/Services. 17.3 Pursuant to clause 17.2 above, the Supplier/Service Provider shall keep full and accurate records of all costs associated with the supply of the Goods/Services to Transnet, in a form to be approved in writing by Transnet. The Supplier/Service Provider shall produce such records to Transnet for inspection at all reasonable times on request and such records may, at Transnet's option, be audited by Transnet or its designated representatives. 17.4 Should Transnet and the Supplier/Service Provider fail to reach an agreement on Price for the successive period, either Party shall be entitled to submit this matter to dispute resolution in accordance with clause 32 of the Master Agreement [Dispute Resolution]. 17.5 If during the period of this Agreement Transnet can purchase similar Goods/Services of a like quality from another supplier at a total delivered cost to a Transnet facility that is lower than the total delivered cost of the Goods/Services purchased hereunder from the Supplier/Service Provider, Transnet may notify the Supplier/Service Provider of such total delivered cost and the Supplier/Service Provider shall have an opportunity to adjust the Price of the Goods/Services purchased hereunder, on such a basis as to result in the same total delivered cost to Transnet, within 30 [thirty] calendar days of such notice. If the Supplier/Service Provider fails to do so or cannot legally do so, Transnet may (i) purchase the Goods/Services from such other supplier in which case the obligations, including, but not limited to, any purchase and sale requirements and/or commitments, if any, of Transnet and the Supplier/Service Provider hereunder shall be reduced accordingly; (ii) terminate this Agreement without any penalty, liability or further obligation; or (iii) continue purchases under this Agreement. 17.6 If during the period of this Agreement the Supplier/Service Provider sells any materials which are the same as, equivalent to, or substantially similar to the Goods/Services herein, at a total delivered cost to a third party lower than the total delivered cost to a Transnet facility, then the Supplier/Service Provider has an opportunity to adjust its Price for the Goods/Services purchased hereunder within 30 [thirty] calendar days so that the Price is the same or lower than the total delivered cost of such third party. If the Supplier/Service Provider fails to do so or cannot legally do so, Transnet may (i) purchase the Goods/Services from any other such supplier, in which case the obligations, including, but not limited to, any purchase and sale requirements and/or commitments, if any, of Transnet and the Supplier/Service Provider hereunder shall be reduced accordingly; or

  • Price Adjustments for OGS Centralized Contracts Periodic price adjustments will occur no more than twice per year on a schedule to be established solely by OGS. Pricing offered shall be fixed for the first twelve (12) months of the Contract term. Such price increases will only apply to the OGS Centralized Contracts and shall not be applied retroactively to Authorized User Agreements or any Mini-bids already submitted to an Authorized User. Price decreases may be made at any time. Additionally, some price decreases shall be calculated in accordance with Appendix B, section 17, Pricing.

  • Purchase Price Adjustments (a) The Parties agree that, so long as any distributions made are reflected in Closing Working Capital and in any adjustments to the Purchase Price under Section 1.4(c), the Seller shall have the right, at or prior to the Closing, to cause the Company to distribute cash to the Seller or its Affiliates, by one or more dividends and/or other distributions. (b) Within 90 calendar days following the Closing, the Buyer shall prepare, or cause to be prepared, and deliver to the Seller a statement (the “Closing Statement”), in accordance with the Accounting Principles, which shall include (i) a balance sheet of the Company as of the Closing Date, (ii) a calculation of the total Working Capital of the Company as of the Closing Date (the “Closing Working Capital”), (iii) a calculation of the Working Capital Deficit or the Working Capital Excess, as the case may be (which, for the avoidance of doubt, shall include the Buyer’s calculation of the Target Working Capital), (iv) a calculation of Closing Cash, (v) a calculation of Closing Indebtedness, (vi) a calculation of Transaction Expenses and (vii) the Buyer’s determination of the final Purchase Price (the “Final Purchase Price”) resulting therefrom. For purposes of the Buyer’s preparation of the Closing Statement, the Seller shall make available or provide reasonable access to the Buyer and its Representatives, upon advance notice and during normal business hours, all information, books, records, data and working papers created or used in connection with the preparation of the Estimated Working Capital Certificate, to the extent not in the possession of the Company or the Buyer. The Seller shall have a period of 30 calendar days after delivery of the Closing Statement to review (and cause the Seller’s auditors to review) such documents and make any objections it may have in writing to the Buyer. For purposes of the Seller’s evaluation of the Closing Statement, the Buyer shall, and shall cause the Company to, make available or provide reasonable access to the Seller and its Representatives, upon advance notice and during normal business hours, all information, books, records, data and working papers created or used in connection with the preparation of the Closing Statement; and shall permit reasonable access, upon advance notice and during normal business hours, to the facilities and personnel of the Company as may be reasonably requested by the Seller and its Representatives to analyze the Closing Statement. If the Seller delivers written objections to the Buyer within such 30-day period, then the Buyer and the Seller shall attempt to resolve the matter or matters in dispute. If no written objections are made by the Seller within such 30-day period, then the Closing Statement shall be final and binding on the Parties. If disputes with respect to the Closing Statement cannot be resolved by the Buyer and the Seller within 30 calendar days after timely delivery of any objections thereto, then, at the request of the Buyer or the Seller, the specific matters in dispute (but no others) shall be submitted to such independent accounting firm as may be approved by the Seller and the Buyer (the “Auditors”), which firm shall render its opinion as to such specific matters. If no such referral is made within 45 calendar days after the delivery of the objections, then the Closing Statement shall be final and binding on the Parties. If all objections are so resolved between the Parties prior to such time, the Closing Statement with such changes as have been agreed in writing by the Buyer and the Seller shall be final and binding on the Parties. The matters to be resolved by the Auditors shall be limited to the remaining unresolved disputes between the Buyer and the Seller. The Parties shall cooperate with the Auditors during its engagement, and the Auditors shall have access to the books and records of the Company and the Buyer, the personnel of, and work papers prepared by, the Parties’ accountants to the extent that they relate to the unresolved disputes as it may reasonably request for the purpose of reviewing such unresolved disputes, provided, that such access shall be in a manner that does not interfere with the normal business operations of the Buyer, the Company or the Seller. The Auditors shall promptly deliver to the Buyer and the Seller a written report setting forth their resolution of the disputes along with their determination of the Final Purchase Price, which determination shall be made in accordance with the definitions and principles set forth in this Agreement and shall be final and binding on the Parties. As to each disputed item, the Auditors shall be limited to awarding only one or the other of the Buyer’s proposal, on the one hand, or the Seller’s proposal, on the other hand, and shall have no authority to select or propose to the Parties any resolution other than as set forth in one of such two proposals originally submitted to the Auditors. Judgment may be entered upon the determination of the Auditors in any court having jurisdiction over the Party against which such determination is to be enforced. The fees and expenses of the Auditors shall be borne by the Parties as designated by the Auditors, which designation shall be based upon the inverse proportion of the amount of disputed items resolved in favor of such Party (i.e., so that the prevailing Party bears a lesser amount of such fees and expenses). If the Parties refer a dispute to the Auditors and if the Adjustment Escrow Funds exceed the amount by which the Estimated Purchase Price is greater than the Final Purchase Price (as claimed by the Buyer), then the Buyer and the Seller shall, pursuant to the terms of the Escrow Agreement, promptly instruct the Escrow Agent to pay the Seller the amount of such excess out of the Adjustment Escrow Funds, and the remaining balance of the Adjustment Escrow Funds shall be paid out pursuant to Section 1.4(c) after the final determination of the Final Purchase Price pursuant to this Section 1.4. (c) If the Estimated Purchase Price is greater than the Final Purchase Price, then within two business days following the final determination thereof, the Buyer and the Seller shall, pursuant to the terms of the Escrow Agreement, instruct the Escrow Agent to pay the Buyer the amount of such excess out of the Adjustment Escrow Funds (and if the balance of the Adjustment Escrow Funds is less than the amount due to the Buyer pursuant to this Section 1.4, then at the Buyer’s option the Buyer may recover the remaining amount from the Indemnity Escrow Funds or require the Seller to pay such amount to the Buyer by wire transfer in immediately available funds to the account or accounts designated by the Buyer). If the Final Purchase Price is greater than the Estimated Purchase Price, then within two business days following the final determination thereof, the Buyer will pay to the Seller by wire transfer in immediately available funds to the account or accounts designated by the Seller the amount of such excess and the Buyer and the Seller shall, pursuant to the terms of the Escrow Agreement, instruct the Escrow Agent to pay the Seller the entire balance of the Adjustment Escrow Funds. Any payments pursuant to this Section 1.4(c) shall be treated as an adjustment to the Purchase Price by the parties for Tax purposes, unless otherwise required by Law.

  • True-Up Adjustments From time to time, until the Retirement of the Recovery Bonds, the Servicer shall identify the need for True-Up Adjustments and shall take all reasonable action to obtain and implement such True-Up Adjustments, all in accordance with the following:

  • Market Adjustments Neither this Article nor any other in this Collective Agreement prevents the Employer from using other funds to increase a Member’s salary in response to offers received from other employers or to accommodate other market forces.

  • Recovery Schedule If the initial schedule or any current updates fail to reflect the Work’s actual plan or method of operation, or a contractual milestone date is more than fifteen (15) days behind, Owner may require that a recovery schedule for completion of the remaining Work be submitted. The Recovery Schedule must be submitted within seven (7) calendar days of Owner’s request. The Recovery Schedule shall describe in detail Construction Contractor’s plan to complete the remaining Work by the required Contract milestone date. The Recovery Schedule submitted shall meet the same requirements as the original Construction Schedule. The narrative submitted with the Recovery Schedule should describe in detail all changes that have been made to meet the Contract milestone dates.

  • Mechanical Adjustments If the Company shall pay a dividend in shares of its Common Stock (other than payments of Common Stock as interest on preferred stock), subdivide (split) its outstanding shares of Common Stock, combine (reverse split) its outstanding shares of Common Stock, issue by reclassification of its shares of Common Stock any shares or other securities of the Company, or distribute as a stock dividend to holders of its Common Stock any securities of the Company or of another entity, the number of shares of Common Stock or other securities the Holder hereof is entitled to purchase pursuant to the Warrants immediately prior thereto shall be adjusted so that the Holder shall be entitled to receive upon exercise the number of shares of Common Stock or other securities which he, she or it would have owned or would have been entitled to receive after the happening of any of the events described above had the Warrant been exercised immediately prior to the happening of such event, and the Exercise Price shall be correspondingly adjusted; provided, however, that no adjustment in the number of shares and/or the Exercise Price shall be required unless such adjustment would require an increase or decrease of at least one percent (1%) in such number and/or price; and provided further, however, that any adjustments which by reason of this Section 11 are not required to be made shall be carried forward and taken into account in any subsequent adjustment. An adjustment made pursuant to this Section 11 shall become effective immediately after the record date in the case of a stock dividend or other distribution and shall become effective immediately after the effective date in the case of a subdivision, combination or reclassification. The Holder shall be entitled to participate in any subscription or other rights offering made to holders of Common Stock as if he, she or it had purchased the full number of shares as to which the Warrant remains unexercised immediately prior to the record date for such rights offering.

  • Fee Adjustments The fixed fees and other fees expressed as stated dollar amounts in this Schedule C and in this Agreement are subject to annual increases, commencing on the one-year anniversary date of the date of this Agreement, in an amount equal to the percentage increase in consumer prices for services as measured by the United States Consumer Price Index entitled “All Services Less Rent of Shelter,” or a similar index should such index no longer be published, since such one-year anniversary or since the date of the last fee increase, as applicable.

  • Price Schedule, Payment Terms and Billing, and Price Adjustments (a) Price Schedule: Price Schedule under this Contract is set forth in Exhibit B.

  • Shift Schedule The words "shift schedule" when used in this Agreement shall mean a timetable of the shifts and off days assigned to a position or group of positions which commences at the beginning of a pay period and includes one complete rotation of said shifts.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!