Opinion of Probable Cost Any opinions of probable Project cost or probable construction cost provided by Engineer are made on the basis of information available to Engineer and on the basis of Engineer’s experience and qualifications and represents its judgment as an experienced and qualified professional engineer. However, since Engineer has no control over the cost of labor, materials, equipment or services furnished by others, or over the contractor(s’) methods of determining prices, or over competitive bidding or market conditions, Engineer does not guarantee that proposals, bids or actual Project or construction cost will not vary from opinions of probable cost Engineer prepares.
Maintenance of the Property Neither Broker nor Brokerage Firm is responsible for maintenance of the 324 Property nor are they liable for damage of any kind occurring to the Property, unless such damage is caused by their negligence or 325 intentional misconduct.
Construction With Other Parts Of The Tariff This ISA shall not be construed as an application for service under Part II or Part III of the Tariff.
Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof. (ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii). (iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii). (iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.
Early Construction of Base Case Facilities Developer may request Connecting Transmission Owner to construct, and Connecting Transmission Owner shall construct, subject to a binding cost allocation agreement reached in accordance with Attachment S to the ISO OATT, including Section 25.8.7 thereof, using Reasonable Efforts to accommodate Developer’s In-Service Date, all or any portion of any System Upgrade Facilities or System Deliverability Upgrades required for Developer to be interconnected to the New York State Transmission System which are included in the Base Case of the Class Year Study for the Developer, and which also are required to be constructed for another Developer, but where such construction is not scheduled to be completed in time to achieve Developer’s In-Service Date.
Maintenance of Total Unencumbered Assets The Company and its Subsidiaries will maintain Total Unencumbered Assets of not less than 200% of the aggregate outstanding principal amount of the Unsecured Debt of the Company and its Subsidiaries on a consolidated basis.
Maintenance of Tangible Net Worth The Borrower shall maintain during each Fiscal Quarter a Tangible Net Worth of not less than the Minimum Tangible Net Worth.
Closing Costs and Prorations Taxes and assessments for the current year, if any, shall be prorated between the prior owner of the Personal Property and Buyer as of the date of closing. Seller shall pay one-half (½) of Closing Agent’s closing and escrow fees. Buyer shall pay one-half (½) of Closing Agent’s closing and escrow fees. In addition, Buyer shall pay all other closing costs, including but not limited to: (1) recording fees for the cost of recording the State Deed; (2) the cost for any title insurance purchased at Buyer’s option; (3) lender fees, if any, together with all associated recording fees, if any;
Costs and Prorations (a) At Closing, the Parties shall prorate, without duplication, as of the Closing Date, the following with respect to the Assets: (i) Solely to the extent (a) payable by the Company and (b) not covered by Section 1.4(a)(iii) or Section 1.4(a)(iv) below, all ad valorem/personal property taxes and current installments of special assessments levied or assessed with respect to the Assets on a daily basis based upon the fiscal year of the appropriate Taxing Authority on an accrual basis. (ii) All prepaid items and deposits applicable to the operation of the Assets covering periods prior to and after the Closing Date, including all utilities (including gas, water and electricity). The Company shall pay, or cause to be paid, prior to the Closing, all such amounts for which a xxxx has been received for which payments are due prior to the Closing Date, and Purchaser shall be credited, and Seller shall be debited, with an amount equal to all utility charges for the period from the last day covered by any such xxxx until the Closing Date if such utilities will continue to be received. (iii) Amounts payable under Leases and Permits and other Assets shall be prorated on an accrual basis. The Company shall pay, or cause to be paid, when due all amounts due thereunder prior to the Closing Date. For such amounts due on or after the Closing Date and reflected on the Closing Statement or the Final Closing Statement, Purchaser shall be credited, and Seller shall be debited, for Seller’s prorated share of such amount. For such amounts due on or after the Closing Date, Seller agrees to pay its prorated share when due or to promptly reimburse Purchaser if paid by Purchaser; provided, however, to the extent funds are available, such amounts shall first be paid from the Escrow Fund. Percentage rents based on advertising revenues for periods including days both before and after the Closing Date, and Seller’s prorated share thereof, shall be estimated in good faith by extrapolating the advertising revenue for the period upon which the percentage rents are based by applying the average monthly revenue for the months (or portions thereof) preceding the Closing, to the months (or portions thereof) following Closing. For the avoidance of doubt, (x) paid-up/pre-paid rental on Sign Locations Leases pre-paid not more than twelve (12) months beyond the Closing Date shall be prorated, but (y) paid-up/pre-paid rental on Sign Locations Leases prepaid more than twelve (12) months beyond the Closing Date and perpetual easements shall not be prorated. (iv) The Purchase Price shall be decreased by: (a) the pro rata portion of the amount of any remaining balance at the Closing Date of credits for advertisements received prior to the Closing Date or other credits due advertisers from Seller or the Company as of the Closing Date; and (b) pre-billed and/or pre-collected accounts receivable items actually collected and for which outdoor advertising services are to be rendered after the Closing Date. (v) The Purchase Price shall be increased by any amounts posted as security deposit by CCOI or any of its Affiliates with respect to any Assumed Contract (which deposits are not being refunded to CCOI or its Affiliates but rather being retained by the counterparties for the Company’s account). (b) Seller has prepared, in good faith, a closing statement (the “Closing Statement”) consistent with the foregoing and otherwise consistent with this Agreement and has delivered it, along with reasonably detailed information showing the manner in which the contents of the Closing Statement were calculated, to Purchaser prior to the date of this Agreement. In preparing the Closing Statement, Seller used the best available information, subject to additional adjustment among the Parties after Closing upon receipt of definitive information or final bills; provided, however, that no such adjustments will be made after the Closing Statement becomes final pursuant to Section 1.4(c). (c) As soon as practicable after the Closing (but in any event within ninety (90) days after the Closing), Seller shall deliver a final Closing Statement (the “Final Closing Statement”) to Purchaser, which Final Closing Statement shall set forth (among the other information described above) the amount of actual Closing Date Indebtedness. Each Party shall provide to the other Party, reasonable access at reasonable times to the books and records of such Party and to appropriate employees and representatives (including independent accountants) as such other Party shall reasonably request in connection with the preparation and review of the Final Closing Statement, or any component thereof or information contained or referred to therein, as the case may be, including all work papers of the accountants who audited, compiled or reviewed such statements or notices (subject to each Party and its representatives entering into any such access letters required by the other Party’s accountants in connection herewith), and shall otherwise cooperate reasonably and in good faith with such other Party to arrive at a final determination of the amounts set forth in the Final Closing Statement. Unless Purchaser notifies Seller in writing within 15 days after Seller’s delivery of the Final Closing Statement of any objection to the matters set forth in the Final Closing Statement (the “Notice of Objection”), the Final Closing Statement shall become final and binding. Any Notice of Objection shall specify in reasonable detail the basis for the objections set forth therein. If Purchaser provides the Notice of Objection to Seller within such 15-day period, Purchaser and Seller shall, during the 30-day period following Seller’s receipt of the Notice of Objection, attempt in good faith to resolve Purchaser’s objections. If Purchaser and Seller are unable to resolve all such objections within such 30-day period, the matters remaining in dispute that were properly included in the Notice of Objection (the “Unresolved Items”) shall be submitted to a nationally recognized independent public accounting firm mutually acceptable to the Parties (the “Accounting Firm”), which Accounting Firm shall resolve such matters; provided that if Purchaser and Seller are unable to agree upon such firm within ten days after the end of such 30-day period, then the Accounting Firm shall be an accounting or valuation firm of national standing appointed by the American Arbitration Association in New York, New York; provided that such firm shall not be the independent auditor of (or otherwise provide services under a contractual arrangement with) either Purchaser (or any of its Affiliates) or Seller (or any of its Affiliates including iHeartMedia, Inc. or any of its Subsidiaries). Each Party shall furnish the Accounting Firm such work papers and other documents and information pertaining to the Unresolved Items still in dispute as the Accounting Firm may reasonably request and shall be afforded an opportunity to discuss such Unresolved Items with the Accounting Firm at such hearing as the Accounting Firm shall request or permit; provided, that (i) each Party shall provide the other Party with a copy of all materials provided to, and communications with, the Accounting Firm, and (ii) no Party (or any of its Affiliates, advisors or representatives) shall engage in any ex parte communication with the Accounting Firm at any time with respect to the Unresolved Items. The Accounting Firm shall only resolve the Unresolved Items. The resolution of the Unresolved Items by the Accounting Firm shall be final and binding, and the determination of the Accounting Firm shall constitute an arbitral award that is final, binding and non-appealable and upon which a judgment may be entered by a court having jurisdiction over the party against which such determination is to be enforced. Purchaser and Seller shall each pay their own costs and expenses incurred under this Section 1.4; provided, however, that the Accounting Firm shall allocate, and Purchaser and Seller shall pay, its fees, costs and expenses between Purchaser and Seller in accordance with the percentage that the portion of the contested amount not awarded to such Parties bears to the amount actually contested by or on behalf of such Parties. (d) Within five (5) Business Days after the Final Closing Statement is finalized pursuant to clause (c) of this Section 1.4: (i) If the Closing Consideration delivered on the Closing Date exceeds the final Purchase Price as adjusted pursuant to this Section 1.4 and contained in the Final Closing Statement; Seller shall pay to Purchaser an amount equal to such excess; and (ii) If the amount of the final Purchase Price as adjusted pursuant to this Section 1.4 and contained in the Final Closing Statement exceeds Closing Consideration delivered on the Closing Date; Purchaser shall pay Seller an amount equal to such excess. Any amount paid with respect to final adjustments to the Purchase Price made pursuant to this Section 1.4 shall be (i) paid by wire transfer of immediately available funds to an account designated by the receiving Party and (ii) treated as an adjustment of the Purchase Price for applicable tax purposes to the extent permitted by Tax Law.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
